Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor
September 09, 2024 —
David Adelstein - Florida Construction Legal UpdatesA recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project.
In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Consequential Damage Claims for Insurer's Bad Faith Dismissed
April 22, 2019 —
Tred R. Eyerly - Insurance Law HawaiiPartial dismissal of the insured's complaint seeking consequential damages for the insurer's bad faith was granted by the court. Bryant v. General Cas. Co., 2019 U.S. Dist. LEXIS 15369 (N.D. N.Y. Jan. 30, 2019).
Bryant purchased from General Casualty Company of Wisconsin (GCCW) a commercial property and casualty policy to cover the insured premises. While the building was rented to a tenant who operated a restaurant, it sustained a collapse. GCCW refused to cover the loss. Bryant sued. In addition to the cost of repairing and replacing the damage to the property, Bryant alleged he was out the value of rental revenue from his tenant, which was forced to close the restaurant and relocated as a result of the unrepaired damage.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Up in Smoke - 5th Circuit Finds No Coverage for Hydrochloric Acid Spill Based on Pollution Exclusion
October 19, 2020 —
Kerianne E. Kane & David G. Jordan - Saxe Doernberger & VitaThe Fifth Circuit Court of Appeals recently held that an insurer was not obligated to pay damages associated with a hydrochloric acid spill based on a pollution exclusion in the policy.
In Burroughs Diesel, Inc. v. Travelers Indemnity Co. of America,1 a trucking company sued its property insurer, Travelers Indemnity Company of America (“Travelers”) when it refused to pay a claim for a storage tank leak which resulted in over 5,000 gallons of hydrochloric acid entering the property and causing significant damage to buildings, vehicles, tools, and equipment. The acid was initially dispensed in liquid form, but quickly became a cloud that engulfed the property. Travelers denied coverage for the claim based on the pollution exclusion because “acids” fell within the policy’s definition of “pollutants.”
The trucking company sued Travelers in the United States District Court for the Southern District of Mississippi, alleging breach of contract and breach of good faith and fair dealing for refusing to pay the claim. The trucking company argued that coverage was warranted because there is an exception to the pollution exclusion if “the discharge, dispersal, seepage, migration, release or escape is itself caused by any of the ‘specified causes of loss,’” and the hydrochloric acid cloud was a form of “smoke,” which is a specified cause of loss covered by the policy. The District Court entered summary judgment in favor of Travelers, finding that the trucking company failed to demonstrate that an exception to the pollution exclusion applied. The trucking company appealed to the Fifth Circuit Court of Appeals.
Reprinted courtesy of
Kerianne E. Kane, Saxe Doernberger & Vita and
David G. Jordan, Saxe Doernberger & Vita
Ms. Kane may be contacted at kek@sdvlaw.com
Mr. Jordan may be contacted at dgj@sdvlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Condominium Exclusion Bars Coverage for Construction Defect
August 17, 2011 —
Tred R. Eyerly - Insurance Law HawaiiCoverage was denied under the policy’s condominium exclusion in California Traditions, Inc. v. Claremont Liability Ins. Co.,2011 Cal. App.LEXIS912 (Cal. Ct. App., ordered published July 11, 2011).
California Traditions was the developer and general contractor for a housing development. California Traditions subcontracted with Ja-Con to perform the rough framing work for 30 residential units. The project had 146 separate residences that were freestanding with no shared walls, roof, halls, or plumbing or electrical lines. To allow a higher density development, the project was developed, marketed and sold as condominiums.
The purchaser of one of the units filed a complaint against California Traditions alleging property damage from the defective construction. California Traditions cross-complained against Ja-Con.
Read the full story…
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
Read the court decisionRead the full story...Reprinted courtesy of
We've Surveyed Video Conferencing Models to See Who Fits the CCPA Bill: Here's What We Found
August 10, 2020 —
Shaia Araghi & Kyle Janecek – Newmeyer DillionWorldwide closures as a result of COVID-19 have resulted in an extreme surge in video conferencing use. This spike in use has also resulted in increased concern about the privacy of these video conferencing applications, including a class action lawsuit against one of the applications: Zoom. Because of this, we took a deeper look into the privacy policies of six prominent video conferencing applications and created a chart showing each video conferencing application's compliance with the California Consumer Privacy Act. Reviewing these materials will provide an awareness of the deficiencies within the Privacy Policies, which can help you become more well-informed about your own rights, and more knowledgeable about any deficiencies in your own business' privacy policy. If these widely-used and widely-known companies can have deficiencies, it is an important way to re-examine and fix these issues in your own.
To determine this, we reviewed the CCPA's twenty requirements for compliance, including: (1) the existence of a privacy policy, (2) required disclosures of information regarding the existence of rights under the CCPA, (3) instructions on how to exercise rights, and (4) providing contact information.
Here are the top 5 discoveries from our review:
1)
No videoconferencing applications address authorized agents. This makes sense, as the treatment of authorized agents were just laid out in the recently finalized regulations. This is a reminder to businesses to utilize these regulations when setting up compliance measures to ensure there is no risk in missing out on requirements like this, which will still be required and enforced by the Attorney General.
2)
Three platforms (WebEx, Skype, and Teams) have separate tabs and pages detailing privacy policies, and don't necessarily have a single unified and simple policy. Because of the accessibility requirements, this means that the privacy policy may not be readily accessible on the business's website, and may open companies to arguments that the entirety of their policy is non-compliant if key portions are hidden or otherwise inaccessible. Therefore to eliminate this concern, keep your policy unified, simple and in one location for ease of viewing.
3)
None of the platforms address information relating to minors under the age of 16, which is notable as some of these platforms have been used for online education. The final regulations outline different treatment for minors from ages 13 to 16, and for minors under the age of 13. As a result, privacy policies focused on compliance with the Children's Online Privacy Protection Act (COPPA) may be insufficient as it only applies to those under 13 years old.
4)
While all of the platforms state that no sale of information occurs, two platforms (Zoom and GoToMeeting) go above and beyond to explain the right to opt-out of sales. This is especially great as the CCPA permits that no notice needs to be given if no sale occurs. By taking this extra step, Zoom and GoToMeeting explain to their users that they have additional rights, which may be necessary as these platforms are also used by other entities, which may collect or otherwise use information collected from a videoconference meeting.
5)
Only one platform (Wire) does not give instructions on how to delete information. The CCPA regulations still require that information regarding instructions on how to delete information be given. The lack of instructions does not relieve Wire from its obligations, and similarly situated businesses may find themselves in a position where they will have to comply with a consumer request, in any form, as the regulations require that a business either comply, or list the proper instructions on how to make the request.
Download the Full Breakdown
To learn more about our findings and how the video conferencing companies stacked up against the CCPA, visit: https://www.newmeyerdillion.com/ccpa-privacy-policy-compliance-videoconferencing-platforms/. We hope this serves as a reminder to everyone to read the privacy platforms for the services you use and update your company's privacy policies to comply with the most recent regulations, as none of these services are currently in complete compliance, and it is only a matter of time before enforcement begins.
Shaia Araghi is an associate in the firm's Privacy & Data Security practice, and supports the team in advising clients on cyber-related matters, including compliance and prevention that can protect their day-to-day operations. For more information on how Shaia can help, contact her at shaia.araghi@ndlf.com.
Kyle Janecek is an associate in the firm's Privacy & Data Security practice, and supports the team in advising clients on cyber related matters, including policies and procedures that can protect their day-to-day operations. For more information on how Kyle can help, contact him at kyle.janecek@ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Estoppel Certificate? Estop and Check Your Lease
May 06, 2019 —
Lauren Podgorski - Snell & Wilmer Real Estate Litigation BlogIf you are leasing space in a building, there may come a time when you receive a request from your landlord to fill out and sign an estoppel certificate. Estoppel certificates are usually sent to tenants in connection with the sale or refinance of a building, and a third party may rely on the accuracy of the statements and information contained in the estoppel certificate in connection with that transaction. Estoppel certificates can range from a very simple, one-page document, to several pages.
I’ve received an estoppel certificate in the mail. What do I do now?
Consider the following:
Check your lease. Your lease may require you to deliver the signed estoppel certificate and may even give you a timeframe within which you are required to return it. A form of estoppel certificate may also be included in your lease as an exhibit. If you’ve previously agreed to a form of estoppel certificate in your lease, check to ensure the one you have received matches the form you previously agreed to and if it doesn’t make sure to review it carefully to make sure it is acceptable.
Review the estoppel certificate and confirm that all of the information is accurate. Be on the lookout for any terms or provisions that you did not agree to in your lease. If it seems like the landlord is trying to modify your lease, you likely do not need to consent to the change in this document. Cross off (or modify or delete, if you have an electronic copy) any information that is inaccurate. Fill in all blanks (if the blank is not applicable, write “N/A”), and if any exhibits are referenced in the body of the document, make sure they are actually attached.
Read the court decisionRead the full story...Reprinted courtesy of
Lauren Podgorski, Snell & WilmerMs. Podgorski may be contacted at
lpodgorski@swlaw.com
Viva La France! 2024 Summer Olympics Construction Features Sustainable Design, Including, Simply Not Building at All
August 26, 2024 —
Garret Murai - California Construction Law BlogIf you’re like me and many others you’ve probably been watching the 2024 Summer Olympics in Paris, France. We were in Paris last year and we passed the construction site of the Aquatics Centre, one of only three new permanent facilities that was constructed for this year’s Olympics. On a side note, Parisian Uber drivers are some of the most aggressive drivers I’ve seen, replete with honking, hand gestures, and cursing at other drivers and pedestrians in, of course, French. Putain!
In recent history, Olympic construction costs have skyrocketed, often vastly exceeding the planned budgets of the host cities, and, in recent years, has caused even some host city hopefuls to reconsider
whether to even throwing their hats in the ring. The 2020/2021Summer Olympics in Tokyo, for example, had an original budget of $7.5 billion. The actual cost was over $13 billion and, depending on what beans you count, may have been over twice that! Paris seeks to change all of this.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Hawaii Federal District Court Rejects Insurer's Motion for Summary Judgment on Construction Defect Claims
November 06, 2018 —
Tred R. Eyerly - Insurance Law HawaiiTaking into consideration a "Revised Occurrence Endorsement," the federal district court determined the insurer had a duty to defend. Gemini Ins Co. v. Constrx Ltd., 2018 U.S. Dist. LEXIS 163453 (D. Haw. Sept. 24, 2018).
Constrx Ltd. (CRX) contracted with the AOAO to perform remedial construction repairs to condominium buildings and apartment units. CRX asserted that it completed all work, including charge orders and punch list items and it left the site. CRX was paid less that the contract amount and demanded arbitration against the AOAO. In the arbitration the AOAO relied upon a report by Posard Brock & Associates (PBA) Report which set forth the AOAO's claims against CRX, including corrective work, remaining punch list work, construction delay costs, cost overruns, and other items justifying its payment than less that the contract amount.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
