FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Buy Clean California Act Takes Effect on July 1, 2022

July 25, 2022 — Garret Murai - California Construction Law Blog
The Buy Clean California Act (BCCA) – Public Contract Code section 3500 et seq. – requires state agencies to consider the carbon content of the following products when awarding contracts:

• Structural steel;
• Concrete reinforcing steel;
• Flat glass; and
• Mineral wool board insulation.

It is anticipated that additional products may be added through future legislation. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Florida Representative Wants to Change Statute of Repose

December 10, 2015 — Beverley BevenFlorez-CDJ STAFF
Currently in Florida, the ten year clock for construction defect claims typically starts ticking after the final payment is made by the owner. However, WFSU reported, Representative Keith Perry wants to change it so that the completion of the construction triggers the statute of repose. This change “could favor the construction industry, by shifting the power to start the clock from home owners to builders,” WFSU claimed. Representative Dwight Dudley worries about “what would happen if a contractor felt she was finished but the property owner didn’t agree.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Construction Law Firm Opens in D.C.

January 13, 2014 — CDJ STAFF
Stephen Palley, a lawyer in the Washington, D.C. area who was recognized in 2013 as a “DC Super Lawyer” for his work in construction litigation, has open his own firm, Palley Law, PLLC. Mr. Palley said that his practice “remains focused on addressing insurance issues faced by construction industry clients.” He also noted that “few firms focus specifically on construction insurance, so a significant part of my practice involves helping other lawyers with individual projects or disputes for their clients.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Congratulations to BWB&O’s Los Angeles Office on Another Successful MSJ!

July 11, 2022 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is proud to announce Partner Daniel Crespo and Associate Stefon Jackson successfully argued and won a Motion for Summary Judgment (“MSJ”) for our client, a property owner of an apartment complex. Plaintiff was involved in a physical altercation with one of the tenants at an apartment complex owned by our client. Plaintiff alleged that our client had notice of a propensity for violence claiming that there were prior instances of contentious interactions between this particular tenant and Plaintiff. As a result, Plaintiff alleged that our client had a duty to prevent further interactions between Plaintiff and the tenant presuming that an act of physical violence was reasonably foreseeable. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

---

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Eleventh Circuit Finds Professional Services Exclusion Applies to Construction Management Activities

April 29, 2024 — Ashley Kellgren - Traub Lieberman Insurance Law Blog
In Colony Ins. Co. v. Coastal Constr. Mgmt., LLC, 2024 U.S. App. LEXIS 4809 (11th Cir. Feb. 29, 2024), the Eleventh Circuit found the insurer had no duty to defend or indemnify its insured based on a professional services exclusion. In that case, the underlying claims arose out of the construction of a four-story apartment complex. The owner and project developer contracted with the insured to provide construction management services as a construction manager and construction consultant. Several years after the project was completed, the owner filed suit against the architect, general contractor, and the insured alleging numerous defects and deficiencies with respect to the project. The owner asserted claims against the insured for breach of contract and negligence, alleging various failures by the insured in connection with its supervision of construction and failures to properly and timely complete the project, and correct inadequate, defective, and noncomplying work. Colony issued two commercial general liability policies to the insured, both of which contained a professional services exclusion. Although the policy did not expressly define “professional services,” the professional services exclusion provided a non-exhaustive list of examples, including: (2) preparing, approving, or failing to prepare or approve maps, drawings, opinions, reports, surveys, change orders, designs or specifications; Read the court decision
Read the full story...
Reprinted courtesy of Ashley Kellgren, Traub Lieberman
Ms. Kellgren may be contacted at akellgren@tlsslaw.com

---

Ohio Condo Development Case Filed in 2011 is Scheduled for Trial

April 09, 2014 — Beverley BevenFlorez-CDJ STAFF
In a recent hearing regarding the Cleveland, Ohio case Stonebridge Towers Homeowners v K&D Group, Judge John O’Donnell scheduled a trial for May 28th. Lead attorney for the homeowners stated that they would settle for “ten million and change,” according to The Plain Dealer. However, an attorney for K&D Group retorted that “the damaged condos could be fixed for much less money.” “The lawsuit claims negligent design, poor construction and multiple defects resulted from fraud and bribe-paying by the developers,” reported Plain Dealer. Read the court decision
Read the full story...
Reprinted courtesy of

---

Hunton Insurance Coverage Partner Lawrence J. Bracken II Awarded Emory Public Interest Committee’s 2024 Lifetime Commitment to Public Service Award

February 26, 2024 — Hunton Insurance Recovery Blog
On February 7, the Emory Public Interest Committee (EPIC) honored insurance coverage partner Lawrence (Larry) J. Bracken II with their 2024 Lifetime Commitment to Public Service Award at the annual EPIC Inspiration Awards. As one of the Emory University School of Law’s signature events, the Inspiration Awards celebrate members of the community who do extraordinary work in the public interest and provide funding for public interest summer jobs. Larry has more than 37 years of experience litigating insurance coverage, class action and commercial cases in federal and state courts throughout the United States. He represents policyholders in insurance coverage litigation and arbitration, and is a Fellow of the American College of Coverage Lawyers. Larry also has litigated class actions and other complex commercial disputes for more than three decades. Pro bono representation of clients in habeas corpus, prisoner rights, and landlord-tenant litigation is an important part of his practice. Larry currently serves as the President of the Board of Directors of the Atlanta Volunteer Lawyers Foundation. Read the court decision
Read the full story...
Reprinted courtesy of Hunton Andrews Kurth LLP

---