Fairfield Connecticut Building Expert Directory

Coverage for Faulty Workmanship Found In South Dakota

October 11, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The South Dakota Supreme Court found coverage in favor of the general contractor who was sued for alleged faulty workmanship. Owners Ins. Co. v. Tibke Constr., Inc., 2017 S.D. LEXIS 106 (S.D. Aug. 23, 2017). The homeowners hired Tibke Construction Inc. as general contractor to build a new house. Tibke hired Jerry's Excavating Inc. as a subcontractor to prepare the soil and perform excavation work. After the project was completed, the homeowners sued Tibke and Jerry's Excavating for negligent construction and breach of contract. The homeowners alleged that Jerry's Excavating failed to conduct soil-compaction testing before construction. They alleged that the home was built upon highly expansive soils, resulting in damage to the home by "excessive settlement, cracking, structural unsoundness and other damages." The complaint further alleged that damages existed only on portions of the home not worked on by Jerry's Excavating. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Broker for Homeowners Policy Has No Duty to Advise Insureds on Excess Flood Coverage

November 02, 2017 — Tred R. Eyerly - Insurance Law Hawaii
A broker who assisted the insureds in procuring a homeowners policy had no duty to advise the insureds to secure additional flood coverage. Ring v. Meeker Sharkey Assocs., LLC, 2017 N.J. Super. Unpub. LEXIS 3458 (N.J. Super Ct. App. Div. Sept.26, 2017). The insureds owned two beachfront properties that were located in a designated flood zone. They secured homeowners and flood insurance through Meeker's predecessor. Subsequently, Meeker became the insureds' homeowners insurance broker while Willis, N.A. was their flood insurance broker. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

The Secret to an OSHA Inspection

December 02, 2015 — Craig Martin – Construction Contractor Advisor
Wouldn’t it be nice to know ahead of time what an OSHA inspector will be looking for when he comes to your work site? Well, I know the secret. And, it’s not really a secret. Just look at OSHA’s top ten citation standards and it becomes quite clear. In 2015, OSHA’s top ten most frequently cited violations are:

1. Fall protection (C) 2. Hazard communication 3. Scaffolding (C)

Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Owners Should Serve Request for Sworn Statement of Account on Lienor

August 10, 2017 — David Adelstein - Florida Construction Legal Updates
When an owner receives a construction lien, an owner should serve the lienor with a Request for Sworn Statement of Account. The Request for Sworn Statement is authorized by Florida Statute s. 713.16(2) and should be in the following form: REQUEST FOR SWORN STATEMENT OF ACCOUNT WARNING: YOUR FAILURE TO FURNISH THE REQUESTED STATEMENT, SIGNED UNDER OATH, WITHIN 30 DAYS OR THE FURNISHING OF A FALSE STATEMENT WILL RESULT IN THE LOSS OF YOUR LIEN. To: (Lienor’s name and address) The undersigned hereby demands a written statement under oath of his or her account showing the nature of the labor or services performed and to be performed, if any, the materials furnished, the materials to be furnished, if known, the amount paid on account to date, the amount due, and the amount to become due, if known, as of the date of the statement for the improvement of real property identified as (property description) . (name of contractor) (name of the lienor’s customer, as set forth in the lienor’s Notice to Owner, if such notice has been served) (signature and address of owner) (date of request for sworn statement of account) From both an owner and lienor’s perspective, the bolded, capitalized language is key. It states that if the lienor fails to respond under oath within 30 days, it will LOSE its lien. That is a very punitive measure for a lienor’s failure to respond, meaning a lienor should absolutely respond, no questions asked. Plus, a lienor’s response to a Request for Sworn Statement of Account is not a burdensome ordeal. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

Run Spot...Run!

November 18, 2024 — Daniel Lund III - Lexology
"The 'classic' definition of spot zoning is 'the process of singling out a small parcel of land for a use classification totally different from that of the surrounding area for the benefit of the owner of such property and to the detriment of other owners.’ Anderson’s American Law of Zoning, 4th Edition, § 5.12 (1995)” (from plannersweb.com). A wireless carrier rebuffed in Jennings, Louisiana, on an application to rezone residential property to site a monopole cell tower sought relief from the federal court for the Western District of Louisiana. The city lacked any wireless tower provisions in its ordinances, and the carrier asserted that existing “commercial property within the appropriate range” was unavailable. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Former Trump Atlantic City Casino Set for February Implosion

December 29, 2020 — Stephanie Loder - Engineering News-Record
The 39-story main tower of the former Trump Plaza hotel-casino on the Atlantic City, N.J., boardwalk, sold to investor Carl Icahn in 2016, will be imploded in February by a Philadelphia general contractor already in the process of dismantling the former showplace of President Donald Trump's real estate holdings. Reprinted courtesy of Stephanie Loder, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

U.K. Puts Tax on Developers to Fund Safer Apartment Blocks

March 08, 2021 — Emily Ashton & Olivia Konotey-Ahulu - Bloomberg
The U.K. announced an extra 3.5 billion pounds ($4.8 billion) toward the cost of stripping dangerous cladding from apartment blocks in England, with a new tax on developers from next year to help cover the costs. Housing Secretary Robert Jenrick said the new cash will add to a previously announced 1.6 billion-pound “safety fund” to remove the material, which was blamed for the deaths of 72 people in a catastrophic fire at London’s Grenfell Tower in 2017. A new tax will be introduced for U.K. residential developers in 2022 to raise at least 2 billion pounds over the next decade to ensure homebuilders “make a fair contribution” to solving the problem, Jenrick told the House of Commons on Wednesday. Reprinted courtesy of Emily Ashton, Bloomberg and Olivia Konotey-Ahulu, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES