Seattle Washington Building Expert Directory

Triple Points to the English Court of Appeal for Clarifying the Law on LDs

July 01, 2019 — Vincent C. Zabielski & Julia Kalinina Belcher - Gravel2Gavel
Can an employer recover liquidated damages (LDs) from a contractor if the contract terminates before the contractor completes the work? Surprisingly, heretofore, English law provided no clear answer to this seemingly straightforward question, and inconsistent case law over the past century has left a trail of confusion. Given the widespread use of English law in international construction contracts, this uncertainty had gone on far too long. The good news is that drafters of construction contracts throughout the world can now have a well-deserved good night’s sleep courtesy of the English Court of Appeal’s March 2019 decision in Triple Point Technology, Inc. v PTT Public Company Ltd [2019] EWCA Civ 230. The Triple Point case concerned the delayed supply by Triple Point (the “Contractor”) of a new software system to employer PTT. The contract provided for payments upon achievement of milestones, however order forms incorporated into the contract set out the calendar dates on which fixed amounts were payable by PTT, resulting in an apparently contradictory requirements on when payment was due. Triple Point achieved completion (149 days late) of a portion of the work milestones, and were paid for that work. Triple Point then sought payment for the work which was not yet completed, relying on the calendar dates in the order forms rather than achievement of milestone payments. Things got progressively worse as PTT refused payment, Triple Point suspended the work for PTT’s failure to pay, PTT terminated the contract and then appointed a new contractor to complete the work. Reprinted courtesy of Vincent C. Zabielski, Pillsbury and Julia Kalinina Belcher, Pillsbury Mr. Zabielski may be contacted at vincent.zabielski@pillsburylaw.com Ms. Belcher may be contacted at julia.belcher@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

What You Need to Know About Additional Insured Endorsements

August 30, 2017 — Gary Barrera - California Construction Law Blog
A well-drafted insurance clause is an integral part of a construction contract because it sets forth a subcontractor’s obligations to add the general contractor to its policies of insurance as an additional insured and identifies the manner by which the general contractor will qualify as an additional insured. In a typical construction contract, the general contractor will be an additional insured via a scheduled endorsement or a blanket endorsement. Scheduled Endorsements A scheduled endorsement contains a “schedule” in which the person or organization that is named in the schedule is added to the policy as an additional insured. The following scheduled endorsements are commonly used in construction contracts. Read the court decision
Read the full story...
Reprinted courtesy of Gary Barrera, Wendel Rosen Black & Dean LLP
Mr. Barrera may be contacted at gbarrera@wendel.com

Pollution Exclusion Found Ambiguous

May 23, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The Mississippi Supreme Court found the pollution exclusion ambiguous under the facts presented. Omega Protein, Inc. v. Evanston Ins. Co., 2022 Miss. LEXIS 90 (Miss. March 31, 2022). Omega Protein, Inc., entered a contract with Ascu-fab to perform welding and other fabrication work at their facility. Accu-fab was required to have CGL coverage naming Omega as an additional insured. Accu-fab purchased a $1 million primer policy from Colony Insurance Company and a $5 million excess policy issued by Evanston Insurance Company. Accu-fab performed welding and other fabrication work on a large metal storage tank used for the temporary storage of stickwater, which was a liquid composed of water, fish oil, and fish solids. An explosion occurred at the Omega plant while Accu-fab workers were welding and grinding on a large metal tank that was used for the temporary storage of stickwater. One of Accu-fab's workers , Jerry Lee Tayler, was killed, another was seriously injured, and still others suffered less serous injuries. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Kahana Feld Welcomes Six Attorneys to the Firm in Q4 of 2023

January 16, 2024 — Linda Carter - Kahana Feld
Kahana Feld is pleased to announce the addition of six attorneys to the team in the fourth quarter of 2023. We are excited to have each of these individuals on the team. In our Houston office, Kahana Feld welcomes Partner Donald Loving II and Attorney Elliott Wright. Mr. Loving is a member of the General Liability and Trucking & Transportation practice groups. He earned his Juris Doctor from the University of Houston and has over 30 years of litigation and trial experience, including working as staff & corporate counsel for several prominent insurance carriers including GEICO, Progressive, USAA and Travelers. Mr. Wright is a member of the Construction Defect, General Liability, and Trucking & Transportation practice groups. He earned his Juris Doctor from SMU Dedman School of Law, and has extensive litigation and insurance defense experience. Read the court decision
Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

US Court Questions 102-Mile Transmission Project Over River Crossing

February 07, 2022 — Mary B. Powers - Engineering News-Record
A federal judge will decide in February whether to stop construction of a $492-million Iowa-to-Wisconsin transmission line, after issuing an opinion in mid-January “declaring” that federal rules preclude the 102-mile Cardinal-Hickory Creek project from crossing the 261-mile Upper Mississippi River National Wildlife and Fish Refuge by right-of-way or land transfer. Reprinted courtesy of Mary B. Powers, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Colorado Homes Approved Despite being Too Close Together

January 22, 2014 — Beverley BevenFlorez-CDJ STAFF
ABC 7 reported that more than a dozen homes in Adams County, Colorado were inspected and approved by Building and Safety despite being built too close together. The problem was discovered by an inspector who cited a new home for being “4 inches too close to adjoining property.” Jim Williamette, the Adams County Chief Building Official told ABC 7, “It’s a fire issue for the separation of buildings.” The county may have solved the issue, according to ABC 7. Williamette stated that the properties “will be modified with fire-resistant windows” and combined with the “already-installed fire-resistant siding, the windows will satisfy the international building code.” Currently, the parties are in verbal agreement, and a “signed design proposal” is expected no later than January 21st. Read the court decision
Read the full story...
Reprinted courtesy of

Melissa Pang Elected Vice President of APABA-PA Board of Directors

December 21, 2016 — White and Williams LLP
Melissa Pang has been elected Vice President of the Asian Pacific American Bar Association of Pennsylvania's (APABA-PA) Board of Directors. She will serve a one-year term in the position, beginning January 1, 2017. As part of her responsibilities, Melissa will co-chair the National Asian Pacific American Bar Association Northeast Regional Conference, which will be hosted by the APABA-PA in Philadelphia. Melissa has been a member of the APABA-PA since 2010 and has served on the board since 2015. Her involvement includes participation on the Law Student Outreach Committee as well as the Annual Banquet Committee. In 2016, she chaired the organization's Lunar Banquet. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Pang, White and Williams LLP
Ms. Pang may be contacted at pangm@whiteandwilliams.com

Case-Shiller Redo Shows Less Severe U.S. Home-Price Slump

September 03, 2014 — Lorraine Woellert – Bloomberg
The collapse in U.S. home prices that stoked the worst recession since the Great Depression wasn’t quite as severe as initially estimated, according to data from S&P/Case-Shiller. Property values nationally fell 26 percent from the February 2007 peak to the December 2011 trough, not 34 percent as previously reported, revised data showed last week. The index will now be issued monthly rather than quarterly. The change is the result of CoreLogic Inc. (CLGX)’s $6 million purchase of the S&P/Case-Shiller index from technology company Fiserv Inc. in March 2013. Case-Shiller has spent more than a year retrofitting its model with CoreLogic’s bigger, higher-quality data set, leading to a change in how the index looks. Read the court decision
Read the full story...
Reprinted courtesy of Lorraine Woellert, Bloomberg
Ms. Woellert may be contacted at lwoellert@bloomberg.net

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES