Fairfield Connecticut Building Expert Directory

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Are We Headed for a Work Shortage?

June 17, 2015 — Craig Martin – Construction Contractor Advisor
A recent Wall Street Journal article, Worker Shortage Hammers Builders, noted that construction industry employers are facing a tight labor market. “U.S. builders shed more than 2 million jobs during and after the housing bust. Now they say they can’t find enough carpenters, electricians, plumbers and other craftsmen for a growing pipeline of work.” That is certainly consistent with everything that I’ve heard and read about construction companies in the Midwest. Unfortunately, it seems as though the problem is only going to get worse. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

In Colorado, Primary Insurers are Necessary Parties in Declaratory Judgment Actions

December 09, 2011 — Heather M. Anderson, Colorado Construction Litigation

The United States District Court for the District of Colorado recently ruled that primary insurers are necessary parties, under Fed. R. Civ. P. 19, in a declaratory judgment action being pursued by an excess carrier. See Insurance Co. of State of Pennsylvania v. LNC Communities II, LLC, 2011 WL 5548955 (D. Colo. 2011). Federal Rule of Civil Procedure 19 is almost identical to Colorado Rule of Civil Procedure 19 and pertains to the joinder of persons needed for “just adjudication.” The Insurance Co. of the State of Pennsylvania (“ICSOP”) sought a declaratory judgment that it did not have a duty to defend or indemnify the defendants (collectively referred to as “Lennar Companies”) with regard to the underlying lawsuit brought by The Falls at Legend Trail Owners Association, Inc. (the “HOA”). Id. at *2. In its lawsuit, the HOA alleged Lennar Companies were liable for construction defects at The Falls at Legend Trail residential development.

Lennar Companies held two primary insurance policies, one issued by OneBeacon Insurance Company f/k/a General Accident Insurance Company (“General Accident”) and the other issued by American Safety Risk Retention Group, Inc. (“American Safety”). Lennar Companies also carried excess policies issued by ICSOP and Ohio Casualty Insurance Company (“Ohio Casualty”).

Read the full story…

Reprinted courtesy of Heather M. Anderson of Higgins, Hopkins, McClain & Roswell, LLP. Ms Anderson can be contacted at anderson@hhmrlaw.com

Read the court decision
Read the full story...
Reprinted courtesy of

Wendel Rosen Construction Attorneys Recognized by Super Lawyers and Best Lawyers

August 30, 2017 — Wendel Rosen Black & Dean LLP - California Construction Law Blog
Two members of Wendel Rosen’s Construction Practice Group were recognized recently. Garret Murai was selected for inclusion in the 2017 list of Northern California Super Lawyers and Matthew Graham was selected for inclusion in The Best Lawyers in America© 2018 edition. Garret Is co-chair of the firm’s Construction Practice Group and Matt is a 30+ year veteran of construction law. Read the court decision
Read the full story...
Reprinted courtesy of

Subcontract Requiring Arbitration Outside of Florida

August 07, 2018 — David Adelstein - Florida Construction Legal Updates
Have you entered into a subcontract that requires you to arbitrate disputes? If so, does the arbitration provision require you to arbitrate your dispute outside of Florida? If so, the case of Sachse Construction and Development Corp. v. Affirmed Drywall, Corp., 43 Fla. L. Weekly D1622e (Fla. 2d DCA 2018) applies and reinforces the notion: Read and consider what you sign! In Sachse Construction, a drywall subcontractor entered into a subcontract for a construction project in Miami with an arbitration provision. The subcontract provided that it shall be construed in accordance with Michigan law and required that arbitration shall take pace in Michigan per the Construction Industry Rules of the American Arbitration Association. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Claim Against Broker Survives Motion to Dismiss

January 25, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The insured's complaint against its broker for failure to secure adequate coverage survived a motion to dismiss. Broecker v. Conklin Prop., LLC, 2020 N.Y. App. Div. LEXIS 7399 (Dec. 2, 2020). Conklin Property, LLC purchased real property and entered into a contract with JJC Contracting, Inc. for construction and renovation of the property. The broker, Total Management Corp. (TMC) was retained by Conklin to secure insurance for the construction phase of the renovation project. During the renovation, an employee of JJC was injured at the property and died. The employee's estate then sued Conklin. US Underwriters, the insurer, disclaimed coverage pursuant to an exclusion for bodily injury to contractors and subcontractors and their workers. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Home Prices Expected to Increase All Over the U.S.

July 09, 2014 — Beverley BevenFlorez-CDJ STAFF
According to a survey of the National Association of Realtors (as quoted by the Housing Wire), home prices are expected “to increase in all states and the District of Columbia over the next 12 months, with most of the heavy growth in Florida, Texas, and California, among other states.” The highest expected price growth was “in states with low inventory levels, strong cash sales, and strong growth sectors (e.g., technology, oil).” Read the court decision
Read the full story...
Reprinted courtesy of

What are the Potential Damages when a House is a Lemon?

September 01, 2016 — Haldon L. Greenberg, Esq. – Florida Construction Law News
It seems that lemons are front page news these days. Beyonce just released a chart-topping[1] album all about what to do when life hands you lemons. In today’s vernacular, we use the term “Lemon” to describe a person or thing that is unsatisfactory, disappointing, or feeble.[2] In Florida, there is a “Lemon Law” that provides a way for consumers to receive a replacement or full refund for vehicles found to have defects which may affect the vehicle’s safety, value or use.[3] While there is no “Lemon Law” for construction projects, in Gray v. Mark Hall Homes, Inc.,[4] Florida’s Second District Court of Appeal cited to Florida Supreme Court precedent in holding that a home builder was on the hook for the entire contract value of a home he contracted to build for the Plaintiff, when it was revealed the home was a “Lemon”, or as the evidence at trial showed, “valueless.” Read the court decision
Read the full story...
Reprinted courtesy of Haldon L. Greenberg, Esq., Cole, Scott & Kissane, P.A.
Mr. Greenberg may be contacted at haldon.greenburg@csklegal.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES