Fairfield Connecticut Building Expert Directory

General Partner Is Not Additional Insured For Construction Defect Claim

August 26, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The court determined that the project owner's general partner was not an additional insured entitled to a defense and indemnity against claims for construction defects. St. Paul Fire & Marine Ins. Co. v,. Cypress Fairway Condo. Ass'n, 2015 U.S. Dist. LEXIS 94012 (M.D. Fla. July 20, 2015). Construction of the Cypress Fairway Condominium project took place in 1999 and 2000. Cypress Fairway Ltd. ("Cypress") was the owner and Vineland Partners , LLC ("Vineland") was its general partner. The general contractor was Winter Park Construction Company ("WPC"). Water intrusion and property damage occurred, but it was unclear when or whether the damage was known. Cypress' expert indicated that the damage began shortly after the end of construction. In 2004, the complex was sold to Cypress Madison Ownership Company. In 2010, the Cypress Fairway Condominium Association sued Cypress and Vineland. Count V of the underlying complaint asserted there were construction defects that Cypress and Vineland were responsible for when they owned and managed the project. Count VI alleged that Cypress and Vineland negligently supplied information which the Association relied on for the purchase of the condominiums. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Employees Versus Independent Contractors

February 23, 2017 — Chadd Reynolds – Autry, Hanrahan, Hall & Cook, LLP
Are the workers you employ on the job site considered employees or independent contractors? This is an important distinction that contractors and subcontractors must understand for many purposes, including federal taxes. The classification of your workers can affect their federal income, social security, and Medicare taxes, and the type of benefits they can receive. When determining whether workers should be classified as employees or independent contractors, courts generally look at three key factors: behavioral control, financial control, and the relationship of the parties. Behavior Control Behavior control concerns the business’s right to direct or control how the worker does its work. A worker is likely to be considered an employee when the business maintains behavior control. Such control can be exercised by giving instructions. This would include instructions on how, when, or where to do the work, what tools or equipment to use, who to hire to help with the work, or where to purchase the supplies to be used. Behavioral control can also occur through training. If the business provides training to tell the worker to do the work in a certain manner then the worker is more likely to be an employee. Read the court decision
Read the full story...
Reprinted courtesy of Chadd Reynolds, Autry, Hanrahan, Hall & Cook, LLP
Mr. Reynolds may be contacted at reynolds@ahclaw.com

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Two Texas Cities Top San Francisco for Property Investors

October 22, 2014 — Brian Louis – Bloomberg
Houston and Austin are the most attractive U.S. markets for buying and developing real estate, topping San Francisco, as growth potential in the Texas cities draws investors from popular coastal areas, a survey shows. The Northern California city ranked third, down from No. 1 last year, according to a report released today by PricewaterhouseCoopers LLP and the Urban Land Institute. Denver and Dallas-Fort Worth rounded out the five markets offering the best prospects for investors in 2015, the poll of more than 1,400 people in the real estate business shows. Manhattan slipped out of the top 10 to rank 14th. Some non-coastal markets are drawing more property investors partly because they offer higher yields than places such as San Francisco and Manhattan, which led the recovery from the financial crisis. The smaller cities also are benefiting from employment growth and increasing numbers of people moving into urban centers, according to Mitch Roschelle, a partner and U.S. real estate advisory practice leader at PricewaterhouseCoopers in New York. Read the court decision
Read the full story...
Reprinted courtesy of Brian Louis, Bloomberg
Mr. Louis may be contacted at blouis1@bloomberg.net

Unwrapped Pipes Lead to Flooding and Construction Defect Lawsuit

July 31, 2013 — CDJ STAFF
Homeowners in New Jersey have filed a lawsuit over unwrapped pipes in exterior walls. During the cold winter weather, the pipes froze, leading one homeowner to experience a “massive leak.” A plumber was able to end the flooding by shutting off water to the house. He then told the homeowner, Robert Long, that he had been doing the same at other homes in the community. The Longs are now party to a class-action lawsuit which seeks that the homebuilder, Ryan Homes, tell those who have purchased homes about the defect. Further, the suit seeks compensation for those whose home have been damaged, and repairs to assure that additional homes do not have their pipes burst. Stephen P. DeNittis, who is representing the Longs, said that “the code violation alleged in this case is particularly troublesome because it involves unprotected pipes hidden inside an exterior wall.” Read the court decision
Read the full story...
Reprinted courtesy of

Zoning Hearing Notice Addressed by Georgia Appeals Court

April 20, 2017 — David R. Cook Jr. - Autry, Hanrahan, Hall & Cook, LLP
The Georgia Court of Appeals recently addressed the requisite notice of zoning proceedings that ultimately requested in a zoning decision. The key question was whether, after a properly noticed planning meeting, additional notice was required before the board’s formal vote that occurred three months later. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Your Bad Faith Jury Instruction Against an Insurer is Important

March 09, 2020 — David Adelstein - Florida Construction Legal Updates
A statutory bad faith claim against an insurer is derived from Florida Statute s. 624.155. A bad faith claim against a first party insurer, such as a property insurer, must be statutory. Check out the hyperlink of the statute, but a party must first file a Civil Remedy Notice identifying the statutory violations to preserve the statutory bad faith claim giving the insurer an opportunity to cure. In a noteworthy case, Cooper v. Federated National Insurance Company, 44 Fla. L. Weekly D2961a (Fla. 5th DCA 2019), the Fifth District Court of Appeal dealt with the jury instruction for an insured’s statutory bad faith claim against their property insurer. The insured filed a bad faith claim predicated on the property insurer violating the provisions of Florida Statute s. 626.9541(1)(i)3, which involves unfair claim settlement practices. The insured had a jury trial and submitted a proposed jury instruction regarding bad faith that tracked the very essence of their bad faith claim and was modeled after s. 626.9541(1)(i)(3). The trial court, however, denied this jury instruction, instead adopting a standard jury instruction for bad faith. The jury returned a verdict in favor of the property insurer and the insured appealed arguing it was reversible error for the trial court NOT to present to the jury their bad faith jury instruction. The Fifth District agreed and ordered a new trial finding that the trial court’s failure to present the jury instruction amounted to a miscarriage of justice. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Denial of Coverage for Bulge in Wall Upheld

November 26, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The insurer properly denied coverage for a bulge in a warehouse wall that the insured claimed was caused by Hurricane Ike. Russell v. Scottsdale Ins. Co., 2014 U.S. Dist. LEXIS 143882 (S.D. Tex. Sept. 30, 2014). Hurricane Ike displaced metal roof coverings on the insured's warehouse, causing interior water damage to several rooms. Scottsdale eventually paid $84,820.36 for the loss of the roof, less the deductible. The parties disagreed on whether a horizontal bulge on the north wall of the warehouse was also caused by the hurricane. The bulging portion of the wall was not cracked, but cracks were seen around the corners and windows. The insured admitted to an engineer retained by Scottsdale that the cracks in the exterior walls had been filled with caulking on several occasions prior to Hurricane Ike. Scottsdale denied coverage for the damage to the north wall under exclusions for soil sinking, rising, or shifting and for damage from faulty, inadequate or defective design, construction, and repair.The insured later sent a demand for $800,000 for the damage to the wall. A suit was eventually filed by the insured. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES