Fairfield Connecticut Building Expert Directory

Chapman Glucksman Press Release

October 17, 2022 — Chapman Glucksman
Chapman Glucksman Dean & Roeb, a Los Angeles based law firm, has unveiled a dynamic new brand. The firm will now be known as “Chapman Glucksman.” The name change reflects the forward thinking and creative approach that the firm brings to its client service. “Chapman Glucksman has always been a firm of innovative thinkers with a keen focus on obtaining very favorable results for our clients. Our new brand captures the firm’s energy and focus,” said Craig Roeb, a shareholder who has spent his entire legal career with the firm. “We are excited about the growth of Chapman Glucksman, with the recent addition of new shareholder, Greg Sabo, partners, Chelsea Zwart and David Weinberger, as well as six new associate attorneys. The continued growth of Chapman Glucksman is a reflection of our strong client loyalty and growth,” said Randall Dean, shareholder and head of the Professional Liability Practice Group. Founded in 1985, Chapman Glucksman is a multi-faceted law firm with offices in Los Angeles, Orange County, Bay Area and Palm Springs. Our AV rated firm has diverse practice groups consisting of highly skilled, experienced, insightful, responsive, pragmatic and creative lawyers who vigorously advocate our client’s interests, and secure result-oriented, favorable and creative solutions to complex issues. Our achievements derive directly from our commitment to providing our clients with an unparalleled level of attention, exceptional work product and a strong work ethic with outstanding results achieved. Read the court decision
Read the full story...
Reprinted courtesy of Chapman Glucksman

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Matthew Graham Named to Best Lawyers in America

September 10, 2018 — Garret Murai - California Construction Law Blog
Wendel Rosen’s very own Matt Graham has been selected for inclusion in The Best Lawyers in America© 2019 in the area of Construction Law. First published in 1983, Best Lawyers is the oldest and most respected peer-review publication in the legal profession. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel, Rosen, Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

No Entitlement to Reimbursement of Pre-Tender Fees

April 28, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Federal District Court for the District of Hawaii determined that the insured was not entitled to pre-tender defense fees. The Hanover Ins. Co. v. Anova Food, LLC, 2016 U.S. Dist. LEXIS 38947 (D. Haw. March 24, 2016). Anova sold and marketed fish. It was insured under policies issued by Hanover that covered claims of "personal and advertising injury." A patent infringement and false advertising case was filed against Anova in the District Court for the District of Hawaii.The underlying complaint alleged Anova falsely, misleadingly, and deceptively advertised, promoted, and sold fish. The allegations covered a period of time between 1999 and 2012, a portion of which time Anova was covered by the Hanover policies. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Golden Gate Bridge's $76 Million Suicide Nets Near Approval

June 30, 2014 — Alison Vekshin – Bloomberg
Officials of the agency that runs San Francisco’s Golden Gate Bridge today approved a $76 million funding plan to erect a suicide barrier along the span, where people plunge to their deaths at a rate of about once a week. The Golden Gate Bridge Highway and Transportation District’s 19-member board voted unanimously to approve the funding, which includes $20 million from district reserves. “We must fight mental illness on many fronts and this budget action is a critical component of saving the lives of people who might not see that their brightest days are ahead of them,” Senator Mark Leno, a Democrat from San Francisco, said in a news release yesterday ahead of the meeting. Read the court decision
Read the full story...
Reprinted courtesy of Alison Vekshin, Bloomberg
Ms. Vekshin may be contacted at avekshin@bloomberg.net

Repairs Could Destroy Evidence in Construction Defect Suit

June 28, 2013 — CDJ STAFF
Repair work is underway on the Palladium concert hall in Carmel, Indiana, a suburb of Indianapolis, a contractor for the project says that the repairs will destroy evidence that they need to defect against additional construction defect allegations. Work stopped in 2009 for three months of repairs after problems were found in the steel roof supports. Steel Supply & Engineering Co. has claimed that the column failures are due to errors in the design. They say that if the repair work continues, it “would result in the spoliation of evidence, and will irreparably harm the defendants, and ultimately adversely affect their ability to protect their rights in the action.” They have asked the court to bring repairs to a stop until they are able to inspect the steel. Read the court decision
Read the full story...
Reprinted courtesy of

Forget Palm Springs—Santa Fe Is the New Mecca for Modern Architecture

November 19, 2021 — James Tarmy - Bloomberg
The writer Helen Thompson had been a lifelong visitor to Santa Fe, but when she arrived at Georgia O’Keeffe’s home at Ghost Ranch 30 years ago, “I was shocked,” Thompson says. “Everything there was modern: Her furniture was modern; her light fixtures were modern; her art, of course, was modern. And in this rustic setting, the landscape is so powerful, it was all so elemental. That shock stayed with me.” It was an experience, Thompson says, that led her to the conclusion that Santa Fe, long understood as a city filled with vernacular, decorative architecture, was ripe for a rethinking. “I kept wondering, why does something like that look so right here?” she says. “The landscape is so distinctive, and so not-modern, and yet these very precise pieces of furniture looked so right.” Now, with her new book Santa Fe Modern: Contemporary Design in the High Desert (Monacelli, $50), Thompson has cracked the code. “Modern ideas are site-specific, and tied into what’s right for the landscape and the environment,” she says. Naturally, she continues, this conceptual framework works well in a place like New Mexico, where the dramatic horizon meets an even more dramatic sky. Read the court decision
Read the full story...
Reprinted courtesy of James Tarmy, Bloomberg

Properly Trigger the Performance Bond

January 04, 2018 — David Adelstein - Florida Construction Legal Updates
Originally Published by CDJ on January 5, 2017 A performance bond is a valuable tool designed to guarantee the performance of the principal of the contract made part of the bond. But, it is only a valuable tool if the obligee (entity the bond is designed to benefit) understands that it needs to properly trigger the performance bond if it is looking to the bond (surety) to remedy and pay for a contractual default. If the performance bond is not properly triggered and a suit is brought upon the bond then the obligee could be the one materially breaching the terms of the bond. This means the obligee has no recourse under the performance bond. This is a huge downside when the obligee wanted the security of the performance bond, and reimbursed the bond principal for the premium of the bond, in order to address and remediate a default under the underlying contract. A recent example of this downside can be found in the Southern District of Florida’s decision in Arch Ins. Co. v. John Moriarty & Associates of Florida, Inc., 2016 WL 7324144 (S.D.Fla. 2016). Here, a general contractor sued a subcontractor’s performance bond surety for an approximate $1M cost overrun associated with the performance of the subcontractor’s subcontract (the contract made part of the subcontractor’s performance bond). The surety moved for summary judgment arguing that the general contractor failed to property trigger the performance bond and, therefore, materially breached the bond. The trial court granted the summary judgment in favor of the performance bond surety. Why? Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES