FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Sometimes You Get Away with Unwritten Contracts. . .

July 28, 2018 — Christopher G. Hill - Construction Law Musings
I have spoken often regarding the need for a well written construction contract that sets out the “terms of engagement” for your construction project. A written construction contract sets expectations and allows the parties to the contract to determine the “law” of their project. An unwritten “gentleman’s agreement” can lead to confusion, faulty memories, and more money paid to construction counsel than you would like as we lawyers play around in the grey areas. One other area where the written versus unwritten distinction makes a difference is in the calculation of the statute of limitations. In Virginia, a 5 year statute of limitations applies to written contracts while a 3 year statute of limitations applies to unwritten contracts. This distinction came into stark relief in the case of M&C Hauling & Constr. Inc. v. Wilbur Hale in the Fairfax, Virginia Circuit Court. In M&C Hauling, M&C provided hauling services to the defendant through a subcontract with Hauling Unlimited in 2014, the last of which was in July. M&C provided over 2000 hours of hauling and provided time tickets (that were passed to Mr. Hale on Hauling Unlimited letterhead and signed by Mr. Hale or his agent) and an invoice stating the price term of $75.00 per hour. No separate written contract between M&C and Hauling Unlimited or Mr. Hale existed. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Hail Drives Construction Spending in Amarillo

October 25, 2013 — CDJ STAFF
Amarillo had a hailstorm in May and it’s still having an effect on the construction industry there. Prior to the May 28 hailstorm, the city issued 223 permits for roofing projects, worth a total of $1.9 million. But in the four months after the hailstorm, the city issued 13,696 roofing permits worth about $151.4. During the same nine months of 2012, the total was only $6.9 million. The Amarillo Globe-News reports that there has been a slowing of residential roof work, but the commercial roofing is still going strong. Scott McDonald, an Amarillo building official told the paper that a commercial roof can exceed a million dollars. “The commercial aspect is much more complicated, and we’re just now getting started,” said Mr. McDonald. Read the court decision
Read the full story...
Reprinted courtesy of

---

Missouri Construction Company Sues Carpenter Union for Threatening Behavior

February 10, 2014 — Beverley BevenFlorez-CDJ STAFF
According to KMOV News, Raineri Construction Company in Missouri filed suit against the Local Carpenters’ District Council claiming employees had been “stalked and threatened” by the union. However, the Carpenters Union “denies the allegations” and said “it has the right to protest against a company that doesn’t always meet the union standards for pay and benefits.” Tony Raineri, one of the construction company’s executives, said to KMOV News: “For me it wasn’t such a big deal until they started making threats of bodily harm, started following me and my wife to our home, started following my employees to their homes.” KMOV News reported that a “union representative told News 4’s Craig Cheatham that no one acting on behalf of the Carpenters Union ever threatened, harassed or stalked Raineri, his employees or their clients.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Time is Money. Unless You’re an Insurance Company

December 02, 2015 — Garret Murai – California Construction Law Blog
Benjamin Franklin may never have been President but he’s better known than most of them. Not least of all for his pithy quotes on a wide range of subjects:

On personal finance – “A penny saved is a penny earned.”

On education – “Tell me and I forget, teach me and I remember, involve me and I learn.”

On getting real – “In this world nothing can be said to be certain, except death and taxes.”

On guests – “Guests, like fish, begin to smell after three days.”

On lawyers – “A countryman between two lawyers is like a fish between two cats.”

On beer – “In wine there is wisdom, in beer there is freedom, in water there is bacteria.”

But if you were to pick one theme that seems to recur the most in Franklin’s quotes, it would be productivity:

“Time is money.”

“By failing to prepare, you are preparing to fail.”

“Never leave that till tomorrow which you can do today.”

“Early to bed and early to rise, makes a man happy, wealthy and wise.”

But, as the next case, Grebow v. Mercury Insurance Company, Case No. B261172, California Court of Appeals for the Second District (October 21, 2015), illustrates, sometimes the most efficient way of doing things may not necessarily be the most financially prudent way of doing things. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Real Estate & Construction News Round-Up (11/16/22) – Backlog Shifts, Green Battery Storage, and Russia-Ukraine Updates

December 05, 2022 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
This week’s round-up explores backlog shifts in the nonresidential construction sector, updates from the ongoing war between Russia and Ukraine, lithium-ion battery storage issues in New York City, and more.

• According to Associated Builders and Contractors, construction backlog fell back below the reading observed in February 2020, largely due to a decline in the commercial and institutional sector. (Sebastian Obando, Construction Dive)
• Amid celebration after retaking Kherson from retreating Russian troops, the Kremlin targeted critical infrastructure before withdrawing. (Michael Kern, Oil Price)
• Real estate value in the metaverse is rising, given that virtual land can be built upon to create unique branding experiences that lend to advertising, marketing, socializing, and entertainment. (Evan Bourke & Sarah Hedley Hymers, Euronews)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Bad Faith Claim for Investigation Fails

January 07, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The insurer prevailed in summary judgment, disposing of the insured's bad faith claim based upon the investigation of the loss. Nino v. State Farm Lloyds, 2014 U.S. Dist. LEXIS 163993 (S.D. Tex. Nov. 24, 2014). The insured filed a claim with State Farm for damage resulting from a hailstorm on March 29, 2012. An independent adjuster, Charles Crump, conducted an investigation on behalf of State Farm. Crump inspected the roof, where he noted prior repair to the roof, and found no covered damage to the roof as the result of the 2012 hailstorm. Crump found minimal damage to other parts of the house, totaling $2,311.75, which resulted in no payment after the deduction. Crump provided the insured with a printed copy of his damage estimate. The insured then hired a public adjuster who found damage totaling $31,991.72, including $10,051.22 in roof repairs. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Another Colorado Construction Defect Reform Bill Dies

May 07, 2014 — Beverley BevenFlorez-CDJ STAFF
Colorado construction defects reform Senate Bill 220 died when “Senate President Morgan Carroll, D-Aurora, declined to call a second committee to hear” the bill, according to Ed Sealover writing for the Denver Business Journal. Sen. Carroll declared that the “bill backers” did not incorporate any of the “suggestions she or House Speaker Mark Ferrandino had given them.” “SB 220 would have required condo-unit owners to submit to alternative-dispute resolution such as arbitration or mediation if the unit developer required it,” Sealover reported. “And it would have required that a majority of members of a homeowners association agree to file a lawsuit, a standard significantly larger than the two-person bar that now must be met.” Bill Cosponsor Sen. Mark Scheffel, R-Castle Rock, “believes litigation reform” will become “an election issue and” that it “has strong momentum heading into the 2015 session.” Read the court decision
Read the full story...
Reprinted courtesy of

---