SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Construction Litigation Roundup: “You Left Out a Key Ingredient!”

September 12, 2023 — Daniel Lund III - Lexology
“Baking is as much of a science as it is an art. It’s important to take the time to understand what you’re doing and why. Skipping steps can make or break your cupcakes, and there are a lot of things that can go wrong when baking from scratch.” And so it is with construction contract drafting. Defendants on a Miller Act claim filed by a second-tier subcontractor in federal court in Pensacola, Florida, sought to have the case transferred to Virginia, based upon a forum selection clause in the first-tier subcontract. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

---

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Eleventh Circuit Asks Georgia Supreme Court if Construction Defects Are Caused by an "Occurrence"

December 20, 2012 — TRED EYERLY, INSURANCE LAW HAWAII
The Eleventh Circuit certified a question to the Georgia Supreme Court, asking whether property damage can constitute an "occurrence" under a CGL policy where its effects are not felt on "other property." HDI-Gerling Am. Ins. Co. v. Morrison Homes, Inc., 2012 U.S. App. Ct. LEXIS 23813 (11th Cir. Nov. 19, 2012). The general contractor, Taylor Morrison Services, Inc., was covered by a CGL policy issued by Gerling. The policy excluded "expected or intended injury," contractual liability," and business risk exclusions. Morrison was sued by homeowners in a class action suit. Morrison had allegedly omitted four inches of gravel required beneath the base of the concrete foundations by the Uniform Building Code. Thereafter, the houses sustained water intrusion, cracks in the floors and driveways, and warped and buckling flooring. Gerling defended, but sued Morrison for a declaratory judgment. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii.
Mr. Eyerly can be contacted at te@hawaiilawyer.com

---

New Law Raises Standard for Defense Experts as to Medical Causation

September 05, 2023 — Haight Brown & Bonesteel LLP
On July 17, 2023, California Governor Gavin Newsom signed Senate Bill (SB) No. 652, adding Section 801.1 to the California Evidence Code. This section provides additional requirements for expert opinions relating to medical causation. In particular, it allows a party not bearing the burden of proof to offer a contrary expert in response to an expert proffered by a party bearing the burden of proof as to medical causation who is required to opine that causation exists to a reasonable medical probability. The contrary expert may only be proffered, however, if he or she is able to opine that an alternative medical causation is one that exists to a reasonable medical probability. Section 801.1, however, does not preclude an expert witness from testifying that a specific matter cannot meet a reasonable degree of probability in the applicable field. With respect to medical causation, a “reasonable degree of probability” means that the expert is testifying that a particular event or source was more likely than not the cause of a person’s injuries. Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

---

Catch 22: “If You’re Moving Dirt, You Need to Control Your Dust” (But Don’t Use Potable Water!)

February 18, 2015 — Stephen McKae – California Construction Law Blog
Returning from an Oregon vacation this past Summer along I-5, I found frequent reminders of the extraordinary drought conditions prevailing across California. A grey smoky gloom blanketed the California-Oregon border from Ashland to Weed from at least five wildfires. The prediction of rains in the north state was more curse than blessing as lightning threatened to touch off tender-dry fuel in the forests and start more fires. Farmers tilling fields produced massive dust clouds. And under the I-5 bridge along the Sacramento River arm of Lake Shasta, the lake had receded to the original streambed. On NOAA’s Palmer Drought Severity Index, nearly all of California is listed as in a condition of extreme or severe drought, and the Governor has issued a Proclamation of Continued State of Emergency requiring water conservation measures affecting all California residents. Indeed, early August news reports indicate that hopes of relief from an El Nĩno year are waning. The State Water Resources Control Board’s Emergency Regulation No. 2014 issued July 15 mandates action to reduce water use and require larger water suppliers to activate their Water Shortage Contingency Plan. The emergency regulation will remain in effect until April 25, 2015 unless extended due to ongoing drought conditions. Read the court decision
Read the full story...
Reprinted courtesy of Stephen McKae, Wendel Rosen Black & Dean LLP
Mr. McKae may be contacted at smckae@wendel.com

---

Address 'Your Work' Exposure Within CPrL Policies With Faulty Workmanship Coverage

December 29, 2020 — Joseph Reynolds - Construction Executive
New faulty workmanship coverage forms have emerged to potentially address the “your work” exposure found in most contractors professional liability (CPrL) policies. Once offered by only a single carrier, several insurers have recently entered the marketplace to cover the cost to repair or replace faulty work or the related material costs associated with the “self-performed work” of general and trade contractors. Commonly serving as a separate insuring agreement and offered in carrier-specific CPrL policies, faulty workmanship coverage forms are designed to protect contractors from the “your work” claims triggered by project owners and other third parties. This includes the contractor’s workmanship as well as the equipment, parts and materials such as steel beams, epoxy activators and anchor bolts used to perform construction work. Insureds should be aware that exclusions and strict conditions apply. For instance, faulty workmanship policies typically do not cover resulting bodily injury and property damage and some policies even exclude project delays and other business risks that can arise from the claims of unhappy customers. Another potentially confusing issue is the scope of coverage offered under a ‘faulty work’ endorsement. While some faulty workmanship enhancements are specifically-designed to cover “your work,” claims, others may only cover the products manufactured or fabricated by the insured and not the work they perform or install. Reprinted courtesy of Joseph Reynolds, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Reynolds may be contacted at joseph.reynolds@rtspecialty.com

---

Ahead of the Storm: Preparing for Irma

September 07, 2017 — Stephen H. Reisman – Peckar & Abramson, P.C.
While Hurricane Irma boils in the Atlantic and seems to be aiming towards Florida, storm preparations are well underway. As contractors are busy organizing efforts to secure their job sites, we at Peckar & Abramson offer some quick reminders that may prove helpful when the dust finally settles:

• Review your contracts, particularly the force majeure provisions, and be sure to comply with applicable notice requirements.
• Even if not expressly required at this point in time, consider providing written notice to project owners that their projects are being prepared for a potential hurricane or tropical storm and that productivity and the progress of the work will be affected, with the actual time and cost impact to be determined after the event.
• Consult your hurricane plan (which is often a contract exhibit) and confirm compliance with all specified safety, security and protection measures.

Read the court decision
Read the full story...
Reprinted courtesy of Stephen H. Reisman, Peckar & Abramson, P.C.
Mr. Reisman may be contacted at sreisman@pecklaw.com

---

7 Sustainability Ideas for Modular Classrooms in the Education Industry (guest post)

June 10, 2015 — Melissa Dewey Brumback – Construction Law in North Carolina
Today, a guest post on sustainable modular classrooms from Kathy Werder, a freelance architect by profession and a researcher by nature. According to Kathy, most of her research papers focus on promoting integration that leads to sustainable and lean design and construction practices. Kathy is obsessed with the latest rage in the construction industry – modular building solutions. She is also an avid writer, and loves blogging about green buildings and portable construction units. Welcome, Kathy! According to Wikipedia, a sustainable building refers to “ a structure and using process that is environmentally responsible and resource-efficient throughout a building’s life-cycle from sitting, to design, construction, operation, maintenance, renovation, and demolition.” So if we accept this definition to be true, in order to make an actual sustainable building we have to consider the entire process of building right from the blueprint stage all the way to demolition, and ensure that at every step of the way there is minimal or no negative impact on the environment, especially in terms of resource efficiency. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Construction Law in North Carolina
Ms. Brumback may be contacted at mbrumback@rl-law.com

---