Fairfield Connecticut Building Expert Directory

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Brazil's Detained Industry Captain Says No Plea Deals Coming

September 03, 2015 — Sabrina Valle & Yasmine Batista – Bloomberg
Marcelo Odebrecht, the most prominent executive who has been detained in Brazil’s largest corruption scandal, said he sees no reason to strike a plea bargain with authorities because he has nothing to reveal. Odebrecht said in a congressional hearing Tuesday that he probably discussed with President Dilma Rousseff and her predecessor Luiz Inacio Lula da Silva the relationship between Odebrecht SA and Petrobras, the state-controlled oil producer at the center of the kickback investigation. It was a natural topic given the economic importance of his construction and engineering empire, he said. He declined to answer questions related to the criminal case, saying it is ongoing and he is unaware of the full extent of the accusations. Reprinted courtesy of Sabrina Valle, Bloomberg and Yasmine Batista, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Termination for Convenience Clauses: Maybe More Than Just Convenience

June 06, 2022 — Robert C. Shaia - ConsensusDocs
A contractor begins work on a project and everything is going well, until one day the owner informs the contractor that it is being terminated for convenience. Possibly, there is no discussion about alleged defects, reasons for the termination, or any damages the owner might seek against the contractor. In that moment, the contractor may be unaware of any perceived wrongdoing or problems with its work. The industry has typically accepted that, in this scenario, the owner implicitly waives the right to any remedies against the contractor, except those expressly set forth in the contract. Reasonable minds might assume that, if the owner believed it needed to seek further remedies, it would terminate the contractor for cause instead of convenience. And often overlooked during contract negotiations are the benefits of including an express “waiver of remedies” in the termination for convenience section. Read the court decision
Read the full story...
Reprinted courtesy of Robert C. Shaia, Watt, Tieder, Hoffar, & Fitzgerald, LLP (ConsensusDocs)
Mr. Shaia may be contacted at rshaia@watttieder.com

Insurer's Withheld Discovery Must be Produced in Bad Faith Case

November 03, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The United States District Court for the Western District of Washington granted the insureds' motion to compel and ordered that the insurer produce withheld discovery. Bagley v. Travelers Home & Marine Ins. Co., 2016 U.S. Dist. LEXIS 115028 (W.D. Wash. Aug. 25, 2016). The insureds' dock and boat ramp were damaged in a storm. Travelers refused to pay for the damage, arguing it was not covered. After Plaintiffs filed suit, Travelers admitted coverage and agreed to pay. The insureds' suit included a claim that Travelers wrongfully denied coverage, thereby costing the insureds money. The insureds moved the court to compel Travelers to respond to certain discovery requests. First, the insureds requested the claims file Travelers maintained on their claim. The court did not order the production of privileged documents, but documents related to claims handling were not privileged. Travelers was ordered to produce all documents in the insureds' claim file that related to claim handling, even if the documents were created after the commencement of litigation. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Fed Inflation Goal Is Elusive as U.S. Rents Stabilize: Economy

March 12, 2014 — Michelle Jamrisko and Ilan Kolet - Bloomberg
Federal Reserve efforts to nurture a more robust rate of inflation this year are likely to fall short. The reason: the biggest gains in rents are probably over. The costs to lease residential real estate, the second-biggest component of the price measure tracked by U.S. central bankers, helped put a floor under inflation over the past two years as most other components decelerated. Now, with builders cranking out a record number of multifamily buildings and the job market still far from tight, the outlook for rents is the bleakest it’s been in four years. “Because the economy is still not in the strongest position and certainly the labor market is not in the strongest position, landlords really can’t extract much more in the way of rent growth,” said Ryan Severino, a senior economist at real-estate data provider Reis Inc. in New York. Also, rents are already high, which makes more increases difficult, he said. Ms. Jamrisko may be contacted at mjamrisko@bloomberg.net; Mr. Kolet may be contacted at ikolet@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Michelle Jamrisko and Ilan Kolet, Bloomberg

Haight Brown & Bonesteel Ranked on the 2017 "Best Law Firms" List by U.S. News - Best Lawyers

November 10, 2016 — Haight Brown & Bonesteel LLP
U.S. News – Best Lawyers® ranked Haight Brown & Bonesteel on the 2017 “Best Law Firms” list in the Metropolitan Tier 1 Ranking in Los Angeles for their defense work in insurance law and personal injury litigation. Read the court decision
Read the full story...
Reprinted courtesy of

Committeewoman Requests Refund on Attorney Fees after Failed Legal Efforts

February 10, 2014 — Beverley BevenFlorez-CDJ STAFF
West Deptford, New Jersey township redevelopment counsel Mark Cimino had spent a year arguing that the city should receive a $4 million reduction in construction costs due to “inadequate documentation provided by the bank, as well as receipts showing disbursement had ‘improperly’ been made toward uses other than construction,” according to a December 30th 2013 article in the South Jersey Times. However, a state appellate court upheld the ruling that “the township had no basis” to request the reduction. Now, Committeewoman Denice DiCarlo is “seeking a $10,000 refund on the attorney fees paid” to Cimino, the South Jersey Times reported on February 6th. “This entire matter has been a monumental waste of tax dollars, and I am angry that the entire township committee was misled by Mr. Cimino and induced to believe we had any reasonable chance of recovering loan proceeds from this lawsuit,” DiCarlo stated in a letter to Mayor Raymond Chintall. Not all committee members agree with DiCarlo. Committeeman Sam Cianfarini told South Jersey Times that “he still believed Fulton Bank owed it to West Deptford to answer for any funds put toward anything other than construction.” Cimino declared “that both the lawsuit and appeal were valid,” according to the February 6th article. He “accused DiCarlo of ‘playing politics.’” Read the full story, December 30th Article... Read the full story, February 6th Article... Read the court decision
Read the full story...
Reprinted courtesy of

Congratulations to Haight’s 2021 Super Lawyers San Diego Rising Stars

May 03, 2021 — Catherine M. Asuncion, Arezoo Jamshidi & Michael C. Parme - Haight Brown & Bonesteel LLP
Haight congratulates partners Michael Parme and Arezoo Jamshidi and associate Catherine Asuncion who were selected to the 2021 San Diego Super Lawyers Rising Stars list. Reprinted courtesy of Catherine M. Asuncion, Haight Brown & Bonesteel LLP, Arezoo Jamshidi, Haight Brown & Bonesteel LLP and Michael C. Parme, Haight Brown & Bonesteel LLP Ms. Asuncion may be contacted at casuncion@hbblaw.com Ms. Jamshidi may be contacted at ajamshidi@hbblaw.com Mr. Parme may be contacted at mparme@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES