CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

What is a “Force Majeure” Clause? Do I Need one in my Contract? Three Options For Contractors, Subcontractors and Suppliers to Consider

June 20, 2022 — William L. Porter - Porter Law Group
In the world of the building and construction industry, the general rules of contracting are fairly simple. A supplier agrees to supply equipment or materials for a specific price and within a certain time frame, does so, and is paid an agreed sum. Likewise, contractors and subcontractors agree to build structures per plans and specifications within certain time frames and are paid accordingly. Pretty simple. But what happens when some outside event makes performance impossible or unduly expensive or substantially delayed? What happens, for example, if a ship is sitting off the coast of Long Beach for three months with equipment ordered for the project and it cannot be unloaded due to a labor shortage? What if government mandates cause factories that build needed equipment to close due to an epidemic or pandemic? What if the supply warehouse holding the equipment until it is ready for installation unexpectedly burns to the ground? What if a Russian missile blows up the factory in Ukraine where the intended equipment is being manufactured? What happens then? Who bears the financial consequence? A properly constructed “force majeure” clause may provide the answer to these questions. The Marriam-Webster Dictionary defines “force majeure” as a literal translation from the French meaning “a superior or irresistible force.” It further defines the term as “an event or effect that cannot be reasonably anticipated or controlled.” The Oxford Dictionary defines force majeure as “unexpected circumstances, such as a war, that can be used as an excuse when they prevent somebody from doing something that is written in a contract.” Read the court decision
Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

---

Minnesota Civil Engineers Give the State's Infrastructure a "C" Grade for the Second Time

May 02, 2022 — American Society of Civil Engineers
SAINT PAUL, Mn. — The Minnesota Section of the American Society of Civil Engineers (ASCE) today released preliminary findings from the 2022 Report Card for Minnesota's Infrastructure, with 10 categories of infrastructure receiving an overall grade of a 'C', meaning Minnesota's infrastructure is in mediocre condition. Minnesota has taken steps to make its infrastructure network more sustainable to withstand increasingly severe weather, but additional steps must be taken as the state's infrastructure is aging. Funding has been limited for systems throughout the state, particularly for surface transportation networks, and local and state funding must be increased to bring these critical systems up to speed. Civil engineers graded aviation (B), bridges (C), dams (C), drinking water (C-), energy (C), parks (B-), ports (C-), roads (D+), transit (C-) and wastewater (C). "The ASCE report card serves as an important benchmark for where our infrastructure currently stands and lays out how we can make improvements," said Sen. Sandy Pappas, DFL-St. Paul. "Knowing that these systems play such a crucial role in economic progress and the safety of Minnesotan families, we have made infrastructure a topline issue and must continue to do so to secure a prosperous future here in Minnesota." ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS Founded in 1852, the American Society of Civil Engineers represents more than 150,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel. Read the court decision
Read the full story...
Reprinted courtesy of

---

Quick Note: Notice of Contest of Claim Against Payment Bond

January 31, 2018 — David Adelstein - Florida Construction Legal Updates
On private jobs where the general contractor has an unconditional payment bond, subcontractors, sub-subcontractors and suppliers need to serve a notice of nonpayment to preserve payment bond rights. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---

Colorado Introduces Construction Defect Bill for Commuter Communities

January 23, 2013 — CDJ STAFF
A Colorado State Senator has introduced a bill suggesting a change to the way that construction defect claims are handled in "transit-oriented developments." And what are these? According to the bill these are "any multi-family residential or mixed-use project within one-half mile of any commuter rail stop, commuter light rail stop, or commuter bus stop." So the bill would treat homes with good public transportation differently from those not so convenient to public transportation. The bill, SB 52, would institute a right to repair for construction defects in these developments. Construction defect claims would be referred to binding arbitration. Further, construction professionals could not be sued for environmental conditions related to transit, commercial, public, or retail use. Read the court decision
Read the full story...
Reprinted courtesy of

---

CFTC Establishes Climate-Risk Unit, Echoing Other Biden Administration Agency Themes

April 12, 2021 — Karen C. Bennett & Jane C. Luxton - Lewis Brisbois
On March 17, the Commodity Futures Trading Commission (CFTC or Commission) joined other federal agencies led by Biden Administration appointees in ramping up consideration of climate-related risks in matters under the Commission’s jurisdiction. Stressing the need for a climate-resilient financial system, the CFTC’s new Climate-Risk Unit (CRU) will focus on “the role of derivatives in understanding, pricing, and addressing climate-related risk and transitioning to a low-carbon economy.” Formation of the CRU will accelerate the CFTC’s “engagement in support of industry-led and market-driven processes in the climate – and the larger ESG – space critical to ensuring that new products and markets fairly facilitate hedging, price discovery, market transparency, and capital allocation.” As with similar programs launched by the Securities and Exchange Commission (see our previous alert from March 19), businesses affected by the CFTC’s new initiative should consider active engagement to ensure informed and appropriate approaches are included in any new regulations, policies, or frameworks governing climate-related issues. Reprinted courtesy of Karen C. Bennett, Lewis Brisbois and Jane C. Luxton, Lewis Brisbois Ms. Bennett may be contacted at Karen.Bennett@lewisbrisbois.com Ms. Luxton may be contacted at Jane.Luxton@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Recent Environmental Cases: Something in the Water, in the Air and in the Woods

July 22, 2019 — Anthony B. Cavender - Gravel2Gavel
State of Texas, et al. v. US EPA. The revised regulatory definition of “Waters of the U.S.” continues to generate litigation in the federal courts. On May 28, 2019, the U.S. District Court for the Southern District of Texas held that the 2015 rulemaking proceedings used by EPA and the U.S. Army Corp of Engineers to redefine this important component of the Clean Water Act were flawed in that the notice and comment provisions of the Administrative Procedure Act (APA) were violated because insufficient notice was provided by these agencies that “adjacent” waters newly subject to the regulatory jurisdiction of these agencies, can be determined on the basis of specific distances, which was a change in the agencies’ thinking, and insufficient notice of this change was provided to the public. In addition, the final rule “also violated the APA by preventing interested parties from commenting on the scientific studies that served as the technical basis” for the rule. However, the court did not vacate the new rule, but remanded the matter to the “appropriate administrative agencies” to give them an opportunity to fix this problem. State of Oklahoma, ex rel. Mike Hunter, Attorney General of Oklahoma v. US EPA and the United States Army Corps of Engineers. A day later, on May 29, 2019, the U.S. District Court for the Northern District of Oklahoma rejected arguments that the new redefinition should be preliminarily enjoined.While this case was filed in 2015, intervening litigation in the federal courts, including the U.S. Supreme Court, caused a substantial delay in the disposition of this case. The court, noting that the tests for granting such an injunction against the federal government are fairly exacting, held that the plaintiffs, the State of Oklahoma and a number of industry groups and associations, failed to convince the court that the harm they would suffer if the rules remained effective would be irreparable. Presumably, this case will be going to trial in the near future. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---

KF-103 v. American Family Mutual Insurance: Tenth Circuit Upholds the “Complaint Rule”

May 12, 2016 — Adria Robinson – Colorado Construction Litigation
In Colorado, the “complaint rule” requires insurance carriers to provide a defense to its insured when the allegations contained in the complaint allege any set of facts that may fall within an insurance policy. Some insurers have pushed back on this rule arguing that it may cause an insurer to exercise its duty to defend although the underlying facts ultimately do not fall within the policy. In KF 103-CV, LLC v. American Family Mutual Insurance Company, 2015 WL 6517782, the Tenth Circuit of the United States Court of Appeals upheld the complaint rule. In its decision, the Tenth Circuit cited several Colorado state court rulings recognizing the courts’ intent to incentivize insurers to defend policies that may facially fall within the terms of the policy. Where there is uncertainty about coverage, the Tenth Circuit cited a Colorado Supreme Court case stating, “[t]he appropriate course of action for an insurer who believes that it is under no obligation to defend, is to provide a defense to the insured under the reservation of its rights.” Read the court decision
Read the full story...
Reprinted courtesy of Adria Robinson, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Robinson may be contacted at robinson@hhmrlaw.com

---

The Prolonged Effects on Commercial Property From Extreme Weather

January 29, 2024 — The Hartford Staff - The Hartford Insights
As evidenced by the extraordinary heat in the Southwest, a string of tornadoes in South and Midwest, and heavy rains in California and Florida, 2023 was a banner year for extreme weather. However, 2024 may be no different, which means now is the time for businesses to rethink the way they approach volatile weather, as well as the frequency and severity of storms and natural disasters. The risks and challenges that businesses face as extreme weather becomes stronger and causes more property damage, requires innovative technology with specialized insurance solutions. Through updated building codes, advancements in technology and meaningful infrastructure improvements, businesses can make a difference in protecting their property and reducing losses. Stronger Building Codes To Withstand Storms It is not uncommon to see the destruction that a hurricane or tornado leaves behind. However, stronger building codes are one of the best ways to make sure property can withstand catastrophes. Florida for example implemented changes to its building codes after Hurricane Andrew, and then again in 2007 after the Hurricanes of 2004 and 2005. New construction since then has made houses and buildings significantly more hurricane proof. Buildings constructed 30 years ago were likely built with codes that may have neglected the impact of strong winds from an extreme hurricane or significant rainfall that a storm can bring, especially along the Atlantic and Gulf coasts. Read the court decision
Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

---