Cambridge Massachusetts Building Expert Directory

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

Construction Litigation Roundup: “Who Needs Them”

August 28, 2023 — Daniel Lund III - Lexology
Who needs them? So argued a surety pursuing recovery under its general agreement of indemnity when the indemnitors urged a Louisiana federal court to dismiss the surety’s complaint for failure to join various allegedly required parties as defendants in the litigation. As part of its court action, the surety moved for preliminary injunction to enforce its collateral security rights. In response thereto, the indemnitors informed the court that if the injunction were to be granted, the indemnitors would “be forced to sell assets that are encumbered by security interests senior to those held by” the surety. In connection therewith, the indemnitors demanded that the other creditors be joined in the action or the lawsuit dismissed. The indemnitors also urged that the public project owner be joined as a party because the surety was seeking proceeds from the project that were still in the possession of the project owner. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

99-Year-Old Transmission Tower Seen as Possible Cause of Devastating Calif. Wildfire

December 11, 2018 — Contra Costa Times - Engineering News-Record
Dec. 08 --PULGA -- With winds gusting around 50 mph in the morning hours of Nov. 8 , portions of a PG&E steel lattice transmission tower -- exposed to the elements high on a ridgetop and originally built when Woodrow Wilson was president -- failed. As high-voltage lines got loose and whipped around, striking the metal tower, molten aluminum and metal sprayed across tinder dry vegetation, igniting the brush. Arriving firefighters could only watch as the blaze underneath the power lines quickly spread to wild timber and brush. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

A Relatively Small Exception to Fraud and Contract Don’t Mix

April 01, 2015 — Christopher G. Hill – Construction Law Musings
Remember all of my posts about how fraud and contract claims don’t usually play well in litigation? Well, as always with the law, there are exceptions. For instance, a well plead Virginia Consumer Protection Act claim will survive a dismissal challenge. A recent opinion out of the Alexandria division of the U. S. District Court for the Eastern District of Virginia sets out another exception, namely so called fraudulent inducement. In XL Specialty Ins. Co. v. Truland et al, the Court considered the question of whether both a tort and contract claim can coexist in the same lawsuit when the tort claim is based upon the information provided to the plaintiff when that information proves false. As the courts of Virginia have held for years, only certain information and statements made pre-contract can be the basis for a fraud claim in the face of a contractual duty to perform. One type of statement that is not properly the subject of a fraud in the inducement type claim is sales talk or opinion. Such sales talk (for example claiming that your company is the best for the job) is not the subject of a fraud claim because it is not meant to be relied upon and that such talk is an opinion about future performance, not a false statement of present fact or intent. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

New York Team’s Win Limits Scope of Property Owners’ Duties to Workers for Hazards Inherent in Their Work

May 20, 2024 — Lewis Brisbois Newsroom
New York, N.Y. (May 9, 2024) - New York Partners Jennifer Oxman and Andrew Harms recently secured dismissal of a personal injury plaintiff’s complaint on summary judgment in Queens County, with a state judge accepting their argument that a porter who allegedly tripped and fell on loose wood in a stairwell had no cause of action against the property owner because it was his job to clean the stairs in the first instance. The porter was not an employee of the property owner, but rather an employee of a property management company. Therefore, the workers compensation bar did not apply to the employee’s claims. In a four-page decision, Justice Chereé A. Buggs of Queens County Supreme Court found that plaintiff’s duties as a porter included cleaning the stairwell and that he saw and cleaned loose pieces of wood on occasions prior to his accident. Justice Buggs held that while the wood debris likely came from an “outside source”, i.e. a contractor performing work at a neighboring building, the source of the debris was not relevant. Rather, what mattered was the fact that the hazard upon which plaintiff tripped was “inherent in or related to” plaintiff’s work responsibilities. By contrast, Justice Buggs held that the contractor who allegedly was the source of the wood was not entitled to summary judgment under the same legal theory because it arguably caused and created the hazard upon which plaintiff tripped. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

Rent Increases During the Coronavirus Emergency Part II: Avoiding Violations Under California’s Anti-Price Gouging Statute

April 06, 2020 — Dan Schneider - Newmeyer Dillion
In my earlier article, Profiting From Fear: What You Need to Know About Price Gouging During the Coronavirus Emergency, I discuss price gouging and how the anti-price gouging statute, California Penal Code 396 (“CPC 396”), protects buyers of goods and services deemed vital and necessary for the health, safety and welfare of consumers. Part II of the article provides guidance to landlords on the parameters applicable to acceptable price increases and focuses attention on the application of CPC 396 to rental housing and related issues. California Penal Code 396 As it pertains to housing, defined as “any rental housing with an initial lease term of no longer than one year,” price gouging occurs when a landlord increases the rent of an existing or prospective tenant by more than 10 percent of the previously charged or advertised price following an emergency or disaster declaration for a period of 30 days.2 A residential landlord is only allowed to increase rent in excess of 10 percent if “the increase is directly attributable to additional costs for repairs or additions beyond normal maintenance that were amortized over the rental term that caused the rent to be increased greater than 10 percent or that an increase was contractually agreed to by the tenant prior to the proclamation or declaration” (CPC 396(e).) Further, landlords are prohibited from evicting a tenant and then re-renting the property at a rate that the landlord would have been prohibited from charging the evicted tenant under the statute (CPC 396(f).)3 Read the court decision
Read the full story...
Reprinted courtesy of Dan Schneider, Newmeyer Dillion
Mr. Schneider may be contacted at daniel.schneider@ndlf.com

Prison Contractors Did Not Follow the Law

October 15, 2013 — CDJ STAFF
Under Iowa law, nearly ninety-percent of the construction workers for the new state prison in Fort Madison should have been Iowa residents. But according to reports obtained by the Des Moines Register, about fifty percent of the workers were from other states. The law responds to a similar one in Illinois that requires that most workers on public projects must be Illinois residents. Many of the out-of-state employees live on the other side of the Mississippi River and, according to Ryan Drew of the Southeast Iowa Building and Construction Trades Council, are part of a broader Illinois-Iowa community, shopping at Iowa retailers. Read the court decision
Read the full story...
Reprinted courtesy of

Congratulations to BWB&O’s Los Angeles Office on Another Successful MSJ!

July 11, 2022 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is proud to announce Partner Daniel Crespo and Associate Stefon Jackson successfully argued and won a Motion for Summary Judgment (“MSJ”) for our client, a property owner of an apartment complex. Plaintiff was involved in a physical altercation with one of the tenants at an apartment complex owned by our client. Plaintiff alleged that our client had notice of a propensity for violence claiming that there were prior instances of contentious interactions between this particular tenant and Plaintiff. As a result, Plaintiff alleged that our client had a duty to prevent further interactions between Plaintiff and the tenant presuming that an act of physical violence was reasonably foreseeable. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES