Cambridge Massachusetts Building Expert Directory

Executive Insights 2024: Leaders in Construction Law

August 05, 2024 — Construction Executive
The key risks that should always be taken into account when a contract is signed are risks associated with uncompensated delays and cost increases. Provisions relating to the scope of work deserve significant attention to help minimize these risks. Defining the scope of work is often put on the backburner while parties focus on negotiating the rest of the terms and conditions of the contract. And when these scopes are inserted, they are often not closely reviewed by attorneys who tend to defer to project personnel on scope. These situations can lead to costly disputes. Instead, make sure: (1) the correct plans and specifications have been referenced in the contract; (2) an attorney or his/her business counterpart is familiar with relevant specifications; (3) the exhibit containing the assumptions and clarifications is clearly written, has been coordinated with language in the body of the contract and can be clearly understood by attorneys and business people beyond the preconstruction personnel who drafted them; and (4) the contract addresses the order of precedence in the event of a conflict between or among contract provisions (including exhibits). With regard to specifications referenced above, an attorney review is advised because many specification sections, including submittal sections, change order sections, payment provisions and construction progress documentation sections, regularly vary from the negotiated sections of the actual contract. Contractors also unwittingly accept design risk through performance specifications, and the accompanying obligations and risks are underestimated by those tasked with the initial review of those documents. In sum, a clear scope is as important as clear terms and conditions. Reprinted courtesy of Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Guessing as to your Construction Damages is Not the Best Approach

November 18, 2019 — David Adelstein - Florida Construction Legal Updates
Arbitrarily guessing as to your construction damages is NOT the best approach. Sure, experts can be costly. No doubt about it. Having an expert versus guessing as to your construction damages caused by another party’s breach of contract is a no brainer. Engage an expert or, at a minimum, be in a position to competently testify as to your damages caused by another party’s breach of contract. Otherwise, the guessing is not going to get you very far as a concrete subcontractor found out in Patrick Concrete Constructors, Inc. v. Layne Christensen Co., 2018 WL 6528485 (W.D. New York 2018) where the subcontractor could not competently support its delay-related damages or change orders and, equally important, could not support that the damages were proximately caused by the general contractor’s breach of the subcontract. In this case, the concrete subcontractor entered into a subcontract to perform concrete work for a public project. The project was delayed and the general contractor was required to pay liquidated damages to the owner. Not surprisingly, the subcontractor disputed liability for delays and sued the general contractor for all of its delay-related damages “in the form of labor and materials escalation, loss of productivity, procurement and impact costs, field and home office overhead, idle equipment, inability to take on other work, lost profits, and interest.” Patrick Concrete Constructors, 2018 WL at *1. The general contractor moved for summary judgment as to the plaintiff’s delay-related damages – the subcontractor’s damages were nothing but guesses and the subcontractor could not prove the general contractor was the cause of the subcontractor’s damages. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Get Construction Defects in Writing

December 11, 2013 — CDJ STAFF
Sometimes, even if a developer is willing to make a repair, sometimes the repair doesn’t get to the actual problem, according to Nicholas D. Cowie of Cowie & Mott, writing on his blog. He notes that “getting it ‘right’ the first time is important and written documentation is key.” He gives the example of “when a developer agrees to informally repair a window or roof leak, the ‘repair,’ as far as the developer is concerned, may consist merely of sending out a worker with a caulk gun to seal gaps that should have been protected with a solid flashing material during the original installation.” As a better course, he says that homeowner associations should “request a written description of the proposed repair” in order that it can be evaluated. This also allows follow-up to determine if the agreed-upon repair was done properly. And, although some homeowners associations would rather not have the original subcontractor repair their own work, here warranties often come into play. Read the court decision
Read the full story...
Reprinted courtesy of

When Subcontractors Sue Only the Surety on Payment Bond and Tips for General Contractors

August 13, 2019 — Ira M. Schulman & Emily D. Anderson - ConsensusDocs
Payment bonds have been a staple of public construction projects since 1874, when the U.S. Congress first passed the Heard Act, which required that contractors obtain payment bonds for public projects to ensure that subcontractors and material suppliers have a way to recover their damages if an upstream contractor fails to pay for work performed and materials furnished on the project. The 1874 Heard Act has since been replaced by the 1935 Miller Act, and the concept has been expanded to construction projects funded by the states through state statutes known as “Little Miller Acts.” But the structure remains the same: On most public projects where the project’s cost exceeds $100,000, the prime contractor (the bond principal) is required to obtain a payment bond from a surety equal to the contract price to guarantee to subcontractors and material suppliers (the bond obligees) that the surety will pay for labor and materials under certain statutory or contractual conditions should the contractor fail to make payment. A surety is jointly and severally liable with the contractor to the subcontractor, which means that the subcontractor may seek recovery against either the contractor or the surety or both, and the contractor and surety will be liable for the damages together. Put another way, in most states and in federal court, an unpaid subcontractor has the right to sue only the surety on the payment bond without joining the contractor because a contract of suretyship is a direct liability of the surety to the subcontractor.1 When the contractor fails to perform, the surety becomes directly responsible at once — it is unnecessary for the subcontractor to establish that the contractor failed to carry out its contract before the obligation of the surety becomes absolute. Reprinted courtesy of Ira M. Schulman, Pepper Hamilton LLP and Emily D. Anderson, Pepper Hamilton LLP Mr. Schulman may be contacted at schulmani@pepperlaw.com Ms. Anderson may be contacted at andersone@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Team Temporarily Stabilizes Delaware River Bridge Crack

February 02, 2017 — Justin Rice - Engineering News-Record
The team temporarily stabilizing the Delaware River Bridge and planning its permanent repair also are trying to find a precedent for the bridge’s uncommon fracture. Connecting the Pennsylvania and New Jersey turnpikes, the 61-year-old symmetrical truss bridge was shut down indefinitely on Jan. 20, when a complete fracture in a steel truss was discovered below the bridge deck. Read the court decision
Read the full story...
Reprinted courtesy of Justin Rice, ENR
Mr. Rice may be contacted at ricej@enr.com

Repair of Fractured Girders Complete at Shuttered Salesforce Transit Center

July 22, 2019 — Nadine M. Post - Engineering News-Record
The repair of two fractured girders spanning Fremont Street and the reinforcement of twin girders spanning First Street are complete at the beleaguered Salesforce Transit Center in San Francisco. Reprinted courtesy of Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

BHA has a Nice Swing: Firm Supports CDCCF Charity at 2014 WCC Seminar

April 29, 2014 — Beverley BevenFlorez-CDJ STAFF
Stop by the Bert L. Howe & Associates (BHA) booth at the 2014 West Coast Casualty Construction Defect Seminar at the Disneyland Hotel on May 15th and 16th, and Sink A Putt For Charity! This year, seminar attendees and would-be duffers who try their hand at the golf putting game at the Bert L. Howe & Associates booth will not only have the chance to win a free gift card, they’ll also have the opportunity to help raise funds for a very important cause, the Construction Defect Community Charitable Foundation (CDCCF). Throughout this year’s seminar, with every hole-in-one made at their booth, BHA will make a $25.00 cash donation in the golfer’s name to the CDCCF. Bert L. Howe & Associates strongly supports the goals and principles of the CDCCF, and is honored to assist the foundation in fulfilling its mandate of assisting those in the construction defect community who are in need. Read how the CDCCF assists the construction defect community... Read the court decision
Read the full story...
Reprinted courtesy of

Climate-Proofing Your Home: Upgrades to Weather a Drought

January 03, 2022 — Todd Woody - Bloomberg
Climate-driven drought is making the once unthinkable foreseeable. Amid water shortages, your faucets could run dry, as has been a possibility in Marin County, California. Violate mandatory water restrictions and you might face steep fines or even a cutoff of service. With the western United States in the grip of an extreme drought, rivers and reservoirs are at record lows and some water utility districts in California have asked residents to curtail consumption by as much as 40%. A 2019 study found regions across the nation could face water shortages in the coming decades in part due to climate change. That puts a premium on making homes more resilient to drought by maximizing efficiency and minimizing waste through technologies that monitor consumption and recycle and capture water that would otherwise be lost. Read the court decision
Read the full story...
Reprinted courtesy of Todd Woody, Bloomberg

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES