Seattle Washington Building Expert Directory

No Damage for Delay? No Problem: Exceptions to the Enforceability of No Damage for Delay Clauses

October 18, 2021 — Chris Broughton, Jones Walker LLP - ConsensusDocs
Introduction: Under a no-damage-for-delay clause, the owner is not liable for any monetary damages resulting from delays on the project. In lieu of monetary recovery, the contractor’s remaining remedy is a non-compensatory time extension. These clauses are common at the contractor-subcontractor interface as well. While no-damage-for-delay clauses are enforced in most jurisdictions, some states, either by statute or case law, have limited the enforceability of no-damage-for-delay clauses. Other states have also limited the enforceability of these clauses on state government contracts, and a select few have outlawed them on all projects regardless if they are publicly or privately owned. Additionally, for subcontractors on federal projects, the Miller Act may provide a way to avoid no-damage-for-delay and recover against the general contractor’s payment bond. This article provides an overview of no-damage-for-delay clauses and the exceptions to enforcement of these clauses. However, due to the consequences of a no-damage-for-delay clause, it is important to know the terms of your contract and the law that governs your project. Read the court decision
Read the full story...
Reprinted courtesy of Chris Broughton, Jones Walker LLP
Mr. Broughton may be contacted at cbroughton@joneswalker.com

Zinc in London Climbs for Second Day Before U.S. Housing Data

January 21, 2015 — Alex Davis – Bloomberg
Zinc rose for a second day and copper held gains before data showing increased housing construction in the U.S. and a stimulus decision by the European Central Bank. Zinc advanced as much as 0.8 percent. Housing starts in the U.S., the second-largest metals consumer, climbed 1.2 percent in December from the previous month, according to a Bloomberg survey, after falling 1.6 percent in November. The ECB will announce a 550 billion-euro ($636 billion) government-bond purchase program this week, according to 93 percent of respondents in a separate survey. Read the court decision
Read the full story...
Reprinted courtesy of Alex Davis, Bloomberg
Mr. Davis may be contacted at adavis150@bloomberg.net

Strategy for Enforcement of Dispute Resolution Rights

May 30, 2018 — Whitney Judson - Smith Currie
Arbitration and litigation each offer their own benefits and drawbacks to litigants looking to resolve a construction dispute. A careful analysis of these benefits and drawbacks may be helpful in determining whether to avoid or pursue either dispute resolution process. Arbitration is oftentimes regarded as the more economically feasible dispute resolution option and is therefore attractive to many construction dispute litigants. Although arbitration may prove to be less expensive than litigation in the long run, some litigants may prefer to file a case in court because the upfront filing fees in litigation are less expensive than the filing fees of arbitration. Litigants may also prefer the decision makers of one process for dispute resolution over another. Arbitrators in a construction dispute oftentimes have a background in the construction industry, whereas a judge or jury may not. Strategy may dictate whether the preferable decision maker should have experience within the construction industry or be free of any construction industry knowledge and possible biases. The finality of decisions may also be a reason to strategically choose one dispute resolution process over another. Arbitration decisions are overturned only under very narrow and specific circumstances. The losing party in litigation however, has a right to appeal decisions to a higher court and has more options for recourse when the findings of the court are not supported by the evidence or the law. Read the court decision
Read the full story...
Reprinted courtesy of Whitney Judson, Smith Currie
Ms. Judson may be contacted at wtjudson@smithcurrie.com

To Ease Housing Crunch, Theme Parks Are Becoming Homebuilders

January 29, 2024 — Patrick Sisson - Bloomberg
For visitors, Universal Studios Florida offers a chance to visit a fantastical land full of wizards, Minions and various characters from NBC Universal’s many film and television properties. But for the roughly 28,000 men and women who work at the 840-acre theme park and resort complex in Orlando, the troubles of the real world — like the rising cost of housing — are not far away. Central Florida has seen some of the nation’s fastest pandemic-era rent increases, thanks to a confluence of job growth, migration and housing underproduction that has put a strain on residents. The average tenant in the region saw their monthly rent jump by $600 between early 2020 and early 2023. According to the National Low Income Housing Coalition, the Orlando-Kissimmee-Sanford metro area has one of the worst affordable housing shortages in the US, with only 15 available units for every 100 extremely low-income renter households. The dire need for workforce housing is behind the entertainment conglomerate’s latest project in Central Florida: a 1,000-unit mixed-use development, set to open in 2026, that promises to give tenants who work in the service industry a short commute to the constellation of tourist attractions and hotels nearby. To launch the project, Universal donated 20 acres of land adjacent to the Orange County convention center. Called Catchlight Crossings and built in partnership with local developer Wendover Housing Partners, the project broke ground in November. Read the court decision
Read the full story...
Reprinted courtesy of Patrick Sisson, Bloomberg

Hotel Owner Makes Construction Defect Claim

January 28, 2013 — CDJ STAFF
A lawsuit has been filed over the construction of the GrandStay Hotel & Conference Center in Apple Valley Minnesota. Apple Valley GSRS, LLC, who invested in the hotel, has sued Cole Group Architects and Cornerstone Construction, alleging that the architects design was not to industry standards and that the builder used inferior materials and techniques. The lawsuit makes claim of "significant damage." The hotel hired an engineer who subsequently recommended that all the stucco and the roof should be be replaced. The stucco has shown signs of cracking and crumbling. The hotel states that the roof has problems with leaking. Cornerstone has denied the hotel's claims. They have also counter-sued their subcontractors. Read the court decision
Read the full story...
Reprinted courtesy of

Party Loses Additional Insured Argument by Improper Pleading

September 20, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The Archdiocese failed to plead breach of contract against the County for failure to name the Archdiocese as an additional insured under the liability policy. Pachella v. Archdiocese of Philadelphia, 2017 Pa. Commw. Unpub. LEXIS 595 (Pa. Commw. Ct. Aug. 14, 2017). Richard and Pachella filed a complaint against the Archdiocese, alleging that Mrs. Pachella was injured when she tripped and fell on the sidewalk outside of St. Patrick's Parish. At the time, the County was leasing St. Patrick's premises for use as an election polling place. The Archdiocese filed a third party complaint alleging negligence and breach of contract claims under a Lease Agreement between St. Patrick's and the County. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Contractor to Repair Defective Stucco, Plans on Suing Subcontractor

February 21, 2013 — CDJ STAFF
The contractor for the Manatee County Judicial Center will be replacing the defective stucco on the building, but they have stated that they intend to go after the subcontractor who initially installed the defective stucco. The contractor, Balfour Beatty LLC, has said they will pay for the repairs, but Steve Holt, an executive of the firm said that “we have initiated a lawsuit against the subcontractor, who we believe was substantially or completely responsible to recover those funds.” Mr. Holt named Commercial Plastering as the subcontractor responsible. Read the court decision
Read the full story...
Reprinted courtesy of

AECOM Out as General Contractor on $1.6B MSG Sphere in Las Vegas

January 18, 2021 — Doug Puppel - Engineering News-Record
Developers of the $1.66-billion MSG Sphere in Las Vegas have removed AECOM as general contractor on the project and will bring construction management in-house for the 875,000-sq-ft entertainment venue, according to a Madison Square Garden Entertainment Corp. statement released Dec. 17. Reprinted courtesy of Doug Puppel, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES