Cambridge Massachusetts Building Expert Directory

California Court of Appeal Holds a Tenant Owes No Duty to Protect a Social Guest From a Defective Sidewalk Leading to a Condominium Unit

May 22, 2023 — Garrett A. Smee & Lawrence S. Zucker II - Haight Brown & Bonesteel LLP
On May 5, 2023, the California First District Court of Appeal, Division One, issued an opinion in Moses v. Roger-McKeever (A164405), holding that a condominium tenant owes no duty to a social guest using a walkway that leads to the unit. Eleanor Moses fell on a walkway outside a condo rented by Pascale Roger-McKeever. Moses would not have used the walkway but for Roger-McKeever’s invite to a small gathering for members of a political activist group. Upon entering the condo for the event that night, Moses brought to Roger-McKeever’s attention the poor lighting in the entryway. Roger-McKeever apologized, and stated that her landlord had delayed repairing the porch light. The accident supposedly happened on a short walkway that had three steps leading away from a street sidewalk. Supposedly, Moses tripped on the second step while leaving the social gathering because of the poor lighting. Reprinted courtesy of Garrett A. Smee, Haight Brown & Bonesteel and Lawrence S. Zucker II, Haight Brown & Bonesteel Mr. Smee may be contacted at gsmee@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Avoid the Headache – Submit the Sworn Proof of Loss to Property Insurer

September 28, 2020 — David Adelstein - Florida Construction Legal Updates
Property insurance policies (first party insurance policies) contain post-loss obligations that an insured must (and should) comply with otherwise they risk forfeiting insurance coverage. One post-loss obligation is the insurer’s right to request the insured to submit a sworn proof of loss. Not complying with a post-loss obligation such as submitting a sworn proof of loss can lead to unnecessary headaches for the insured. Most of the times the headache can be avoided. Even with a sworn proof of loss, there is a way to disclaim the finality of damages and amounts included by couching information as estimates or by affirming that the final and complete loss is still unknown while you work with an adjuster to quantify the loss. The point is, ignoring the obligation altogether will result in a headache that you will have to deal with down the road because the property insurer will use it against you and is a headache that is easily avoidable. And, it will result in an added burden to you, as the insured, to demonstrate the failure to comply did not actually cause any prejudice to the insurer. By way of example, in Prem v. Universal Property & Casualty Ins. Co., 45 Fla. L. Weekly D2044a (Fla. 3d DCA 2020), the insured notified their property insurer of a plumbing leak in the bathroom. The insurer requested for the insured to submit a sworn proof of loss per the terms of the insured’s property insurance policy. The insurer follow-up with its request for a sworn proof of loss on a few occasions. None was provided and the insured filed a lawsuit without ever furnishing a sworn proof of loss. The insurer moved for summary judgment due the insured’s failure to comply with the post-loss obligations, specifically by not submitting a sworn proof of loss, and the trial court granted the insurer’s motion. Even at the time of the summary judgment hearing, the insured still did not submit a sworn proof of loss. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Wake County Justice Center- a LEED Silver Project done right!

October 01, 2014 — Melissa Dewey Brumback – Construction Law in North Carolina
Yesterday evening, I had the privilege of attending the Triangle USGBC’s “Talk & Walk” at the Wake County Justice Center. The 576,996 square foot Justice Center was completed 6 months early and over 30 million under budget. (The final cost, including soft costs, came in at ~$141,000,000). Now that’s what I call a LEED project done right! Interestingly, the County did not endeavor for a LEED Silver rating– the plan was to aim for a Certification. However, as the process unfolded, the Team kept meeting the goals and points for a Silver certification without any appreciable additional costs. The end result? An “iconic but energy efficient building,” according to Tim Ashby, current Wake County Facilities Project Manager. Tim was initially involved in the Project while working at O’Brien Atkins, which served as the architecture firm for the Project under the direction of Architect Andrew Zwiacher. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Construction Law in North Carolina
Ms. Brumback may be contacted at mbrumback@rl-law.com

Hennigh Law Corporation Wins Award Against Viracon, Inc In Defective Gray PIB Case

July 11, 2022 — Scott Hennigh - Hennigh Law Corporation
LOS ANGELES, July 08, 2022 (GLOBE NEWSWIRE) -- Hennigh Law Corporation has announced that, after an over four-year battle in and out of court, a three arbitrator panel issued a 93-page interim award in finding Viracon, Inc., liable for $13,682,840 in direct damages for defrauding the owner of the premier office building in Burbank, California, The Pointe. The matter now enters the second phase, where the arbitration panel will rule on the amount of punitive damages to assess, as well as attorney fees and interest. Scott Hennigh, trial attorney, states, "The California construction industry is very robust with high standards. The arbitration panel appears to have recognized that California law does not tolerate large out-of-state companies misleading customers. They appear poised to send a message to Viracon about its lack of corporate responsibility." The premier Class-A office building in Burbank, California, The Pointe, serves high-end tenants in entertainment industries such as Warner Brothers. Constructed in 2009, the 13 exterior curtain wall of the 13-story building is encased in seamless glass panels. Read the court decision
Read the full story...
Reprinted courtesy of Scott Hennigh, Hennigh Law Corporation
Mr. Hennigh may be contacted at Scott.hennigh@hennighlaw.com

Perrin Construction Defect Claims & Trial Conference

June 11, 2018 — Beverley BevenFlorez-CDJ STAFF
Richard Glucksman, Esquire, Partner of the Los Angeles firm Chapman Glucksman Dean Roeb & Barger, will be moderating the panel, “Green Building/LEED: An Overview and Claims Discussion” at the Perrin Construction Defect Claims & Trial Conference in Las Vegas, Nevada. The panel will be discussing the following topics:

Risk and claims case studies including solar and SIPs (Structural Insulated Panels)
Green Building/LEED and The Law: Review of National Claims/Lawsuits
AIA Documents for Sustainable Projects

Thursday, June 21st, 2018 Four Seasons Hotel 3960 S Las Vegas Blvd Las Vegas, NV 89119 Read the court decision
Read the full story...
Reprinted courtesy of

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Union Handbilling: When, Where, and Why it is Legal

November 06, 2018 — Wally Zimolong - Supplemental Conditions
A few days ago, IBEW Local 98 began began protesting a restaurant owned by professional football player Jahri Evans. The organizers are accusing Evans of violating local construction wage standards and are advertising their dispute with “handbills.” What are handbills? Walking down Fremont Street in Las Vegas is impossible without one or several characters putting a small business card with “questionable” adult entertainment advertisements in your hand. Some will slap papers to your chest, leaving you no choice but to grab the flyers. On a different level, this action occurs on a regular basis by union member. But instead of shady characters pushing questionable entertainment, it is union representatives pushing a dispute with a local employer over working conditions. However, in either case the practice is known as i as handbilling. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Construction Litigation Roundup: “Just Hanging Around”

August 14, 2023 — Daniel Lund III - Lexology
A subcontractor asserting a payment bond claim for “standby” time for its equipment on the Cline Avenue bridge project (over Indiana Harbor and Ship Canal in East Chicago, Indiana) received pushback from the payment bond surety. In fact, the duration of the standby time occurred after the surety’s principal, the general contractor, had been placed in default and terminated on the general contract. According to the surety: “After termination of the contract… it is impossible for labor, materials, and equipment to have been furnished for use in performing the terminated contract.” The surety filed a motion for summary judgment. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES