How Does Your Construction Contract Treat Float
November 08, 2017 —
David Adelstein - Florida Construction Legal UpdatesAlthough there are different types of construction schedule float and more technical definitions, the definition that makes sense to me is that float is the amount of time a particular activity can be delayed without that activity delaying the project’s completion date (substantial completion date). In looking at a construction schedule, this determination is made from looking at the difference between the early start date for an activity and the late start date for that activity or the difference between the early finish date for that activity and the late finish date for that activity in your CPM schedule (which should be the same amount of time). This is often referred to as “total float” and is the float that I usually focus on since it may pertain to a delay to the substantial completion date of the project and can trigger either the assessment of liquidated damages and/or the contractor’s extended general conditions, whatever the case may be.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
Dadelstein@gmail.com
Does Article 2 of the Uniform Commercial Code Impact Your Construction Project?
November 07, 2022 —
Chris Cazenave - ConsensusDocsThe Uniform Commercial Code (UCC) is a set of statutes governing commercial transactions. Every state has adopted the UCC or some version of it. Understanding when and how the UCC applies to construction contracts is important because it can affect the agreement’s terms.
Article 2 of the UCC applies to the sales of goods, which the UCC defines very broadly to mean “all things (including specialty manufactured goods) which are movable . . . other than money in which the price is to be paid . . . .” UCC § 2-105. For the construction industry, UCC Article 2 governs most, if not all, purchases of materials and equipment installed or incorporated into the project. As a result, contractors and subcontractors should be familiar with the circumstances under which Article 2 may apply and how it may affect the project.
This article provides a brief overview of when Article 2 may affect your construction project and why it matters. The article also generally covers the UCC’s potential effects on the applicable statute of limitations, implied warranties, and when the obligation to make the payment arises.
Read the court decisionRead the full story...Reprinted courtesy of
Chris Cazenave, Jones Walker LLP (ConsensusDocs)Mr. Cazenave may be contacted at
ccazenave@joneswalker.com
Dispute Waged Over Design of San Francisco Subway Job
July 30, 2019 —
Erica Berardi - Engineering News-RecordContractor Tutor Perini Corp. is clashing with the San Francisco Municipal Transportation Agency over what the firm says are alleged design flaws that may push past December the completion of the already-delayed $1.6-billion Central Subway Project.
Read the court decisionRead the full story...Reprinted courtesy of
Erica Berardi, ENRMs. Berardi may be contacted at
BerardiE@enr.com
Landowners Try to Choke Off Casino's Water With 19th-Century Lawsuit
December 17, 2015 —
Edvard Pettersson – BloombergCalifornia’s latest water war is being waged at the edge of wine country against an Indian tribe planning a massive casino expansion as a group of landowners tries to stop them with a lawsuit from 1897.
The Santa Ynez Band of Chumash Indians is spending $170 million to build out its resort, featuring a 12-story tower on a bucolic landscape where only the mountains are higher. The tribe has also snapped up 1,400 more acres to house cramped residents of its reservation.
Read the court decisionRead the full story...Reprinted courtesy of
Edvard Pettersson, Bloomberg
Part of the Whole: Idaho District Court Holds Economic Loss Rule Bars Tort Claims Related to Water Supply Line that was Part of Home Purchase
October 03, 2022 —
Gus Sara - The Subrogation StrategistIn Safeco Ins. Co. of Ill. v. LSP Prods. Grp., 2022 U.S. Dist. LEXIS 139566, the United States District Court for the District of Idaho (District Court) considered whether the plaintiff’s tort claims against the manufacturer of an allegedly defective toilet water supply line were barred by the economic loss rule. The defendant filed a motion for summary judgment arguing that, since the supply line was a part of the home when the plaintiff’s insureds purchased it, the plaintiff was barred by the economic loss rule from bringing tort claims against the manufacturer. The District Court granted the defendant’s summary judgment motion, ruling that the supply line was a part of the home, which was the subject of the transaction, at the time it was purchased. Thus, the District Court held that the economic loss rule barred the plaintiff’s tort claims.
In 2012, Melissa Norris and Richard Meyers (collectively, the Homeowners) purchased a newly built home in Eagle, Idaho. In 2016, a toilet supply line in one of the bathrooms began leaking, causing water damage to the home as well as to window blinds, an oven and dishwasher. The Homeowners also incurred a loss of rental income. The Homeowners submitted a claim to Safeco Insurance Company (Insurer), their property insurance carrier, who ultimately covered the Homeowners’ losses.
Read the court decisionRead the full story...Reprinted courtesy of
Gus Sara, White and WilliamsMr. Sara may be contacted at
sarag@whiteandwilliams.com
Washington’s Court of Appeals Protects Contracting Parties’ Rights to Define the Terms of their Indemnity Agreements
March 19, 2024 —
Margarita Kutsin - Ahlers Cressman & Sleight PLLCIt has long been the law in Washington that contracting parties are free to draft contractual indemnity agreements to allocate risk arising from performance of the work, and Courts will generally enforce those agreements as written. This well-settled principle was recently reaffirmed in King County v. CPM Development Corp., dba ICON Materials[1] a decision from Division I of the Washington Court of Appeals, wherein one party to an indemnity agreement attempted to evade its contractual obligations by arguing that certain common law indemnity principles supersede the written terms. This appeal followed a multi-week jury trial from which the client and Ahlers Cressman and Sleight legal team, including Lindsay Watkins, Klien Hilliard, and Christina Granquist, obtained a seven-figure judgment in the client’s favor, including an award of all attorneys’ fees and costs.
ICON was the general contractor on a Vashon Island Highway Pavement project for King County. Part of the work on the project involved hauling away and disposing of ground milled asphalt (the “millings”) at King County-approved sites. ICON and D&R Excavating Inc., (“D&R”) executed a subcontract for D&R to perform that work. The subcontract incorporated the contract between ICON and King County, including the obligation to stockpile millings only at approved sites. D&R, however, did not obtain the requisite approvals from King County, and placed the millings at various sites on the Island, including locations that King County explicitly rejected.
Read the court decisionRead the full story...Reprinted courtesy of
Margarita Kutsin, Ahlers Cressman & Sleight PLLCMs. Kutsin may be contacted at
margarita.kutsin@acslawyers.com
Real Estate & Construction News Roundup (4/24/24) – Omni Hotels Hit with Cyberattack, Wisconsin’s Low-Interest Loans for Home Construction, and Luxury Real Estate Sales Increase
May 20, 2024 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, alternative lenders take the lead in CRE loans, construction workers worry about artificial intelligence, prospective homeowners express concerns about climate risks, and more!
- Even as overall real estate sales fell 4% nationwide in the first quarter, luxury real estate sales increased more than 2%, posting their best year-over-year gains in three years. (Robert Frank, CNBC)
- As many banks cut back from commercial real estate loans amid rising interest rates and a regional banking crisis that exploded in early 2023, a number of alternative lenders jumped in to lead the way. (Andrew Coen, Commercial Observer)
- Workers in construction and other industries are worried about artificial intelligence, and it’s keeping their companies from moving forward more decisively with the surging technology. (Matthew Thibault, Construction Dive)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Formal Request for Time Extension Not Always Required to Support Constructive Acceleration
April 25, 2022 —
David Adelstein - Florida Construction Legal UpdatesDoes a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim.
But first, what is constructive acceleration:
Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows:
(1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule.
Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com