FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Manhattan Home Prices Jump to a Record as Buyers Compete

April 02, 2014 — Oshrat Carmiel – Bloomberg
Manhattan apartment sales surged in the busiest start to a year since 2007, setting price records as buyers vied for a limited supply of homes for sale and deals were completed at new high-end developments. Sales of co-ops and condominiums in the first quarter jumped 35 percent from a year earlier to 3,307, according to a report today from appraiser Miller Samuel Inc. and brokerage Douglas Elliman Real Estate. The median price climbed 19 percent to $972,428, while the the average price per square foot rose 24 percent to $1,363, the highest in 25 years of record-keeping. Price gains are accelerating in a market where the inventory of homes for sale plummeted to record lows three times in the past year as buyer demand increased. Of the deals completed in the first quarter, 38 percent were at or above the asking price, up from 17 percent a year earlier, according to Jonathan Miller, president of New York-based Miller Samuel. Read the court decision
Read the full story...
Reprinted courtesy of Oshrat Carmiel, Bloomberg
Ms. Carmiel may be contacted at ocarmiel1@bloomberg.net

---

Late Filing Contractor Barred from Involving Subcontractors in Construction Defect Claim

March 01, 2012 — CDJ STAFF

The Colorado Court of Appeals looked at that state’s Construction Defect Action Reform Act in determining if a general contractor could add subcontractors as third-party defendants to a construction defect lawsuit. Shaw Construction, LLC was the general contraction of the Roslyn Court condominium complex, and was sued by the homeowners’ association in a construction defect case. United Builder Services was the drywall subcontractor on the project. MB Roofing had installed roofs, gutters, and downspouts. The certificate of occupancy for the last building was issued on March 10, 2004. The project architect certified completion of all known remaining architectural items in June, 2004.



The HOA filed a claim against the developers of the property on January, 21, 2009. A week later, the HOA amended its complaint to add Shaw, the general contractor. Shaw did not file its answer and third-party complaint until March 29, 2010, sending its notice of claim under the CDARA on March 30.



The subcontractors claimed that the six-year statute of limitations had ended twenty days prior. Shaw claimed that the statute of limitations ran until six years after the architect’s certification, or that the HOA’s suit had tolled all claims.



The trial court granted summary judgment to the subcontractors, determining that “substantial completion occurs ‘when an improvement to real property achieves a degree of completion at which the owner can conveniently utilize the improvement of the purpose it was intended.’”



The appeals court noted that “Shaw correctly points out that the CDARA does not define ‘substantial completion.’” The court argued that Shaw’s interpretation went against the history and intent of the measure. “Historically, a construction professional who received a complaint responded by ‘cross-nam[ing] or add[ing] everybody and anybody who had a part to play in the construction chain.’” The court concluded that the intent of the act was to prevent unnamed subcontractors from being tolled.



The court further rejected Shaw’s reliance on the date of the architect’s certification as the time of “substantial completion,” instead agreeing with the trial court that “the architect’s letter on which Shaw relies certified total completion.”



The appeals court upheld the trial court’s determination that the statute of limitation began to run no later than March 10, 2004 and that Shaw’s complaint of March 29, 2010 was therefore barred. The summary judgment was upheld.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Why’d You Have To Say That?

October 09, 2023 — Daniel Lund III - Lexology
A surety seeking collateral from indemnitors filed suit in federal court in Louisiana pursuant to a forum selection clause in the indemnity agreement between the parties. The indemnitors were being called upon to provide collateral as a result of defaults on two Louisiana Department of Transportation projects. Seeking to move the dispute to Louisiana state court from federal court, the indemnitors filed a forum non conveniens motion. Among the arguments of the indemnitors removing the case out of federal court was the doctrine of “direct-benefits” estoppel – a policy which “‘holds a non-signatory to a clause in a contract if it “knowingly exploits the agreement” containing the clause.’ In re Lloyd's Reg. N. Am., Inc., 780 F.3d 283, 291 (5th Cir. 2015) (quoting Bridas S.A.P.I.C. v. Gov't of Turkmenistan, 345 F.3d 347, 361-62 (5th Cir. 2003)).” Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

---

Evaluating Smart Home Technology: It’s About More Than the Bottom Line

May 03, 2021 — James W. McPhillips & Rachel Newell - Gravel2Gavel Construction & Real Estate Law Blog
Outfitting a commercial real estate space with smart technology can be a significant cost. While the long-term benefits and strategic improvements we’ve discussed previously can make that investment worthwhile, the evaluation period is critical to ensure an impactful ROI. Property developers, owners, and managers should undertake a rigorous evaluation process to ensure the technology procurement aligns with the project’s overall financial plan. And this is not just about getting the cost right. If the technology does not meet the needs of the space, then all the smart technology in the world will not prevent the project from being a sunk cost. Do the Research so You Know … The Technology. While the RFP is a key step of the procurement process, a more informal research phase should be undertaken first. Smart technology is a rapidly evolving field, and before reaching out to vendors, the business should ensure that it understands what is available—both in terms of the kinds of technology that can be implemented, and the various companies that offer solutions. Gathering this information early will yield results that align more closely with a particular building’s needs. Reprinted courtesy of James W. McPhillips, Pillsbury and Rachel Newell, Pillsbury Mr. McPhillips may be contacted at james.mcphillips@pillsburylaw.com Ms. Newell may be contacted at rachel.newell@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Daiwa House to Invest 150 Billion Yen in U.S. Rental Housing

March 07, 2014 — Kathleen Chu – Bloomberg
Daiwa House Industry Co. (1925), Japan’s biggest homebuilder by market value, plans to invest 150 billion yen ($1.48 billion) in U.S. rental housing, three times more than it had aimed to allocate to overseas investments, to boost revenue. Daiwa House will acquire and develop leasing properties in Texas and allocate the funds over the next three years, the Osaka-based company said in an e-mailed statement today. The homebuilder targets 50 billion yen of revenue in the U.S. by the year ending March 2019, it said. Japan’s shrinking population has prompted the country’s homebuilders such as Daiwa House to seek new revenue sources. Texas is the most that Daiwa House is investing overseas for rental housing and compares with the 50 billion yen the company had announced for investments abroad in its mid-term plan in November. Read the court decision
Read the full story...
Reprinted courtesy of Kathleen Chu, Bloomberg
Ms. Chu may be contacted at kchu2@bloomberg.net

---

Does Stricter Decertification Mean More “Leedigation?”

August 04, 2015 — Christopher G. Hill – Construction Law Musings
Recently, my friend and fellow construction attorney/consultant, Chris Cheatham (@chrischeatham) posted the news that USGBC will be more stringent on the de-certification front. This statement relates to the continued energy performance of LEED certified buildings and increases the likelihood that energy performance (as opposed to mere reporting) could lead to de-certification. I have discussed on several occasions the potential legal risks relating to green building. One of the big potential sources for such litigation (or “leedigation” as coined by Mr. Cheatham) is the possible de-certification of a previously certified building. With this latest statement by USGBC the specter of such de-certification seems even stronger. Couple this potential with the fact that anyone can challenge the certification of a building at any time and contractors, subcontractors and other construction professionals face potential liability for the performance of a building in ways well beyond their control. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---

Hunton’s Alice Weeks Selected to the Miami Dade Bar’s Circle of Excellence for Insurance Litigation

April 25, 2023 — Hunton Insurance Recovery Blog
Congratulations to Alice Weeks, an associate on Hunton Andrews Kurth’s insurance coverage team, for being selected to the Miami Dade Bar’s Circle of Excellence for Insurance Litigation. The Circle of Excellence award is awarded to peer-selected attorneys in their area of practice. Alice was selected from among many highly qualified nominees and was recognized at the Miami Dade Bar’s Judicial Reception. Alice is a past board member of the Miami Dade Bar YLS, as well as past-editor of the Miami Dade Bar’s newsletter, the Bulletin. Alice’s Circle of Excellence selection follows her recent selection to the Cystic Fibrosis Foundation’s 40 Under 40 Outstanding Young Professionals of South Florida and her receipt of the Miami Dade Bar’s 40 Under 40 Award. Read the court decision
Read the full story...
Reprinted courtesy of Hunton Andrews Kurth LLP

---