Cambridge Massachusetts Building Expert Directory

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

House Bill Clarifies Start Point for Florida’s Statute of Repose

September 14, 2017 — Lian Skaf - White and Williams LLP
The Florida legislature recently enacted a law clarifying when the ten-year statute of repose begins to run for cases involving “improvements to real property,” as that phrase is used in Florida Statute Section 95.11. House Bill 377 was signed into law on June 14, 2017 and took effect in all cases accruing on or after July 1, 2017. This amendment is significant to subrogation professionals evaluating when cases involving contractors and design professionals are time barred. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

Housing Starts in U.S. Slumped More Than Forecast in March

April 20, 2016 — Sho Chandra – Bloomberg
New-home construction in the U.S. slumped more than projected in March, reflecting a broad-based retreat that showed the industry lost momentum heading into the busiest time of year. Residential starts decreased 8.8 percent to a 1.09 million annualized rate that was the lowest since October and weaker than any forecast of economists surveyed by Bloomberg, Commerce Department data showed Tuesday in Washington. Permits, a proxy for future construction, also dropped. Read the court decision
Read the full story...
Reprinted courtesy of Sho Chandra, Bloomberg

Visual Construction Diaries – Interview with Jeff Sassinsky of Fovea Aero

November 30, 2017 — Aarni Heiskanen - AEC Business
Jeff Sassinsky, President of Fovea Aero, gave me a live demonstration on Fovea Aero Vision – an app that allows you to a get a fully immersive visual construction diary of your project. The idea for the development of Fovea Aero Vision came from discussions with general contractors, owners, and other construction industry professionals. They were talking about the use of smartphones, particularly phone cameras, in construction. The photos, for example, of a fitting that does not look right end up in a folder on a server or goes back and forth in email messages. “The lack of any structure behind both the collection and the storage and sharing of the photos is hampering their usage,” Jeff said. “We wanted to solve the problem by creating a full record of everything that takes place on a construction site, on a regular basis, sharing it among the stakeholders, and making it super easy to use.” Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

Is Your Construction Business Feeling the Effects of the Final DBA Rule?

June 04, 2024 — Nathaniel Peniston - Construction Executive
The Biden administration’s final rule “Updating the Davis-Bacon and Related Acts Regulations” took effect on Oct. 23, 2023. In “the first comprehensive regulatory review in nearly 40 years,” the Department of Labor has returned to the definition of “prevailing wage” it used from 1935 to 1983—before Microsoft released the first Windows operating system. Construction industry leaders must be aware that this is the most comprehensive review and overhaul of the act in 40 years; with it, the DOL has attempted to modernize its approach to wage creation and fringe benefit allocation. There are more than 50 procedural changes to the act, which means it is very important for contractors to be aware of wage classifications when bidding, performing work on Davis-Bacon Act projects and using applicable fringe dollars for bona fide benefits. UNDERSTANDING THE CHANGES Some of the critical adjustments included in the final rule that contractors should be aware of include: Wage determination changes during a project: Historically, contractors could rely on the wage determinations used to win a project for the life of the project. However, the final rule now requires the contractor to use current wage determinations when a contract is changed or extended. The DOL “proposed this change because—like a new contract—the exercise of an option requires the incorporation of the most current wage determination.” Reprinted courtesy of Nathaniel Peniston, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Peniston may be contacted at npeniston@fbg.com

Prevailing HOAs Not Entitled to Attorneys’ Fees in Enforcement Actions Brought Under Davis-Stirling

August 30, 2017 — Lawrence S. Zucker II & Michael C. Parme – Haight Brown & Bonesteel LLP
In Retzloff v. Moulton Parkway Residents’ Ass’n, (2017) Cal. App. LEXIS 727, the Fourth District Court of Appeal considered the novel question of whether attorneys’ fees can be included as part of the cost award to a ‘prevailing association’ under Cal. Civ. Code §5235(c). Plaintiffs were former board members of Moulton Parkway Residents’ Association, No. One (“the Association”) who sued the Association for alleged violations of the Davis-Stirling Common Interest Development Act (Civ. Code §4000 et. seq.) which regulates the governance of common interest developments such as condominium communities and homeowners associations. Plaintiffs’ suit alleged that the Association regularly conducted business outside of scheduled board meetings and failed to make certain records available for inspection. Reprinted courtesy of Lawrence S. Zucker II, Haight Brown & Bonesteel LLP and Michael C. Parme, Haight Brown & Bonesteel LLP Mr. Zucker may be contacted at lzucker@hbblaw.com Mr. Parme may be contacted at mparme@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Bert L. Howe & Associates to Join All-Star Panel at West Coast Casualty Seminar

March 26, 2014 — Beverley BevenFlorez-CDJ STAFF
Don MacGregor of Bert L. Howe & Associates, a consulting firm, will join fellow panelists Hon. Peter Lichtman (ret), Hon. Nancy Wieben Stock (ret), Peter S. Curry, Brian Kahn, Esq., and Paul R. Kiesel, Esq in a break-out discussion entitled “Working Smarter with Technology” at this year’s West Coast Casualty Construction Defect Seminar being held May 15th-16th at the world-famous Disneyland Hotel in Anaheim, California. West Coast Casualty's Construction Defect Seminar is the largest seminar of its kind worldwide focusing on all of the elements of the prosecution, defense, coverage and technologies of construction defect claims and litigation from a national perspective. With offices in California, Nevada, Colorado, Florida and Texas (Houston & San Antonio), Bert L. Howe & Associates provides construction consulting and expert witness services to insurance professionals and lawyers specializing in construction defect litigation, construction risk analysis, and property claims arising from construction-related activities. Download an Invitation and Register... Read the court decision
Read the full story...
Reprinted courtesy of

Timber Prices Likely to Keep Rising

October 30, 2013 — CDJ STAFF
Lumber prices are expected to keep rising, and according to Terry Shumacher, who does business acquisition for private equity firms, that’s a sign to invest in lumber stocks. Writing at Seeking Alpha, he looks at one such company, Tembec, the eleventh largest lumber producer in North America. Tembec is headquartered in Canada, but its stock trades on both the Canadian and American markets. Mr. Schumacher points out that one of the advantages of Tembec as an investment is that its stock is currently trading at about $2.59 a share, so a $50 per million board feet increase in the cost of lumber would make a large percentage change to its earnings to price ratio. (As comparison, Mr. Schumacher offers West Fraser, which is trading at about $89.59. There, the increase in lumber prices would have a much smaller effect on the stock price.) There’s going to be a greater demand for lumber, not only due to increased housing starts but that North American firms have started exporting lumber to China. Add to that the loss of trees in some areas due to beetle infestations. The death of standing timber has lead to some sawmills shutting down for lack of logs. All of which points to increased timber prices. Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES