Cambridge Massachusetts Building Expert Directory

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

ICE Said to Seek Mortgage Role Through Talks With Data Service

August 06, 2014 — Matthew Leising, Jesse Hamilton and Jody Shenn – Bloomberg
Intercontinental Exchange Inc. (ICE), best known for energy trading and its control of the New York Stock Exchange, is engaged in negotiations that would give it a foothold in the $9.4 trillion U.S. mortgage market. ICE is in early stage talks to form a partnership with Mortgage Electronic Registration Systems Inc., which documents the ownership and resale of about half of U.S. home loans, according to a person familiar with the matter, who asked to not be identified because the discussions are private. The Atlanta-based exchange owner has been gauging demand for derivatives that enable investors to bet on defaults by U.S. homeowners, Bloomberg News reported in May. ICE, which earns most of its revenue by owning one of the world’s largest derivatives markets, has recently expanded into new businesses such as equity trading with its 2013 purchase of NYSE Euronext and the administration of interest-rate benchmarks. Mr. Leising may be contacted at mleising@bloomberg.net; Mr. Hamilton may be contacted at jhamilton33@bloomberg.net; Ms. Shenn may be contacted at jshenn@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Matthew Leising, Jesse Hamilton and Jody Shenn, Bloomberg

Third Circuit Follows Pennsylvania Law - Damage Caused by Faulty Workmanship Does Not Arise from an Occurrence

May 10, 2013 — Tred Eyerly
The Third Circuit followed Pennsylvania law in determining that damage caused by faulty workmanship did not arise from an occurrence. Zurich Am. Ins. Co. v. R. M. Shoemaker Co., 2013 U.S. App. LEXIS 6093 (3d Cir. March 27, 2013). The County sued R. M. Shoemaker, alleging faulty construction of an addition to a correctional institution. The County alleged Shoemaker negligently supervised its subcontractor, thereby permitting the subcontractor to engage in willful misconduct, resulting in damage to structural elements of the correctional institution. The County alleged that Shoemaker's negligence permitted water to intrude, damaging the electrical systems, acoustic ceilings and miscellaneous equipment. Zurich sought a declaratory judgment that it was not required to defend or indemnify Shoemaker. The district court granted Zurich summary judgment. Relying on Pennsylvania law, the district court found that the allegations in the underlying action did not arise from an occurrence. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Mr. Eyerly can be contacted at te@hawaiilawyer.com

Loss Ensuing from Faulty Workmanship Covered

April 28, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The court found coverage for damage resulting from faulty workmanship. Drury Co. v. Mo. United Sch. Ins. Counsel, 2014 Mo. App. LEXIS 319 (Mo. Ct. App. March 25, 2014). The School District entered a contract with general contractor, Penzel Construction Company, Inc., to build an addition to a high school. Under the prime contract, the School District was to purchase property insurance, including builder's risk "all-risk" coverage. The policy was to cover the interests of the owner, the contractor, subcontractors and sub-subcontractors in the project. The School District obtained a policy from Missouri United School Insurance Counsel (MUSIC). Exclusions in the all-risk policy included loss due to faulty workmanship or materials, "unless loss by a peril not otherwise excluded ensues and then MUSIC shall be liable only for such ensuing loss." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Contractor Pleads Guilty to Disadvantaged-Business Fraud

November 17, 2016 — Tom Ichniowski – Engineering News-Record
In the latest development in a federal small disadvantaged-business case, a construction company executive has pleaded guilty to a charge of conspiring to commit wire fraud. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, Engineering News-Record
Mr. Ichniowski may be contacted at ichniowskit@enr.com

Tightest Credit Market in 16 Years Rejects Bernanke’s Bid

October 08, 2014 — Prashant Gopal – Bloomberg
James Bregenzer, a 31-year-old marketing strategist in Chicago, was rejected for a mortgage in May after successfully financing two previous home purchases. The hitch this time: his monthly payment would have been $100 more than the lender was willing to approve. Bregenzer is in good company. Standards in the U.S. are so high and inflexible that former Federal Reserve Chairman Ben S. Bernanke, now a Brookings Institute fellow-in-residence with a net worth of at least $1.1 million, said at a conference last week that he couldn’t refinance his house in Washington. Even some doctors struggle to get home loans if they’re self-employed. “We asked if we could go over by $100 and were told that’s just not going to work,” said Bregenzer, who bought his first home before getting married in 2008. “The process of buying a home used to be stupid easy. Now, my wife and I were buying a home with two salaries, we make a heck of a lot more than I used to, and I have to go into great and terrible detail to show documentation.” Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg
Mr. Gopal may be contacted at pgopal2@bloomberg.net

Haight Welcomes Robert S. Rucci

August 26, 2015 — Robert S. Rucci – Haight Brown & Bonesteel LLP
Haight Brown & Bonesteel LLP welcomes new partner Robert S. Rucci. Mr. Rucci joins Haight’s San Diego office in the Construction Law, General Liability and Risk Management & Insurance Law Practice Groups. For 25 years, Mr. Rucci has specialized in defending design professionals, businesses and their employees in addition to representing clients against declaratory relief, breach of contract and bad faith litigation. During his career, he has tried 60 cases to defense verdict and successfully resolved countless matters via mediation, arbitration and settlement conference. His extensive litigation experience is invaluable to our clients. Haight Brown & Bonesteel LLP 402 West Broadway Suite 1850 San Diego, CA 92101 www.hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of Robert S. Rucci, Haight Brown & Bonesteel LLP
Mr. Rucci may be contacted at rrucci@hbblaw.com

How Many New Home Starts are from Teardowns?

April 15, 2015 — Beverley BevenFlorez-CDJ STAFF
In a NAHB/Wells Fargo Housing Market Index survey, builders were asked “Of the homes you started in 2014, approximately what share were on a site where a previous structure, or evidence of a previous structure, was present before you started?” According to the NAHB, the surveyors reported that “[o]n average, weighted by starts, […] just under five percent of their starts were teardowns according to the survey’s criterion.” When compared to census data, it equates to 31,800 single-family teardown starts in 2014. Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES