COLUMBUS OHIO BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Hilti Partners with Canvas, a Construction Robotics Company

April 03, 2023 — Aarni Heiskanen - AEC Business
Hilti announced a strategic partnership with Canvas, a construction robotics company that has developed a robotic drywalling solution. The partnership allows Canvas to scale globally. Hilti launched its Jaibot, the world’s first semi-autonomous ceiling-drilling robot, in 2020. As part of the partnership, Hilti will assume the manufacturing responsibilities for future Canvas systems. They will be based on the Jaibot platform, giving Canvas a reliable and scalable global supply to meet the huge demand for its finishing robots. The partnering companies share a common vision: that robotic tools will unlock vastly untapped potential and drive a new era of productivity and safety for skilled trade workers. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

Ninth Circuit Finds No Coverage for Construction Defects Under California Law

April 05, 2017 — Tred R. Eyerly – Insurance Law Hawaii
The Ninth Circuit, applying California law, affirmed the district court's decision finding there was no coverage for construction defects. Archer W. Contractors v. Nat'l Union Fire Ins. Co., 2017 U.S. App. LEXIS 3796 (9th Cir. March 2, 2017). Archer Western Contractors (AWC) was the general contractor for the San Diego County Water Authority's emergency water storage project. The pump house and turbine generators suffered property damage. The damage flowed from AWC's allegedly defective work on the property. After settling a construction defect lawsuit brought against it by the Water Authority, AWC filed this case against National Union for failing to indemnity portions of the settlement agreement. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Why Federal and State Agencies are Considering Converting from a “Gallons Consumed” to a “Road Usage” Tax – And What are the Risks to the Consumer?

August 26, 2015 — Roger Hughes – California Construction Law Blog
“‘We’re going to have to find another way to finance the upkeep of the roads,’ Gov. Jerry Brown said earlier this year in rolling out his 2015 budget. Governor Brown gave no specifics, but last fall he signed a law that set up a commission to study a ‘road usage charge’ with a call to ‘establish a pilot program by Jan. 1, 2017…'” – San Jose Mercury News, January 27, 2015 This Change, It’s a Coming (Maybe) Many states and the federal government are seriously considering converting from a “gallons consumed” tax levy to a “miles driven” program for determining gasoline tax. There are several compelling reasons for such a change. First, our roads are falling apart while revenue from current highway taxes fall woefully short of our current and projected needs. In the meantime, the number of miles driven by all-electric cars that pay no gas tax, is increasing rapidly; and by hybrids that pay substantially reduced tax; and worse for the taxing authorities, by increasingly efficient gas-powered cars. All of this means rapidly dropping gas tax revenues. Seeing this trend, local, state and the federal governments are making a major push to convert from a consumption based tax to a “miles driven” tax. This a good thing for those of us that believe increased investment in our transportation infrastructure is of high national concern. Read the court decision
Read the full story...
Reprinted courtesy of Roger Hughes, Wendel Rosen Black & Dean LLP
Mr. Hughes may be contacted at rhughes@wendel.com

---

Real-Estate Pros Fight NYC Tax on Wealthy Absentee Owners

October 15, 2014 — Henry Goldman and Allyson Versprille – Bloomberg
A political battle is brewing at the apex of New York’s property market. The real-estate industry is mobilizing to kill a proposed levy on non-resident owners of apartments valued at more than $5 million, seeking to ensure the world’s biggest city doesn’t follow London, Hong Kong and Singapore in extracting extra cash from trophy properties. The industry’s lobbying arm, the Real Estate Board of New York, says the measure will scare off investors who fuel a business supporting more than 500,000 jobs and generating 40 percent of the five boroughs’ revenue. Brokers warn of economic calamity if officials slap a luxury tax on apartments owned by someone who lives in the city less than half the year. Mr. Goldman may be contacted at hgoldman@bloomberg.net; Ms. Versprille may be contacted at aversprille1@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Henry Goldman and Allyson Versprille, Bloomberg

---

Power of Workers Compensation Immunity on Construction Project

November 30, 2017 — David Adelstein - Florida Construction Legal Updates
On construction projects, workers compensation immunity is real and it is powerful. (See also this article.) Workers compensation immunity is why all general contractors should have workers compensation insurance and they should ensure the subcontractors they hire have workers compensation insurance. Workers compensation insurance becomes the exclusive form of liability for an injured worker thereby immunizing an employer (absent an intentional tort, which is very hard to prove as a means to circumvent workers compensation immunity). If a general contractor, with workers compensation insurance, hires a subcontractor without workers compensation insurance, the general contractor’s workers compensation insurance will be responsible in the event an injury occurs to a subcontractor’s employee. The general contractor becomes the statutory employer. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---

New Jersey Judge Declared Arbitrator had no Duty to Disclose Past Contact with Lawyer

October 22, 2014 — Beverley BevenFlorez-CDJ STAFF
According to the New Jersey Law Journal, in a recent ruling, a federal judge in Newark “ruled that an arbitration award should not be vacated based on the arbitrator’s failure to disclose his professional contacts with defense counsel during his prior career as a federal judge.” The plaintiff had sought to vacate an award “because he failed to disclose interactions he had with Dennis Drasco, the lawyer for the defendant, while serving on the bench. But Brown was not required to disclose his contacts with Drasco because they would not cause a reasonable person to question Brown’s impartiality, U.S. District Judge William Walls ruled Oct. 21,” reported the New Jersey Law Journal. The plaintiff’s assertions “suggest nothing more than that Judge Brown and Mr. Drasco were familiar with one another in their professional capacities,” Walls stated, as quoted by the New Jersey Law Journal. Read the court decision
Read the full story...
Reprinted courtesy of

---

Extreme Flooding Overwhelms New York Roadways, Killing 1 Person

July 24, 2023 — Associated Press - Bloomberg
NEW YORK (AP) — Heavy rain spawned extreme flooding in New York’s Hudson Valley that killed at least one person, swamped roadways and forced road closures on Sunday night, as much of the rest of the Northeast U.S. braced Monday for potentially punishing rains. As the storm moved east, the National Weather Service extended flash flood warnings into Connecticut, including the cities of Stamford and Greenwich, before creeping into Massachusetts. Forecasters said some areas could get as much as 5 inches (12 centimeters) of rain. In New York's Hudson Valley, rescue teams found the body of a woman in her 30s who drowned after being swept away while trying to evacuate her home, Orange County Executive Steven Neuhaus told WABC-TV. Officials were waiting for the medical examiner's office to arrive, he said. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

---