SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Fundamental Fairness Trumps Contract Language

September 24, 2014 — Craig Martin – Construction Contractor Advisor
The Texas Supreme Court recently ruled that a “no-damages-for-delay” clause would not be enforced where the delay was caused by the owner. The court’s ruling flies squarely in the face of the contract language that attempted to insulate the owner from any delay claims, even those it caused. In the case of Zachary Construction v. Port of Houston underlying contract, proposed by the Port of Houston, was heavy handed, to say the least. The contract provided: “[Contractor] shall receive no financial compensation for delay or hindrance to the Work. In no event shall the Port Authority be liable to [Contractor] … for any damages arising out of or associated with any delay or hindrance to the Work, regardless of the source of the delay or hindrance, including events of Force Majeure, AND EVEN IF SUCH DELAY OR HINDRANCE RESULTS FROM, ARISES OUT OF OR IS DUE IN WHOLE OR IN PART, TO THE NEGLIGENCE, BREACH OF CONTRACT OR OTHER FAULT OF THE PORT AUTHORITY. [Contractor’s] sole remedy in any such case shall be an extension of time.” Wow, that’s some one-sided language. If the contract was enforced, the contractor could not get any damages for delay, even those damages caused by the active interference of the Port of Houston. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---

Limiting Liability: Three Clauses to Consider in your Next Construction Contract

June 25, 2019 — Tara Lynch - Gordon & Rees Construction Law Blog
In your next contract, consider including some (or all!) of the following clauses to limit your liability and maximize your profits. Waiver of Consequential Damages While a proven breach of contract will leave a design professional or contractor exposed to direct or compensatory damages, a waiver of consequential damages will help “stop the bleeding” and protect the design professional or contractor from paying every damage that might flow from the breach. Consequential damages include those damages which indirectly flow from the breach of contract, for example, lost rents, lost profits, lost use, lost opportunity, loss of employee productivity, and damages to reputation. The American Institute of Architects (AIA) has included a mutual waiver of consequential damages in its sample A201 for over 20 years. The AIA provision includes a definition of consequential damages which are waived, including many of the examples cited above. However, the AIA waiver of consequential damages clause carves out an exception for liquidated damages to the owner. Prudent design professionals and contractors will strike this exception so as not to render the clause meaningless. A well-drafted waiver clause will be mutual, will define which damages are consequential versus direct, and will not contain exceptions. Read the court decision
Read the full story...
Reprinted courtesy of Tara Lynch - Gordon & Rees Scully Mansukhani
Ms. Lynch may be contacted at tlynch@grsm.com

---

Without Reservations: Fourth Circuit Affirms That Vague Reservation of Rights Waived Insurers’ Coverage Arguments

January 09, 2023 — Lara Degenhart Cassidy & Matthew J. Revis - Hunton Insurance Recovery Blog
The Fourth Circuit recently affirmed insurance coverage for a South Carolina policyholder based on the “axiomatic principle” that an insurer which fails to fully and fairly articulate its potential coverage defenses in a reservation of rights letter loses the right to contest coverage on those grounds. Stoneledge at Lake Keowee Owner’s Assoc. v. Cincinnati Ins. Co., No. 19-2009, 2022 WL 17592121 (4th Cir. 2022) (quoting Harleysville Group Insurance v. Heritage Communities, Inc., 803 S.E.2d 288 (S.C. 2017)). More particularly, in Stoneledge, the Fourth Circuit affirmed per curiam a South Carolina District Court’s grant of summary judgment in favor of a homeowners association that had successfully sued its general contractors for construction defects and was seeking to recover the damages owed from the contractors’ insurers. The Fourth Circuit agreed that the insurers’ vague reservation of rights letters failed to reserve the defenses on which the insurers purported to deny coverage. The question before the court in Stoneledge was whether the two insurers that had each agreed to defend their respective general-contractor insureds in the homeowner association’s underlying litigation had sufficiently informed their policyholders of their coverage positions. Specifically, the court considered whether the insurers provided notice of their intention to challenge coverage on specific bases and explained why those bases applied in their respective reservation of rights letters. Both of the insurers’ letters followed the typical approach of identifying various policy provisions and exclusions and outlining the general mechanics of those provisions, but they fell short of applying the provisions or exclusions to the facts in the case at hand. Further, the letters stated that the insurers would reevaluate how the provisions applied as the underlying case progressed. One of the insurer’s letters expressed doubt as to coverage but did not offer any analysis on the reasons for the prospective coverage denial. Reprinted courtesy of Lara Degenhart Cassidy, Hunton Andrews Kurth and Matthew J. Revis, Hunton Andrews Kurth Ms. Cassidy may be contacted at lcassidy@HuntonAK.com Mr. Revis may be contacted at mrevis@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Pulling the Plug

December 13, 2022 — Todd R. Regan - Construction Executive
As a contractor, you may have wondered if your contract can be terminated by the owner for cause after the project has reached substantial completion. The answer is yes. Under certain circumstances it may be permissible—or even necessary—for a project owner to terminate the contract for cause after the project has reached substantial completion. Although the rights of the parties in any case will depend in large part on the specific contract language, the fact that a project has reached substantial completion is not an absolute bar to termination for cause, particularly when the owner intends to pursue a performance-bond claim. Completion Versus Performance Following substantial completion, a contractor typically will have outstanding contractual obligations such as paying its subcontractors and suppliers, bonding off any mechanic’s liens, completing the punch list, remediating defective work, testing and commissioning equipment, providing manufacturer’s warranties and performing its own warranty obligations. Reprinted courtesy of Todd R. Regan, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

The Great Skyscraper Comeback Skips North America

February 05, 2015 — Patrick Clark – Bloomberg
Tall buildings are back. Developers around the globe completed a record 97 buildings of at least 200 meters (656 feet) in height in 2014, according to a new report from the Council on Tall Buildings and Urban Habitat, as size-obsessed builders got back on a growth track after a two-year skyscraper dip. It’s not hard to explain the pattern. A typical skyscraper takes two to four years to finish, says report co-author Daniel Safarik. Work back from the year of completion, and the global financial crisis looks like an easy explanation for the drop-off in tall buildings. If you thought it was hard to get a home loan in 2009, imagine asking bankers to finance a gravity-and-wind-defying symbol of luxury, industry, and capitalist will. Especially, as Bloomberg Businessweek’s Bryant Urstadt pointed out, since supertall buildings are notorious for being hard to fill with tenants. (It’s worth noting that “tall” isn’t a technical term, though “supertall,” which is used to describe buildings more than 300 meters tall, is. And construction schedules vary. The Ryugyong Hotel in Pyongyang, North Korea, planned for 330 meters, has been under construction for 28 years, according to a CTBUH report last year.) Read the court decision
Read the full story...
Reprinted courtesy of Patrick Clark, Bloomberg

---

Is Construction Heading Off the Fiscal Cliff?

December 20, 2012 — CDJ STAFF
After a period of growth, the construction industry lost 20,000 jobs in November, based on the federal jobs data. Damon Scott of New Mexico Business Weekly suggests that contractors may have laid off employees in anticipation of the “fiscal cliff.” Ken Simpson, the chief economist of the National Association of Home Builders said in a press release that “it is discouraging that construction employment is still struggling after three years of expansion in the overall economy.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Anti-Concurrent Causation Endorsements in CGL Insurance Policies: A Word of Caution

August 29, 2022 — David M. McLain – Colorado Construction Litigation
While I have not performed exhaustive research into the origin of anti-concurrent causation (“ACC”) endorsements on insurance policies, or how or when they migrated from first-party property policies to commercial general liability (“CGL”) policies, they have done so. The result for Colorado’s construction professionals may rear its ugly head as an unwelcome and surprise outright declination of coverage for construction defect claims. ACC endorsements state that if there are two causes of damage: one of which is covered by a policy and one of which is not, the carrier can invoke the ACC endorsement to disclaim coverage for all of the damage. An exemplar ACC endorsement is ISO Form CG 21 67, entitled “Fungi or Bacteria Exclusion.” Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell
Mr. McLain may be contacted at mclain@hhmrlaw.com

---

Building Resiliency: Withstanding Wildfires and Other Natural Disasters

September 25, 2023 — Bill Creedon - Construction Executive
According to the National Fire Protection Association, between 2016 and 2020 an estimated average of 4,300 fires per year plagued structures under construction, adding up to about $376 million in annual property damage. More recently, the National Centers for Environmental Information reported that wildfires accounted for more than $3.2 billion in damages across the United States. These figures alone point to the heightened awareness that all companies—particularly construction companies—should maintain surrounding the unique challenges and risks that wildfires can present and how they could potentially impact the integrity of projects and the associated safety of their workers. As North America grapples with the increasing frequency and severity of wildfires, hurricanes and additional severe weather events, numerous industries have had to adapt and implement proactive measures to minimize their risks and associated exposures. The impact of these natural disasters on the construction industry is indisputable, necessitating proactive measures that construction companies should seriously consider adopting to effectively mitigate those risks, efficiently navigate insurance complexities and seamlessly integrate data-driven solutions alongside modern tools like AI and predictive modeling. Reprinted courtesy of Bill Creedon, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Creedon may be contacted at bill.creedon@wtwco.com

---