Fairfield Connecticut Building Expert Directory

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

Big Changes and Trends in the Real Estate Industry

February 06, 2023 — Rachel Mihai - Bremer Whyte Brown & O'Meara LLP
In my practice, I am fortunate enough to attend a real estate conferences on a regular basis. And, without exception, we always get a run down on hot trends/cases from industry leaders. Some issues that are being attacked in hot cases/trends are:

Are the typical commission structures – e.g., the typical 5% to 6% divided in half – fair or creating an antitrust issue?
Is MLS commission anti-competitive and artificially inflates commission rates?
Can a buyer’s agent advertise/represent that it is working for its client for free, as generally happens and has been allowed?
What is the impact of agent only showing their clients houses with higher typical commissions, like 6%? And how is this being advertised, pushed for and manipulated contrary to the interests of consumers?

There are currently some big, national cases that will likely bring about big changes in the entire national real estate community with regard to how real estate brokers’/agents’ commissions are determined, explained and advertised. These cases revolve around antitrust and alleged conspiracy claims – asserting that the use of commissions in today real estate markets are creating an overcharging to consumers and artificially manipulation of the market. Read the court decision
Read the full story...
Reprinted courtesy of Rachel Mihai, Bremer Whyte Brown & O'Meara LLP
Ms. Mihai may be contacted at rmihai@bremerwhyte.com

Withdrawal Liability? Read your CBA

July 10, 2018 — Wally Zimolong – Supplemental Conditions
Withdrawal liability is a huge issue facing unionized employers. According to Bloomberg, 93% of the Top 200 largest pension plans are underfunded by a combined $382 billion. Contractors that withdraw from a multi-employer pension plan can face hundreds of thousands or millions of dollars in assessed withdrawal liability. However, employers may be able to avoid that liability, plus the legal and consulting fees to fight it, by simply reading their collective bargaining agreement. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Burden to Prove Exception to Exclusion Falls on Insured

April 19, 2022 — Tred R. Eyerly - Insurance Law Hawaii
In a dispute between two insurers, the Ninth Circuit relied upon Nevada law in finding that the burden of proving that an exception to the exclusion applies was on the insured. Zurich Am. Ins. Co. v. Ironshore Specialty Ins. Co., 2022 U.S. App. LEXIS 1626 (9th Cir. Jan. 20, 2022). Ironshore insured seven subcontractors. The policy included an exclusion providing there was no coverage for any property damage for the subcontractors' for "work performed prior to the policy inception." An exception to the exclusion provided that the exclusion did not apply to property damage that was "sudden and accidental and takes place within the policy period." The seven subcontractors were sued for work they had performed. Zurich defended and indemnified the subcontractors. Zurich then sued Ironshore seeking contribution and indemnification for defense and settlement costs. The parties stipulated that all construction work at issue had been completed before the inception of Ironshore's policy and that none of the complaints against the subcontractors alleged that sudden and accidental damage had occurred after the inception of Ironshore's policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Update: New VOSH Maximum Penalties as of July 1

July 26, 2017 — Christopher G. Hill - Construction Law Musings
As those who read Construction Law Musings know, as a construction attorney, I want to assure that not only are my clients successful in their litigation/dispute resolution endeavors, but that they stay out of trouble. I take my problem solving and advising roles quite seriously. As part of this role as advisor, I want to let those that read Musings know that as of July 1, 2017 the Virginia Occupational Safety and Health Administration increased their maximum penalties for safety violations. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Connecticut Supreme Court to Review Several Issues in Asbestos Coverage Case

November 08, 2017 — Ciaran Way & Robert F. Walsh – White and Williams LLP
On October 18, 2017, in R.T. Vanderbilt Company v. Hartford Accident & Indemnity Company, the Connecticut Supreme Court certified four issues for appeal, which relate to trigger, allocation, pollution exclusions, and the occupational disease exclusion in the context of asbestos bodily injury claims. This post identifies the issues the Connecticut Supreme Court will decide on appeal and sets forth the Appellate Court’s ruling on each issue. Issue 1: Whether a “continuous trigger” theory of coverage applies to asbestos-related disease claims and whether expert medical testimony on the timing of injury should be precluded The Appellate Court applied a continuous trigger, and found that the trial court properly excluded testimony from medical experts the insurers had proffered to prove that the asbestos disease process did not support a continuous trigger. Reprinted courtesy of Ciaran Way, White and Williams LLP and Robert Walsh, White and Williams LLP Ms. Way may be contacted at wayc@whiteandwilliams.com Mr. Walsh may be contacted at walshr@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Jury Awards Aluminum Company 35 Million in Time Element Losses

September 23, 2019 — Michael S. Levine & Daniel Hentschel - Hunton Insurance Recovery Blog
On July 3, 2019, a Delaware jury determined that fourteen property insurers for Noranda Aluminum Holding Corp., an aluminum producer that filed for bankruptcy and ceased operations three years ago, owe Noranda over $35 million in time element losses that Noranda sustained as a result of two separate catastrophic incidents that occurred at its aluminum facility in 2015 and 2016. In August 2015, an aluminum explosion occurred at Noranda’s facility, resulting in substantial property damage and bodily injuries. Though the insurers paid for Noranda’s property damage claim, the insurers only covered $5.64 million of Noranda’s $22 million time element claim. In January 2016, the same facility sustained significant damage as a result of equipment failure. The insurers again paid for Noranda’s property damage claim arising from the equipment failure but declined to pay any of its $22.8 million time element claim. Reprinted courtesy of Michael S. Levine, Hunton Andrews & Kurth and Daniel Hentschel, Hunton Andrews & Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Hentschel may be contacted at dhentschel@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Is Construction in Arizona Back to Normal?

September 10, 2014 — William M. Kaufman – Construction Lawyers Blog
The Phoenix Metro area is finally pulling out of the Great Recession of 2008. Potential homebuyers are frantically looking to buy a home before interest rates rise and prices continue their ascent to normalcy. For the last several months, residential construction builders have continued to buy more land around the Valley of the Sun for new subdivisions, especially in North Phoenix and the East Valley. In fact, from January through May of 2013, in the Phoenix Metro area alone, 86 new communities have come to fruition—more than all of 2012. Nationally, single-family housing starts reached 667,000 in December 2013 according to the National Association of Home Builders tracking of single-family home starts, which is comparable to 1985 levels. It has been well documented that since the conclusion of World War II, Arizona’s population growth fostered new home construction at a rapid, almost unmatched pace. At the 2006 construction peak, Arizona’s residential construction output climbed to 64,000, more than double the average 20,000 to 30,000 new homes that are typically constructed annually. Building rates have not come close to the 2006 numbers, but new home starts increased 70 percent since 2012. So after six years after the real estate bubble popped, is the construction industry in Arizona finally back to normal? It depends on your definition of “normal.” In 2009, foreclosures reached alarming proportions. However, in 2010, the engine of Arizona’s population growth, the Phoenix Metro area, began to grow again. Since 2010, Maricopa County had added 125,000 residents. There is strong demand for new housing, and appreciating housing prices has let the construction industry get back on its feet. In residential construction, supply is tight, and all cash offers are common. We all know that Wall Street played a huge role in creating the housing bubble, and eventual bust, by facilitating the use of risky, sub-prime mortgages and turning them into securities that were sold to investors, pension-funds, and the like. Reprinted courtesy of William M. Kaufman, Lockhart Park LP Mr. Kaufman may be contacted at wkaufman@lockhartpark.com, and you may visit the firm's website at www.lockhartpark.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES