MTA Debarment Update
December 02, 2019 —
Steven M. Charney, Gregory H. Chertoff & Paul Monte - Peckar & Abramson, P.C.Alliance for Fair and Equitable Contracting Today, Inc., a nonprofit formed by five trade associations, including the GCA, the BTEA and the NY Building Congress, has sued the Metropolitan Transportation Authority over rules that debar contractors for delays and cost overruns on MTA projects without regard to the reasons for the delays and cost overruns.
As described in our prior client alert (see
here), the current rules automatically debar firms that are determined to have gone over the MTA approved contract price or time by more than 10%. The rules do not consider mitigating circumstances. Delays and cost overruns are often caused by unforeseen conditions, design errors and omissions, and changes requested by the MTA. The MTA’s rules could lead contractors to absorb additional costs they shouldn’t be responsible for rather than face the risk of being debarred. As argued in Alliance’s action, “Debarment is the death penalty for a public works contractor, and not just in New York. A debarment by the MTA could result in debarment nationwide, given that public and private contractors throughout the country commonly inquire about bidders’ debarment history when considering project bids. The Debarment Statute and MTA Regulations thus effectively export an unreasonable law not only throughout New York State, but to all other states as well.”
Reprinted courtesy of Saxe Doernberger & Vita, P.C. attorneys
Steven M. Charney,
Gregory H. Chertoff and
Paul Monte
Mr. Charney may be contacted at scharney@pecklaw.com
Mr. Chertoff may be contacted at gchertoff@pecklaw.com
Mr. Monte may be contacted at pmonte@pecklaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Update Your California Release Provisions to Include Amended Section 1542 Language
April 02, 2019 —
Amy L. Pierce & William S. Hale, P.E. - Gravel2Gavel Construction & Real Estate BlogMost companies have been involved in a situation where they want to end their relationship with another company, or with an employee, and to permanently terminate their mutual obligations (e.g., a settlement agreement resolving end-of-project litigation). In 1992, a California Court of Appeals, in Winet v. Price, confirmed that upholding general releases is “in harmony… with a beneficial principle of contract law: that general releases can be so constructed as to be completely enforceable.”
In California, agreements with a release of claims (or s general release) include what is often referred to as a California Civil Code § 1542 waiver for the purpose of ensuring that the releasing party is consciously releasing both known and unknown claims that may be later discovered. Such a waiver provision generally confirms that the Releasing Party acknowledges that it understands and waives the provisions of Section 1542, followed by the quoted text of Section 1542 (typically in all capital letters).
Reprinted courtesy of
Amy L. Pierce, Pillsbury and
William S. Hale, Pillsbury
Ms. Pierce may be contacted at amy.pierce@pillsburylaw.com
Mr. Hale may be contacted at william.hale@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Construction Companies Must Prepare for a Surge of Third-Party Contractors
February 08, 2021 —
Kim Holly - Construction ExecutiveEconomists agree that the trajectory of the current recession has been different from any other. Looking back at the 2008 economic crisis, there are noticeable trends in the construction space that indicate a surge in third-party contractor hiring could be coming in 2021.
The demand for more contract work will come as no surprise for seasoned construction executives—the share of contractors at U.S. businesses has increased by 15% in the last decade. Contractors are a valuable asset in the construction industry, but organizations will need to prepare for the coming influx to ensure third-party contractors and full-time employees are set up for success to keep operations running smoothly.
THE CONTRACTOR SURGE BLUEPRINT
Managing a substantial influx of contractors on construction worksites can be an overwhelming task. However, with guiding principles in place, construction executives can successfully incorporate more contractors into their operations and effectively manage associated risks.
Reprinted courtesy of
Kim Holly, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Managing Partner Jeff Dennis Recognized as One of the Most Influential Business People & Opinion Shapers in Orange County
November 17, 2016 —
Newmeyer & Dillion LLPNEWPORT BEACH, Calif. – Nov 15th, 2016 – Prominent business and real estate law firm Newmeyer & Dillion LLP is pleased to announce that managing partner Jeff Dennis was selected as one of the 500 most influential business people and opinion shapers in Orange County by the Orange County Business Journal (OCBJ). Dennis will be recognized in OCBJ’s inaugural issue, OC500, publishing November 14, 2016.
Located in the Newport Beach office, Dennis currently serves as the Firm’s Managing Partner and specializes in a variety of litigation arenas, including construction, real estate and business litigation. He also handles insurance and higher education matters. Tom Newmeyer, Newmeyer & Dillion’s Co-founding Partner, believes the award is representative of the leadership displayed by Dennis. “Jeff is an uncanny consensus builder, and you can see his steady hand in the firms’ growth and success. This recognition is a testament to his strong commitment to the community and his ability to facilitate innovative changes in Orange County.”
Dennis believes that community participation is a vital part of his law practice. He currently serves on the Executive Leadership Team for the American Heart Association’s Orange County Heart Walk. Under Dennis’ leadership, the firm proudly supports the OC Heart Walk, with over 150 participants joining Team N&D in 2016. As such, he volunteered to serve in the Orange County District Attorney’s selective Trial Advocacy Partnership (TAP) program. He is the past president of the Occidental College Board of Governors and helped lead Occidental’s Alumni Association as its former Orange County Regional Chair.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Spearin Doctrine: Alive, Well and Thriving on its 100th Birthday
January 15, 2019 —
John P. Ahlers - Ahlers Cressman & Sleight PLLCOn December 9, 2018, United States v. Spearin, [1] a landmark construction law case, will be 100 years old. The Spearin “doctrine”[2] provides that the owner impliedly warrants the information, plans and specifications which an owner provides to a general contractor. The contractor will not be liable to the owner for loss or damage which results from insufficiencies or defects in such information, plans and specifications.
