Fairfield Connecticut Building Expert Directory

Actual Cost Value Includes Depreciation of Repair Labor Costs

November 07, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The court granted the insurer's motion to dismiss after determining that benefits paid for actual cost value (ACV) did not include repair or replacement labor costs. Shahan v. Allstate Vehicle & Prop. Ins. Co., 2022 U.S. Dist. LEXIS 135488 (W.D. La. July 29, 2022). Hurricane Laura damaged the insured's home. She filed a claim with Allstate under her homeowners policy. Allstate issued payment. The insured filed suit alleging Allstate wrongfully withheld amounts by depreciating labor when calculating the ACV of the damaged property. Allstate moved to dismiss. The policy was a replacement cost policy where the insured would receive the actual cash value of her insured property when it was damaged or destroyed by a covered peril. ACV was calculated by taking the repair/replacment which included both material and labor, and then deducting for depreciation. If no repairs or replacements were made, the insured was paid the ACV. If repairs or replacement was done, Allstate reimbursed the insured for the depreciation deduction. The insured challenged Allstate's refusal to pay 100% of the future labor costs, without any depreciation, even if the insured did not replace or repair the damaged property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

New Jersey Construction Company Owner and Employees Arrested for Fraud

December 04, 2013 — CDJ STAFF
Frank Chimento, Jr., the owner of Chimento Construction of Parsippany, New Jersey, and three of his employees, Joseph Carsillo, Frank Chimento III, and Carl J. Corso, were arrested by federal agents. The elder Chimento is accused of falsifying his own income taxes, as well as failing to collect and turn over federal and state payroll taxes. He is additionally charged with falsifying union benefit fund contributions. The three employees are also accused of filing false income tax statements and also of attempting to defraud the state of New Jersey of unemployment compensation benefits. An additional unnamed conspirator made transactions at multiple financial institutions in order to pay employees directly in cash. One of the three employees, Mr. Carsillo, worked for the company and received cash payments while maintaining to the New Jersey Department of Labor and Workforce Development that he was unemployed. Mr. Carsillo was receiving $526 per week from the NJDOL-WD in unemployment benefits, starting in 2009. From 2009 through 2011, Mr. Carsillo received $19,988 in unemployment benefits and an additional $351,788 in wages from Chimento. Read the court decision
Read the full story...
Reprinted courtesy of

No Coverage for Homeowner Named as Borrower in Policy but Not as Insured

July 08, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The magistrate judge recommended that the homeowner's complaint seeking coverage for damage caused by Hurricanes Laura and Delta be denied because the homeowner was only named as the borrower under the policy. LeDay v. Integon Nat'l Ins. Co., 2024 U,S. Dist. LEXIS 87369 (W.D. La. April 15, 2024). When the homeowner sought coverage for hurricane damage, it was denied. The homeowner then sued and Integon moved to dismiss. Integon argued it did not issue a policy to the homeowner, but the policy was issued to Midland Mortgage. The pro se homeowner did not respond to the motion. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Client Alert: Release of Liability Agreement Extinguishes Duty of Ordinary Care

February 05, 2015 — R. Bryan Martin and Whitney L. Stefko – Haight Brown & Bonesteel LLP
On January 27, 2015, the California Court of Appeal, Fourth Appellate District, in Eriksson v. Nunnink (Case No. E057158), held a release of liability between Decedent and Defendant was enforceable as a defense to the Decedent's Parents' wrongful death and negligent infliction of emotional distress ("NIED") claims. In Eriksson, the Court concluded that on the basis of the signed release agreement, Defendant did not owe a duty of care to Decedent and thus could only be liable for Decedent's death if caused by the Defendant's gross negligence. The Court held that Plaintiffs failed to establish gross negligence and affirmed the lower court's judgment. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys R. Bryan Martin and Whitney L. Stefko Mr. Martin may be contacted at bmartin@hbblaw.com; Ms. Stefko may be contacted at wstefko@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

3D Printing Innovations Enhance Building Safety

October 07, 2019 — Mahmut Ekenel & Melissa Sanchez - Construction Executive
The mention of 3D printing alone is enough to get people excited, often conjuring images of a desktop console that can download and create three dimensional objects such as prototypes, or mechanical parts. And yet, in recent years the technology has given way to a slight impatience, as people begin to wonder how and when it will have a direct impact on both their lifestyles and their businesses. The construction industry has been quick to take advantage of these innovations, and the effects are tangible, especially regarding building safety. The 3D construction technology allows for several key advantages in terms of faster construction times, uncompromised quality of construction and lower costs—allowing for affordable dwellings to be quickly built for people in need. These advantages also lead to safety improvements during the building process. The ability to accelerate construction time without requiring an increase in labor results in a fewer construction-related workplace injuries and a reduction in material waste, making it an environmentally friendly construction method as well. ICC-Evaluation Service (ICC-ES), a subsidiary of the International Code Council (ICC) which develops model codes and standards (i.e. International Building Code, International Residential Code) and delivers a wide array of building safety services, has taken the lead on developing acceptance criteria to address building code compliance of 3D printed construction. Currently, 3D construction technology is not within the provisions of the International Building Code (IBC) or International Residential Code (IRC). The acceptance criteria introduces new compliance measures for interior and exterior 3D printed concrete walls (with and without structural steel reinforcement), load-bearing and non-load-bearing walls, and shear walls in one-story, single-unit, residential dwellings. The 3D walls are constructed by printing two outer layers of 3D concrete and then filling the core with 3D concrete to form a solid wall. Reprinted courtesy of Mahmut Ekenel & Melissa Sanchez, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Mr. Ekenel may be contacted at mekenel@icc-es.org Ms. Sanchez may be contacted at msanchez@icc-es.org Read the court decision
Read the full story...
Reprinted courtesy of

Construction Defects #10 On DBJ’s Top News Stories of 2015

December 10, 2015 — Beverley BevenFlorez-CDJ STAFF
The Denver Business Journal’s top 15 news stories of 2015 covers the “Battle Over Construction Defects.” Some developers and other groups have blamed the lack of condominium development in Denver and other Colorado cities on the state’s defect laws. After a construction-defects reform bill failed to pass the Colorado Legislature, several cities passed construction defect-related ordinances, according to the Denver Business Journal: “In November the Denver City Council voted 12-1 to approve an ordinance aimed at making it harder to file class-action lawsuits over construction defects within the city.” Read the court decision
Read the full story...
Reprinted courtesy of

CA Senate Report States Caltrans ‘Gagged and Banished’ its Critics

August 06, 2014 — Beverley BevenFlorez-CDJ STAFF
According to the Sacramento Bee, the California Senate’s latest report said that “at least nine top experts for the new $6.5 billion San Francisco-Oakland Bay Bridge” were “’gagged and banished’” after complaining “about substandard work by the Shanghai, China, firm that built much of the span.” According to the report, reported by the Sacramento Bee, Tony Anziano, Caltrans’ chief executive of the project, “removed or demoted quality-assurance and fabrication engineers who tried to force the contractor to fix cracked roadway welds.” The report did not evaluate the bridge’s quality or safety, however, it “called for greater openness in large construction projects, a review of the weld problems by independent experts, and an investigation of allegations that engineering decisions were made by non-engineers.” Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES