CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Ruling Dealing with Constructive Changes, Constructive Suspension, and the Implied Covenant of Good Faith and Fair Dealing

January 22, 2024 — David Adelstein - Florida Construction Legal Updates
A dispute pending in the Armed Services Board of Contract Appeals (ASBCA) dealt with interesting legal issues on a motion to dismiss. See Appeals of McCarthy Hitt-Next NGA West JV, ASBCA No. 63571, 2023 WL 9179193 (ASBCA 2023). The dispute involves a contractor passing through subcontractor claims due to impacts caused by the COVID-19 pandemic and the government’s response to the pandemic. More particularly, the claim centers on the premise that the government “failed to work with [the contractor] in good faith to develop a collaborative and cooperative approach to manage and mitigate the impacts and delays arising from the COVID-19 pandemic.” See Appeals of McCarthy Hitt. The contractor (again, submitting pass through claims from subcontractors) claimed: (a) constructive changes to the contract entitling it to an equitable adjustment under the Changes clause of Federal Acquisition Regulation (F.A.R.) 52.243-4; (b) construction suspensions of the contractor’s work entitling it to an equitable adjustment under the Suspensions of Work clause of F.A.R. 52-242-14; and (c) the government breached the implied covenant of good faith and fair dealing. Each of these legal issues and theories will be discussed below because they are need-to-know legal issues. Keep these legal issues in mind, and the ASBCA’s ruling on the motion to dismiss as its analysis may demonstrate fruitful in other applications. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Insurer Granted Summary Judgment on Denial of Construction Defect Claim

January 27, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The court granted the insurer's motion for summary judgment, confirming there was no duty to defend or indemnify a construction defect claim against the insured. Fontaine Bros. v. Acadia Ins. Co., 2019 U.S. Dist. LEXIS 148056 (D. Mass. Aug. 29, 2019). The City of Worcester contracted with Fontaine Brothers, Inc. to install a new ice refrigeration system at the City's indoor ice rink. After construction, the condensers in two chiller units eroded and stopped operating. The City sued Fontaine for the costs of leasing temporary chillers and installing new ones. The City alleged that Fontaine installed condensers with carbon steel tubes instead of contractually required stainless stell tubes.Further, Fontaine and its subcontractors did not adequately maintain the condensers, in breach of the contract. Fontaine's insurer, Acadia Insurance Company, denied coverage. Fontaine sued Acadia. The court noted that the City's complaint plainly alleged faulty workmanship by Fontaine. However, the City's complaint did not allege that Fontaine intended the condensers to corrode and left open the possibility that Fontaine was unaware of any potential problem or did not foresee the corrosion likely to result from the use of carbon steel components or the maintenance work being done by its subcontractor. Therefore, the Cit's complaint did not foreclose the possibility that the corrosion resulting from Fontaine's alleged faulty workmanship and maintenance might be shown to be an unforeseen or unintended consequence of reckless or negligent conduct. Accordingly, it was possible that there was an occurrence under the policy language. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Hawaii Supreme Court Finds Excess Can Sue Primary for Equitable Subrogation

July 30, 2015 — Tred R. Eyerly – Insurance Law Hawaii
In responding to a certified question from the U.S. Distric Court, the Hawaii Supreme Court determined that an excess carrier can sue the primary carrier for failure to settle a claim in bad faith within primary limits. St. Paul Fire & Marine Ins. Co. v. Libery Mut. Ins. Co., 2015 Haw. LEXIS 142 (Haw. June 29, 2015). St. Paul, the excess carrier, and Liberty Mutual, the primary carrier, issued polices to Pleasant Travel Service, Inc. The primary policy covered up to $1 million. Pleasant Travel was sued for damages resulting from an accidental death. St. Paul alleged that Liberty Mutual rejected multiple pretrial settlement offers within the $1 million primary policy limit. A trial resulted in a verdict of $4.1 million against Pleasant Travel. The action settled for a confidential amount in excess of the Liberty Mutual policy limit. St. Paul paid the amount in excess. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

'Major' Mass. Gas Leak Follows Feds Call For Regulation Changes One Year After Deadly Gas Explosions

October 21, 2019 — Johanna Knapschaefer - Engineering News-Record
A natural gas leak in explosive range forced Lawrence, Mass. residents to evacuate their homes early on Sept. 27, according to electric utility National Grid, which cut power to more than 1,300 customers to avoid another disaster like last year's natural gas explosions and fires in Lawrence and two other towns north of Boston. The leak came just days after federal officials called for changes to national pipeline regulations as they released a final report on the causes of the Sept. 13, 2018, disaster. Read the court decision
Read the full story...
Reprinted courtesy of Johanna Knapschaefer, ENR
ENR may be contacted at ENR.com@bnpmedia.com

---

A Recession Is Coming, But the Housing Market Won't Trigger It

June 12, 2023 — Edward Harrison - Bloomberg
One big reason to continue to believe this is no 2008-style financial crisis in the making is the housing market, which has held up well. That means, we’re more likely to experience a garden-variety recession, and I think it will happen sometime later this year. Why this isn’t another 2008-style crisis Residential property was famously the trigger for a cataclysmic global financial crisis a decade and a half ago. That’s because residential property is one of the principal assets of the middle classes across the globe. And it’s a leveraged investment to boot because of the money borrowed through mortgages. That makes large and pervasive house-price declines toxic for the economy. But not that many people are worrying about house prices today. So I thought I’d take a breather from the doom and gloom surrounding commercial real estate, banks and the debt ceiling to focus on house prices and why they aren’t worrying us this go round. And I’ll use one of the pricier markets, the UK, as a first example. Read the court decision
Read the full story...
Reprinted courtesy of Edward Harrison, Bloomberg

---

Another Municipality Takes Action to Address the Lack of Condominiums Being Built in its Jurisdiction

March 12, 2015 — Heather M. Anderson – Higgins, Hopkins, McLain & Roswell, LLC
Whether you are in the market to downsize or are looking to be a first time home buyer, you have likely noticed that your housing options in Colorado have become extremely limited over the course of the last several years. If you are a contractor and have worked on multi-family projects in the recent past, you know why the housing options are limited in the State of Colorado. In the past two years, there have been studies commissioned and articles published in local periodicals investigating the extreme slowdown seen in the construction of owner-occupied multi-family housing, namely condominiums and townhomes. Those of us involved in and with the construction industry are intimately familiar with the lengthy, complicated, and incredibly expensive construction defect litigation that has plagued multi-family construction in the State of Colorado and brought it to a virtual halt. And now, local municipalities and elected officials are starting to take notice. Most recently, the City of Lone Tree passed Ordinance No. 15-01, to become effective on April 1, 2015. According to the City of Lone Tree, Ordinance No. 15-01 is “aimed at encouraging the development of owner-occupied, multi-family residential projects through the adoption of regulations designed to balance the risk and exposure to builders and developers of such projects, while still protecting homeowners from legitimate construction defect claims.” Read the court decision
Read the full story...
Reprinted courtesy of Heather M. Anderson, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Anderson may be contacted at Anderson@hhmrlaw.com

---

Should I Stay or Should I Go? The Supreme Court Says “Stay”

June 10, 2024 — Brendan J. Witry - The Dispute Resolver
In the construction industry, arbitration is a frequently agreed-upon and utilized dispute resolution method. The Federal Arbitration Act (the “FAA”), 9 U.S.C. 1, et seq., provides the underpinning and framework for how courts should handle litigation in connection with arbitration agreements. Where a party asserts that a claim brought in court should be subject to arbitration, Section 3 of the FAA provides that the action should be stayed. However, some courts have entertained a party’s request to dismiss a suit where the claim is subject to an arbitration agreement, creating a circuit split in the federal appeals courts. In Smith v. Spizzirri, 2024 WL 2193872, issued on May 16, 2024, the Supreme Court held that, absent some other defect (such as the lack of personal or subject matter jurisdiction), Section 3 of the FAA requires a court which finds a claim is subject to an arbitration must stay the lawsuit during the arbitration proceedings rather than dismissing the action.[1] In so doing, the Court addressed a question that for years it left unanswered. While most Circuits held, prior to Smith, that Section 3 requires a court to stay the litigation pending an arbitral award; the First, Fifth, Eighth, and Ninth Circuits each held that a court could dismiss an action in lieu of staying. In Smith, both parties acknowledged the underlying claims were arbitrable, but when the district court compelled arbitration, the court dismissed the action rather than staying the court proceedings. The Ninth Circuit (relying on its prior precedent) affirmed, with two judges noting that the Ninth Circuit’s approach was incorrect. The Supreme Court granted certiorari and reversed. Read the court decision
Read the full story...
Reprinted courtesy of Brendan J. Witry, Laurie & Brennan LLP
Mr. Witry may be contacted at bwitry@lauriebrennan.com

---