Some construction lawyers questioned whether the Spearin doctrine was still viable in Washington after the Washington Court of Appeals decided the recent case of King County v. Vinci Constr. Grand Projets.[3] Some concerned contractor industry groups even considered a “statutory fix” in the wake of the Court of Appeals Vinci decision. It is our opinion that the facts in the Vinci case are distinguishable and the Spearin doctrine is alive and thriving in Washington.
Read the court decisionRead the full story...Reprinted courtesy of
John P. Ahlers, Ahlers Cressman & Sleight PLLCMr. Ahlers may be contacted at
john.ahlers@acslawyers.com
The International Codes Development Process is Changing to Continue Building Code Modernization
March 06, 2023 —
The International Code CouncilWashington D.C., March 02, 2023 (GLOBE NEWSWIRE) -- The International Code Council is revising its rigorous code development process. The changes will take effect in 2024-2026 for the development of the 2027 International Codes (I-Codes) and will move the development process to an integrated and continuous three-year cycle.
In the new timeline, year one will include two Committee Action Hearings for Group A Codes; year two will include two Committee Action Hearings for Group B Codes; and year three will be the joint Public Comment Hearings and Online Governmental Consensus Vote for both Group A and B Codes.
The addition of the second Committee Actions Hearings in year one and two will foster a more in-depth vetting of code change proposals, allowing an opportunity for the committee members to review and evaluate the original proposals and consider the submitted responses. This also provides more opportunity for proponents to build consensus for their code change proposal and ensure the best version of their intended improvement to the existing codes.
Additionally, with combined Public Comment Hearings in the third year, voting members are able to vote on all suggested changes to the next edition of the I-Codes at one time. The updated process also provides more opportunity for proposed new referenced standards to be developed and finalized on a consistent timeline regardless of the group (Group A or B) with which they are associated.
About the International Code Council
The International Code Council is the leading global source of model codes and standards and building safety solutions. Code Council codes, standards and solutions are used to ensure safe, affordable and sustainable communities and buildings worldwide.
Read the court decisionRead the full story...Reprinted courtesy of
Insurer Could Not Rely on Extrinsic Evidence to Circumvent Its Duty to Defend
February 14, 2023 —
Lorelie S. Masters & Yaniel Abreu - Hunton Insurance Recovery BlogIn
First Mercury Insurance Co. v. First Florida Building Corp., et al., a federal district court ordered that an insurer had a duty to defend its insured against an underlying personal injury lawsuit. 2023 WL 23116, at *1 (M.D. Fla. Jan. 3, 2023). First Mercury is a cautionary tale about how insurers may try to circumvent their obligations by improperly considering extrinsic evidence when determining whether they have a duty to defend their insureds.
First Mercury is a coverage dispute over an underlying personal injury lawsuit that was filed against the insured, a construction company, for injuries the claimant allegedly sustained at a construction site. Id. The claimant alleged that he was at the construction site as an invitee who was “working with” the insured. Id. The insurer agreed to defend the insured against the personal injury lawsuit under a reservation of rights. Id. However, the insurer filed a coverage action seeking a declaration that coverage for the personal injury lawsuit was excluded under the policy. Id. Specifically, the insurer, on summary judgment, argued that the claimant was an employee of the insured who was injured in the course of his employment, thus falling within the employer’s liability and workers’ compensation exclusions in the policy. Id. Although the insurer acknowledged that the personal injury complaint against the insured triggered its duty to defend under the policy, the insurer argued that those exclusions relieved its duty to defend or indemnify the insured. Id.
Reprinted courtesy of
Lorelie S. Masters, Hunton Andrews Kurth and
Yaniel Abreu, Hunton Andrews Kurth
Ms. Masters may be contacted at lmasters@HuntonAK.com
Mr. Abreu may be contacted at yabreu@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Inside the Old Psych Hospital Reborn As a Home for Money Managers
October 28, 2015 —
Simone Foxman – BloombergIt’s the most exclusive club for financiers in Dallas.
With seven Jeffersonian-style buildings and manicured lawns, Old Parkland looks more like a college campus than a hive of private-equity firms, hedge funds, foundations and family offices. But the 9.5-acre site, where an abandoned hospital once stood, is now home to some of the city’s wealthiest investors.
Old Parkland is the pet project of Harlan Crow, 66, a son of swashbuckling real estate developer Trammell Crow, whose empire was in tatters when he gave up control in the late 1980s. It’s also a symbol of a decades-long effort to rebuild the family’s legacy. Step inside any of the buildings and you might think you’re in a museum, with Rodin sculptures in the hallways, a 17th century antique sofa in a lobby and a piece of curtain Abraham Lincoln is said to have grabbed after being shot on display.
Read the court decisionRead the full story...Reprinted courtesy of
Simone Foxman, Bloomberg