Fairfield Connecticut Building Expert Directory

Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can’t Look Back Again)

October 05, 2020 — Christopher G. Hill - Construction Law Musings
I’ve discussed the continuing litigation between White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc. previously here at Construction Law Musings because the case was another reminder that your construction contract terms matter and will be interpreted strictly here in the Commonwealth of Virginia. The prior opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision. In the latest opinion from the Court (PDF) the Court looked at when and how any liquidated damages would be calculated. In its June 22, 2020 opinion, the Court put the issue as follows:

White Oak’s motion for partial summary judgment presents a narrow issue: whether courts may consider the damages actually sustained by a party as a result of a contract breach when deciding if liquidated damages required by a contract “grossly exceed” a party’s actual damages.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Charges in Kansas Water Park Death

March 28, 2018 — David Suggs - CDJ STAFF
Caleb Schwab, a 10-year old boy was killed by decapitation on a water slide at a Kansas City water park, Schlitterbahn in 2016. Thirteen other people had suffered injuries on the ride prior to Caleb’s death ranging in severity from broken toes to concussions. Schlitterbahn employees have since claimed that park officials covered up past occurrences of water slide injuries. Three people have been indicted in this case according to a CNN report by Marlena Baldacci, Sheena Jones and Hollie Silverman. Jeffrey Henry, the co-owner of the Schlitterbahn water park, Tyler Austin Miles, the park’s former director of operations and John Schooley. Charges include second-degree murder, involuntary manslaughter, aggravated battery and aggravated child endangerment. Caleb suffered a fatal injury when the raft that he and the two women who were riding with him became airborne and contacted the netting attached overhead. Investigators have found maintenance issues and ride design flaws that violate safety standards leading to lack of prevention of rafts becoming airborne during the ride. Caleb’s family will receive nearly $20 million in the settlement. Caleb’s father Scott, released a statement about placing full trust in the Attorney General Derek Schmidt who is presiding over the investigation and indictments. Read the court decision
Read the full story...
Reprinted courtesy of

Wilke Fleury Attorneys Featured in 2021 Best Lawyers in America and Best Lawyers: Ones To Watch!

September 28, 2020 — Wilke Fleury LLP
Wilke Fleury congratulates attorneys David Frenznick, Adriana Cervantes and Dan Egan on their inclusion in the 2021 Edition of Best Lawyers in America! Since it was first published in 1983, Best Lawyers® has become universally regarded as the definitive guide to legal excellence. Best Lawyers lists are compiled based on an exhaustive peer-review evaluation. Almost 108,000 industry leading lawyers are eligible to vote (from around the world), and they have received over 13 million evaluations on the legal abilities of other lawyers based on their specific practice areas around the world. For the 2021 Edition of The Best Lawyers in America©, 9.4 million votes were analyzed. Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury

Alexus Williams Receives Missouri Lawyers Media 2021 Women’s Justice Pro Bono Award

November 29, 2021 — Alexus Williams - Lewis Brisbois
St. Louis, Mo. (October 19, 2021) - St. Louis Associate Alexus Williams has received the Missouri Lawyers Media 2021 Women’s Justice Pro Bono Award, which honors women attorneys who have contributed significant effort and time to pro bono work. In connection with this honor, Ms. Williams was interviewed by Missouri Lawyers Media for its 2021 Women’s Justice Awards (WJA) supplement. In the article featuring Ms. Williams, the publication explained that she has “developed a reputation for helping others” and “has continually found ways to level disparities to make the system work for everyone.” For example, as a member of the Bar Association of Metropolitan St. Louis Executive Committee’s Young Lawyers Division, Ms. Williams co-chaired a committee on racial equity during the civil unrest of 2020. Ms. Williams told Missouri Lawyers Media, “When I was looking at grad programs, law school was one that seemed like it kind of aligned with what I was passionate about, which was helping people, counseling people, being able to be of assistance in different kinds of situations.” She further noted, “Everyone has to play their part but also everyone needs the opportunity to play their part.” Read the court decision
Read the full story...
Reprinted courtesy of Alexus Williams, Lewis Brisbois
Ms. Williams may be contacted at Alexus.Williams@lewisbrisbois.com

Citigroup Reaches $1.13 Billion Pact Over Mortgage Bonds

April 09, 2014 — Dakin Campbell – Bloomberg
Citigroup Inc. (C) agreed to pay $1.13 billion to settle claims from mortgage-bond investors as it seeks to curb liabilities tied to the financial crisis. It took a $100 million first-quarter charge. The 68 securitization trusts covered by the settlement issued a combined $59.4 billion in mortgage-backed securities from 2005 to 2008, the New York-based bank said yesterday in a statement. The agreement covers 18 investors represented by Gibbs & Bruns LLP and trustees have until June 30 to accept the deal, the law firm said in a separate statement. The accord must be approved by the Federal Housing Finance Agency. Citigroup, the third-biggest U.S. bank, is resolving a portion of liabilities tied to mortgages it packaged and sold to investors in the run-up to the 2008 crisis. JPMorgan Chase & Co. (JPM) and Bank of America Corp. (BAC), the two largest U.S. lenders, previously agreed to multibillion-dollar settlements with Gibbs & Bruns clients. Read the court decision
Read the full story...
Reprinted courtesy of Dakin Campbell, Bloomberg
Mr. Campbell may be contacted at dcampbell27@bloomberg.net

Additional Insured Not Entitled to Coverage for Post-Completion Defects

December 21, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The general contractor, an additional insured on the subcontractor's policy, was not entitled to coverage for construction defect claims that arose after completion of the project. Weitz Co. v. Acuity, 2016 U.S. Dist. LEXIS 150433 (S.D. Ohio Oct. 31, 2016). Weitz was the general contractor hired by Twin Lakes for construction of a residential community. One of the subcontractors, Miter Masonry, was insured by Acuity under a CGL policy. Work on the project began in 2002 and was substantially completed in 2005. In 2011, Twin Lakes notified Weitz that there were moisture infiltration issues at the project that may be related to work during the project. Twin Lakes filed a Demand for Arbitration against Weitz on November 30, 2012. Twin Lakes alleged that the defects included the building wrap, windows, doors, wood trim, aluminum wrap, vinyl siding, flashing and brick veneer not being installed in accordance with contract documents and/or industry standards. The arbitration panel awarded damages to Twin Lakes in the amount of $2,775,771.86. The panel found that Weitz breached sections of the contract which caused moisture intrusion and damage to all the units. The panel ultimately held that Weitz could recover from the subcontractors 100% of the $2,775,771.86 awarded. Acuity's insured, Miter Masonry, was determined to be 4% at fault for the damages. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Contractor Sues License Board

June 30, 2011 — CDJ STAFF

Judge Kendall J. Newman of the US District Court handed down a decision on June 24 on the case of Kent v California Department of Consumer Affairs. Mr. Kent, appearing as his own counsel, had brought the suit against the California Department of Consumer Affairs and the Contractors State Licensing Board after he was arrested in a sting operation and, as the plaintiff put it, “was absurdly arrested and uncooperatively detained for a time longer than necessary or allowed by law under the false pretense of contracting with out a license.” Mr. Kent’s alleged that Rick Lopez, one of the defendants, formed him to read allow from the California Business and Professions Code. He said he was later handcuffed and placed in an uncomfortable chair, “enduring physical pain and emotional agony.”

Although Kent was given a Notice to Appear, he alleged that a further defendant, Stuart Rind, “closed the plaintiff’s case marked citation A7773 without giving written notice to anyone.” As a result, the Placer County District Attorney’s Office had no record of his Notice to Appear.

Kent alleged that subsequently his firm was essentially shut down for two years and that he was prevented from “legally contracting or selling services for any other contractor or qualifying for any other licensed capacity governed by the CSLB.” After this, the CSLB suspended the license for his firm, DSI Construction. He was assessed a $1,500 fine, after which he claims he sent a letter to the CSLB demanding money damages. The judge noted that the letter was not included in the plaintiff’s Ninth Amended Complaint.

Judge Kendall recommended that the plaintiff’s Complaints be dismissed, although he did allow that sixth, and perhaps the eighth and ninth, could be amended with a tenth amended complaint.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

Florida Condo Collapse Shows Town’s Rich, Middle-Class Divide

August 04, 2021 — The Associated Press (Terry Spencer & Freida Frisaro) - Bloomberg
The condo tower collapse in Surfside could exacerbate the division that already exists between the tiny Florida town’s new luxury buildings built for the global elite and those constructed decades ago for the middle class. It is already creating headaches for some small businesses. The town has seen the construction of numerous new condos in recent years, where large oceanfront units exceeding 3,000 square feet (280 square meters) with modern amenities can fetch $10 million and up. Meanwhile, small units of 800 square feet (75 square meters) in neighboring condo buildings constructed decades ago can be had for $400,000. Ana Bozovic, a South Florida real estate broker, said the June 24 collapse of the 40-year-old, middle-class Champlain Towers South will exacerbate this division. At least 46 people were killed and more than 90 remain missing. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES