Seattle Washington Building Expert Directory

California Expands on Scope of Coverage for Soft Cost Claims

February 14, 2023 — Caitlin N. Rabiyan - Saxe Doernberger & Vita, P.C.
The California federal district court case of KB Home v. Illinois Union Insurance Co., No. 8:20-cv-00278-JLS-JDE, (C.D. Cal. August 23, 2022), provides much needed guidance for cases involving builder's risk insurance claims for soft cost coverage. The case stems from damage to several of KB Home’s residential building sites caused by a severe rainstorm in January 2017. Each home site was a smaller part of a large housing development project. The damage caused significant delay in the completion of some individual home sites, although there was limited evidence of delay to the overall housing development project. As a result, KB Home sought coverage under a builder’s risk policy purchased from Illinois Union for both hard costs and soft costs. “Hard costs” are the costs directly associated with repairing property damage to the sites. Conversely, “soft costs” are indirect expenses associated with project delays caused by such property damage and repair efforts. For example, hard costs would include labor and materials, whereas the soft costs claimed by KB Home included additional real estate taxes, construction loan interest, and advertising and promotional expenses incurred because of the delays. Illinois Union paid the claim for the hard costs, but denied the soft costs claim. KB Home filed suit and Illinois Union eventually filed a motion for summary judgment. Read the court decision
Read the full story...
Reprinted courtesy of Caitlin N. Rabiyan, Saxe Doernberger & Vita, P.C.
Ms. Rabiyan may be contacted at CRabiyan@sdvlaw.com

Novation Agreements Under Federal Contracts

November 29, 2021 — Hal Perloff - Construction Executive
A unique aspect of doing business with the federal government is the built-in limits on a contractor’s right to assign the contract or the right to payment under the contract to third parties. The Anti-Assignment Act (41 U.S.C. § 6305) prohibits the transfer of a government contract or interest in a government contract to a third party. An assignment of a contract in violation of this law voids the contract except for the government’s right to pursue a breach of contract remedies. What’s a contractor to do when it is acquired/merged with another firm, is restructured or goes through a variety of other types of corporate transaction? The Federal Acquisition Regulations recognize that firms involved in government contracts get bought and sold from time to time and includes procedures for the novation of contracts in certain situations to avoid a potential violation of the Anti-Assignment Act. What Is a Novation? A novation is a three-party agreement between the United States, the original contractor and the new contractor offering to assume the government contract. The purpose the novation is to allow the government to recognize a new contractor as the successor-in-interest to a government contract and avoid a violation of the Anti-Assignment Act. Reprinted courtesy of Hal Perloff, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Perloff may be contacted at hal.perloff@huschblackwell.com

Liquidating Agreements—Bridging the Privity Gap for Subcontractors

September 03, 2015 — Craig Martin – Construction Contractor Advisor
What is a subcontractor to do when the owner has demanded additional work, but has refused to pay for it? Typically, a subcontractor cannot sue the owner because the subcontractor doesn’t have a contract with the owner. Perhaps the subcontractor and general contractor should enter into a liquidating agreement through which the general contractor can pursue the claim on behalf of the subcontractor. Liquidating agreements bridge the privity gap between owners and subcontractors who sustain damages because of the others actions. Liquidating agreements or pass-through agreements grant the general contractor a release of its liability to the subcontractor after the general contractor prosecutes the subcontractor’s pass-through claim against the owner and gives the subcontractor any recovery. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

New York Court Temporarily Enjoins UCC Foreclosure Sale

September 21, 2020 — Steven E. Ostrow, Timothy E. Davis, Steven E. Coury & Kristen E. Andreoli - White and Williams
New York courts have become a battleground for challenges to foreclosure sales under the Uniform Commercial Code (UCC) amidst the COVID-19 pandemic. Another trial court of the New York State Supreme Court (New York County) issued a preliminary injunction in Shelbourne BRF LLC v. SR 677 Bway LLC, halting a mezzanine lender’s August 19, 2020 UCC foreclosure sale. The decision confirms that the impact of the pandemic on the value of commercial real estate, and upon traditional steps taken to conduct a foreclosure auction, are both key factors that courts will continue to consider in determining whether a UCC foreclosure sale scheduled during the pandemic can be conducted in a commercially reasonable manner as required by the UCC. THE CASE In Shelbourne, the mezzanine borrowers owned the membership or equity interests in the companies (collectively, the “Property Owner”) that held title to a 12-story office building in Albany, New York. As security for the $3.35 million mezzanine loan, the mezzanine borrowers pledged their equity interests to the mezzanine lender. In May 2020, the mezzanine lender declared a default under the mezzanine loan as a result of the Property Owner’s default under the $28.5 million senior loan secured by a mortgage against the office building. The mezzanine lender then scheduled a public UCC foreclosure sale of the equity interests in the Property Owner for August 19, 2020. If the sale had been held, the equity interests in the Property Owner (and right to control the Property Owner and office building) would have been transferred to the successful bidder, either the mezzanine lender or a third party purchaser. Reprinted courtesy of White and Williams attorneys Steven E. Ostrow, Timothy E. Davis, Steven E. Coury and Kristen E. Andreoli Mr. Ostrow may be contacted at ostrows@whiteandwilliams.com Mr. Davis may be contacted at davist@whiteandwilliams.com Mr. Coury may be contacted at courys@whiteandwilliams.com Ms. Andreoli may be contacted at andreolik@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Traub Lieberman Team Obtains Summary Judgment in Favor of Client Under Florida’s Newly Implemented Summary Judgment Standard

August 23, 2021 — Heather Fleming & Gregory H. Lercher - Traub Lieberman
On July 27, 2021, the Circuit Court of the Ninth Judicial Circuit in and for Osceola County, Florida granted summary judgment in favor of a client insurer defended by Traub Lieberman Partner Heather M. Fleming and Associate Gregory H. Lercher in connection with a first party property lawsuit arising from Hurricane Irma that involved multiple, comingled claims, in part resolved via prior appraisal. As of May 1, 2021, Florida state courts have applied a new summary judgment standard after Florida’s longstanding rule was amended by the Supreme Court of Florida. The amendment aligns Florida’s standard with that of the federal courts and the supermajority of states that have already adopted the federal summary judgment standard codified in Rule 56 of Federal Rules of Civil Procedure. The Supreme Court of Florida’s stated goal in adopting the new standard across the Sunshine State was to improve the fairness and efficiency of Florida's civil justice system, to relieve parties from the expense and burdens of meritless litigation, and to save the work of juries for cases where there are real factual disputes that need resolution. Reprinted courtesy of Heather Fleming, Traub Lieberman and Gregory H. Lercher, Traub Lieberman Ms. Fleming may be contacted at hfleming@tlsslaw.com Mr. Lercher may be contacted at glercher@tlsslaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Aging-in-Place Features Becoming Essential for Many Home Buyers

March 12, 2014 — Beverley BevenFlorez-CDJ STAFF
With the rising number of Americans over the age of sixty-five, there is an “upswing” in demand of “aging-in-place home features,” according to Big Builder. Big Builder also noted seven accessible features that homebuyers identified when surveyed by The National Association of Home Builders (NAHB). A couple of the features listed were “doorways at least three feet wide” and “non-slip floors.” The survey results were reported in What Home Buyers Really Want, released in May 2013 by the NAHB. Read the court decision
Read the full story...
Reprinted courtesy of

Beware of Design Pitfalls In Unfamiliar Territory

September 05, 2022 — Brad Shefrin - Engineering News-Record
$250,000. $1.5 million. $12 million. These are the litigation damage estimates that plaintiffs sought to recover against design professionals who failed to familiarize themselves with local site conditions. Reprinted courtesy of Brad Shefrin, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Gaps in Insurance Created by Complex Risks

January 22, 2024 — The Hartford Staff - The Hartford Insights
From slips, trips and falls to extreme weather and cyberattacks, businesses are regularly confronted with risks to operations and profitability. In 2023, elevated building costs, increased flooding, and growing ransomware attacks made it compelling for business owners to make sure they had adequate insurance to stay ahead of property and liability exposures. However, if left unchecked, these trends can lead to gaps in coverage. As 2024 approaches, now is the time to assess your risk and collaborate with the right resources to fill any potential voids in insurance. Economic inflation for example has changed property valuations, which can result in coverage gaps if policyholders have not examined their replacement costs recently. Read the court decision
Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES