Environmental Law Violations: When you Should Hire a Lawyer
October 09, 2018 —
Bremer Whyte Brown & O’MearaEnvironmental law violations can have an enormous impact on your ongoing profitability. Environmental law is complicated and multifaceted, with laws at the local, state, and federal level often overlapping. In this article, we’ll discuss environmental law violations in the context of defending against an environmental law claim. In doing so, we’ll take a brief look at what environmental law is, and explore some environmental law violations cases. This should shed some light on the complex nature of environmental law litigation, and highlight the importance of securing legal representation with the scope and breadth of practice to wade into an environmental law violation case.
What is Environmental Law?
Before diving into specific environmental law violation cases, it is helpful to first provide a basic outline of what environmental law is and what different levels of environmental law exist in the United States. The most well-known environmental law exists at the federal level and is enforced by the Environmental Protection Agency (EPA). The EPA is responsible for enforcing directives that have been set forth by Congress over time. These include a variety of Acts, including the Clean Air Act and Clean Water Act.
Read the court decisionRead the full story...Reprinted courtesy of
Bremer Whyte Brown & O’Meara
New ANSI Requirements for Fireplace Screens
March 19, 2015 —
Beverley BevenFlorez-CDJ STAFFThe American National Standards Institute (ANSI) now requires “vented gas fireplaces to include a safety barrier screen as standard equipment,” according to Remodeling.
"While gas fireplaces, stoves and inserts are a great asset to any home, the glass can become very hot during operation and stay hot long afterwards, creating a potential burn hazard," Jack Goldman, HPBA president and CEO told Remodeling.
Read the court decisionRead the full story...Reprinted courtesy of
Florida Federal Court to Examine Issues of Alleged Arbitrator Conflicts of Interests in Panama Canal Case
May 24, 2021 —
Sarah B. Biser & Philip Z. Langer - ConsensusDocsThe parties in a $238-million dispute over the construction of the third set of locks for the Panama Canal are raising issues concerning alleged conflicts of interest on the part of the International Chamber of Commerce (“ICC”) arbitrators in the United States District Court for the Southern District of Florida.[2] The case may address rarely litigated issues concerning whether arbitrators who sit on multiple arbitration panels together or who support appointment of each other to lead arbitration panels have disabling conflicts of interest.
The case pits Grupo Unidos por el Canal, S.A. (“Grupo”), a consortium of Spanish, Italian, Belgian, and Panamanian construction firms, against Autoridad del Canal de Panama (“ACP”), the Panamanian entity that operates the Panama Canal and that sponsored the multi-billion-dollar, decade-long project to expand the Canal’s capacity by building a new set of locks (the “Project”). The current dispute (the “Panama 1 Arbitration”), which centers on the suitability of the rock coming from the excavations to be used to produce concrete aggregates for the Project, was arbitrated before a three-member ICC Tribunal and resulted in a $238-million award to ACP and against Grupo. The ICC Tribunal reversed a decision of the dispute review board established in the parties’ contract.
Reprinted courtesy of
Sarah B. Biser, Fox Rothschild LLP and
Philip Z. Langer, Fox Rothschild LLP
Ms. Biser may be contacted at sbiser@foxrothschild.com
Mr. Langer may be contacted at planger@foxrothschild.com
Read the court decisionRead the full story...Reprinted courtesy of
Brad Pitt’s Foundation Sues New Orleans Architect for Construction Defects
September 25, 2018 —
David Suggs – Bert L. Howe & Associates, Inc.Brad Pitt’s foundation has sued its architect of New Orleans projects alleging “defective design work led to leaks and other flaws in homes built for residents of an area that was among the hardest hit by Hurricane Katrina,” reported Insurance Journal.
The Make It Right Foundation claims damages of more than $15 million caused by architect John C. Williams. According to Insurance Journal, “The foundation paid Williams’ firm millions of dollars to produce architectural drawings for more than 100 homes under the program, which was supposed to provide Lower 9th Ward residents with sustainable and affordable new homes.”
This lawsuit against the architect is apparently in response to a class-action lawsuit by New Orleans attorney Ron Austin against Pitt’s Make It Right Foundation. Austin’s lawsuit “accused the charity of building substandard homes that are deteriorating at a rapid pace,” Insurance Journal reported.
The 39 homes involved in a previous suit regarding the manufacturer of TimberSIL are excluded from the lawsuit against Williams.
Read the court decisionRead the full story...Reprinted courtesy of
Renters Who Bought Cannot Sue for Construction Defects
October 08, 2013 —
CDJ STAFFA Wisconsin couple that leased then bought a home cannot sue the couple that built the home for construction defects. The court rejected the claims made by Niksa and Kelly Ivancevic that the sellers, Ronald and Debra Reagan, had breached contract or that the contract represented a mutual mistake.
The Ivancevics initially leased the home, with an agreement that said the house would be “delivered in clean condition and good repair, free of mold and toxic substances, suitable for habitation in compliance with all laws.” Before the purchase, no defects were found. After the purchase, the Ivancevics had problems with the air conditioning, leading to water leaks on the second floor.
The court found that the actual sales contract did not guarantee a defect-free residence. Therefore the Ivancevic’s claim of a mutual mistake, in which “both parties of a contact are unaware of the existence of a past or present fact material to their agreement” did not apply, since the presence of construction defects was not “material to their agreement.”
Read the court decisionRead the full story...Reprinted courtesy of
Behavioral Science Meets Construction: Insights from Whistle Rewards
September 09, 2024 —
Aarni Heiskanen - AEC BusinessIn
this episode of the AEC Business Podcast, Aarni Heiskanen hosts Drew Carter, CEO of Whistle Rewards, and Dr. Laurel Newman, a behavioral scientist, to discuss instant rewards for driving behavioral change in construction. Laurel shares her psychology background and academic career, studying how the environment influences behavior. Drew introduces himself as a data scientist, focusing on predictive modeling. Tune in to learn how they collaborate to create motivating environments in the construction industry.
Whistle Rewards is a platform specializing in rewards, recognition, and incentives in the AEC industry. It is designed to enhance employee engagement, safety compliance, performance, and technology adoption in construction companies.
The Guests
Drew Carter, CEO and Co-Founder at Whistle Systems, Inc.
Drew is improving employee retention using data science and behavioral science.
Read the court decisionRead the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
aec-business@aepartners.fi
Mutual Or Concurrent Delay Caused By Subcontractors
March 23, 2020 —
David Adelstein - Florida Construction Legal UpdatesHow are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project?
Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs.
There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project.
The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
William Doerler Recognized by JD Supra 2022 Readers’ Choice Awards
March 14, 2022 —
William Doerler - White and Williams LLPCongratulations to Bill Doerler, Counsel of the Subrogation Group who has been recognized as a
top author in Product Liability in the 2022 JD Supra Readers' Choice Awards. Bill was ranked number 9 out of a pool of approximately 800 authors writing about product liability matters on JD Supra in 2021.
The Readers’ Choice Awards recognize top authors and firms for their thought leadership in key topics read by C-suite executives, in-house counsel, media and other professionals across the JD Supra platform during 2021. These annual awards (now in their seventh year) recognize JD Supra contributors for the visibility and engagement their thought leadership earned among readers in select subjects during the previous 12 months.
Read the court decisionRead the full story...Reprinted courtesy of
William Doerler, White and Williams LLPMr. Doerler may be contacted at
doerlerw@whiteandwilliams.com