Seattle Washington Building Expert Directory

MTA Debarment Update

December 02, 2019 — Steven M. Charney, Gregory H. Chertoff & Paul Monte - Peckar & Abramson, P.C.
Alliance for Fair and Equitable Contracting Today, Inc., a nonprofit formed by five trade associations, including the GCA, the BTEA and the NY Building Congress, has sued the Metropolitan Transportation Authority over rules that debar contractors for delays and cost overruns on MTA projects without regard to the reasons for the delays and cost overruns. As described in our prior client alert (see here), the current rules automatically debar firms that are determined to have gone over the MTA approved contract price or time by more than 10%. The rules do not consider mitigating circumstances. Delays and cost overruns are often caused by unforeseen conditions, design errors and omissions, and changes requested by the MTA. The MTA’s rules could lead contractors to absorb additional costs they shouldn’t be responsible for rather than face the risk of being debarred. As argued in Alliance’s action, “Debarment is the death penalty for a public works contractor, and not just in New York. A debarment by the MTA could result in debarment nationwide, given that public and private contractors throughout the country commonly inquire about bidders’ debarment history when considering project bids. The Debarment Statute and MTA Regulations thus effectively export an unreasonable law not only throughout New York State, but to all other states as well.” Reprinted courtesy of Saxe Doernberger & Vita, P.C. attorneys Steven M. Charney, Gregory H. Chertoff and Paul Monte Mr. Charney may be contacted at scharney@pecklaw.com Mr. Chertoff may be contacted at gchertoff@pecklaw.com Mr. Monte may be contacted at pmonte@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Public-Private Partnerships: When Will Reality Meet the Promise?

October 09, 2018 — Richard Fechner, GHD - Engineering News-Record
The promise of public-private partnerships (P3s) seems irresistible. The $4.5-trillion that the American Society of Civil Engineers says the U.S. must spend on at-risk infrastructure by 2025 is a backlog beyond the collective means of local, state and federal governments to fund and deliver. Read the court decision
Read the full story...
Reprinted courtesy of Richard Fechner, GHD, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Carin Ramirez and David McLain recognized among the Best Lawyers in America© for 2021

March 15, 2021 — Colorado Construction Litigation Blog
Higgins, Hopkins, McLain & Roswell is pleased to announce that Carin Ramirez and David McLain were recently selected by their peers for inclusion in The Best Lawyers in America© for 2021. Carin Ramirez has been recognized for her work in insurance litigation and David McLain has been recognized for his work in construction law. Carin Ramirez has over 11 years of experience in civil defense litigation with an emphasis on the defense of construction defect lawsuits on behalf of developers, general contractors, and other construction professionals. She also practices in the areas of personal injury defense, premises liability, environmental torts, wrongful death, negligent design, property damage, subrogation claims, contract disputes, bad faith, and commercial litigation. David McLain has over 22 years of experience and is well known for his work in the defense of the construction industry, particularly in the area of construction defect litigation. He is a member of the Executive Committee of the CLM Claims College - School of Construction, which is the premier course for insurance, industry, and legal professionals. HHMR is highly regarded for its expertise in construction law and the litigation of construction-related claims, including the defense of large and complex construction defect matters. Our attorneys provide exceptional service to individuals, business owners, Fortune 500 companies, and the insurance industry. The firm is experienced in providing legal support throughout trials and alternative dispute resolution such as mediations and arbitrations. Read the court decision
Read the full story...
Reprinted courtesy of Higgins, Hopkins, McLain & Roswell

Wisconsin Court of Appeals Re-affirms American Girl To Find Coverage for Damage Caused by Subcontractors

September 20, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The trial court's finding of no occurrence and no property damage due to faulty workmanship was reversed by the appellate court. No. 5 Walworth v. Engerman Contracting, Inc., 2021 Wis. App. LEXIS 401 (Wis. Ct. App, July 30, 2021). Engerman was the general contractor on a construction project at a residence. Engerman was hired to build a poll complex. Engerman subcontracted the project to Downes Swimming Pool Co., Inc. Downes purchased shotcrete (sprayed concrete) from Otto Jacobs Company LLC for the swimming poll walls and base. After completion, the pool immediately began leaking. An investigation determined that the shotcrete material was not installed correctly, contributing to cracking in the pool walls and the steel reinforcing bars were not sufficient to prevent cracks in the pool walls. The owner demolished the pool and constructed a new one. Thereafter, the owner sued Engerman, its insurers (General Casualty Company of Wisconsin and West Bend Mutual Insurance Company) and Downes and its insurer. Downes filed a third-party complaint against Jacobs and its insurer (Acuity Mutual Insurance Company) alleging Jacobs negligently provided inferior shotcrete to Downes. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

City in Ohio Sues Over Alleged Roof Defects

October 29, 2014 — Beverley BevenFlorez-CDJ STAFF
The city of Worthington “is suing the architect and general contractor responsible for constructing the addition to the Worthington Community Center in 2002,” according to ThisWeek Community News. The city is demanding $1.3 million “to replace the roof on the fitness center and pool addition, which is 12 years old.” Moody-Nolan, the architect, and Apex/M&P, the general contractor, have been named as defendants in the case. According to the complaint (as reported by ThisWeek), “experts retained by the city found that the roof has failed ‘due to unknown latent design defects and construction defects that have resulted in property damage.” Read the court decision
Read the full story...
Reprinted courtesy of

Insurer's Motion for Summary Judgment to Dispose of Hail Damage Claim Fails

November 25, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The court denied the insurer's motion for summary judgment seeking to dismiss the insured's complaint requesting coverage for hail damage and a claim for bad faith. Rodriquez v. State Farm Lloyds, 2024 U.S. Dist. LEXIS 160007 (W.D. Tex. Sept. 5, 2024). Mr. Rodriquez sought coverage under his homeowners policy after a hail and wind storm damaged his roof. After inspection, State Farm agreed that some minimal loss caused by hail was covered, but determined that the covered loss was less than the amount of the deductible. State Farm further determined that any hail damage to the roof was excluded by an endorsement, Exclusion of Cosmetic Loss to Metal Roof Coverings Caused by Hail. State Farm also determined that some damage was caused by previous faulty workmanship or wear and tear, both of which were excluded from coverage. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Beware of Statutory Limits on Change Orders

February 18, 2015 — Craig Martin – Construction Contractor Advisor
While change orders are always part of construction projects, it’s important to know whether a public agency is limited on how much it can increase the scope of the work through change orders. A contractor in Virginia found out the hard way that the state agency did not have the authority to increase the scope of the project and thus the contractor could not collect for the extra work. In Carnell Construction Corp. v. Danville Redevelopment & Housing Authority, the contractor was hired by the housing authority to prepare a site for construction. The project did not go well and both sides blamed the other for delays and increased costs. After being removed from the project, the contractor sued the housing authority for, among other things, breach of contract. The jury awarded the contractor a total of $915,000 for the housing authority’s failure to pay for extra work and improper removal. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Sewage Treatment Agency Sues Insurer and Contractor after Wall Failure and Sewage Leak

January 22, 2013 — CDJ STAFF
Trial preparations continue over the failure of a wall at a sewage treatment plant and the failure of the insurer to provide coverage. The Binghamton-Johnson City Joint Sewage Treatment Plant sued its insurer, American Alternative Insurance Corp., in March 2012 over insurance coverage. AAIC claimed that the wall failure, which released hundreds of thousands of gallons of sewage, was due to structural defects which preceded the policy. AAIC did pay more than $300,000 for covered losses, although officials claim that coverage should be a further $3.5 million. Additionally, the board is suing the contractor who constructed the wall. Here, the operators of the sewage plant are seeking $20 million. The wall was built as part of a $67 million improvement project between 2004 and 2006. Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES