Fairfield Connecticut Building Expert Directory

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Congratulations to BWB&O for Ranking #4 in Orange County Business Journal’s 2023 Book of Lists for Law Firms!

April 10, 2023 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is excited to announce that Orange County Business Journal has ranked our firm as a top 4 law firm in the 2023 Book of Lists! BWB&O continues to grow and strives to provide a consistently excellent work product and solution-oriented approach to our clients’ legal issues, coupled with hiring, and retaining diverse and outstanding lawyers, all while providing an outstanding work life balance/integration. We foster a culture that embraces family, friendship, and fun while also supporting individual growth. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Real Estate & Construction News Roundup (4/10/24) – Hotels Integrate AI, Baby-Boomers Stay Put, and Insurance Affects Housing Market

May 06, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, DOT’s major grant programs, proptech’s solution to climate change risks, mortgage-locked sellers put their homes on the market, and more!

The U.S. Department of Transportation opened applications for four major grant programs for infrastructure and transportation projects, totaling about $7.5 billion. (Dan Zukowski, Construction Dive)
Hotel brands are integrating AI into their operational processes — such as virtual concierges — and working toward sustainability initiatives that accelerate more environmentally friendly practices industry-wide. (Noelle Mateer, Hotel Dive)
The housing market will soon exit its slowdown, thanks to a growing number of mortgage-locked sellers opting to put their homes on the market, according to JPMorgan Asset Management. (Jennifer Sor, Business Insider)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

New York Preserves Subrogation Rights

September 06, 2023 — Lian Skaf - The Subrogation Strategist
The insurer’s right of subrogation is equitable in nature, even if not based in contract. However, since the insurer steps into the shoes of its insured and is limited to the rights of its insured, an integral part of the investigation process is determining what rights the insured has. Whether or not the insured can settle with the tortfeasor and that whether the settlement would also apply to the subrogated carrier is a question the Supreme Court of New York, a trial court, recently addressed. In Utica First Ins. Co. v. Homeport I LLC, et al., No. 150448/2022, 2023 N.Y. Misc. LEXIS 3087 (N.Y. Sup. Ct.), the plaintiff insurance carrier’s insured, SI Waterfront Management Inc. (SI Waterfront), owned and operated a restaurant called Wynwood at 24 Navy Pier Court in Staten Island, New York. The owner of the property was Homeport I LLC (Homeport). Significant construction work pertaining to plumbing and draining lines at the property was done by Ironstate Holdings, LLC (Ironstate), the plumbing portion of which was conducted by subcontractor Claire Construction Corp. (Claire). As a result of the construction work, on June 8, 2021, SI Waterfront allegedly sustained property damage from flooding. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

Know What’s Under Ground and Make Smarter Planning Decisions

July 29, 2019 — Aarni Heiskanen - AEC Business
A Finnish experimentation project developed a framework for classifying ground conditions for building and infrastructure construction. It will help anticipate the future cost of foundation laying during the early stages of city planning. The ground conditions of an area can have a substantial effect on the costs and the environmental impacts of constructing buildings and infrastructure. At early stage, urban designers don’t typically have enough data to make smart decisions about zoning in that respect as obtaining that data is time-consuming and hence also costly. Consequently, an experimentation project called MAKU-digi: Making the costs of land use visible devised a method for automating the analysis of ground conditions. I had the pleasure of interviewing Juha Liukas, Lead Advisor at Sitowise, and Hilkka Kallio, Geologist at Geological Survey of Finland (GTK), about the project. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Construction Contract Clauses That May or May Not Have Your Vote – Part 3

November 23, 2016 — Garret Murai – California Construction Law Blog
Scope, time and cost provisions may be the most important clauses in your construction contract but they’re not the only ones which can impact your bottom line. The third in a multi-part series, here are some other important construction contract clauses that may determine whether you come out a winner.

Provision: Supervisory Personnel, Employees, and Authority to Bind Provisions

Typical Provision: ”At all times during performance of the Work, Subcontractor shall have at the job site a competent supervisor approved by Owner. Subcontractor’s supervisor shall be deemed a representative of Subcontractor and all communications given to Subcontractor’s supervisor shall be as binding as if such communications were given to Subcontractor. Should Contractor object to Subcontractor’s supervisor’s presence at the job site, or the presence at the job site, or the presence at the job site of any other employee or agent of Subcontractor or any employee or agent of Subcontractor of Subcontractor, Subcontractor shall cause such persons to be replaced immediately as directed by Contractor.”
What it Means: Higher-tiered parties have a legitimate interest in ensuring that only competent individuals are allowed to perform work on a project and in ensuring that there are peaceable relations at a job site. Higher-tiered parties also have an interest in ensuring that directives and agreements made and reached in the field are followed. However, it is unreasonable for higher-tiered party or to require that such personnel be able to bind that lower-tiered party to agreements best decided by others.
What You Can Do: Lower-tiered parties should seek to include language which provides that only “reasonable” changes to personnel are allowed and, as necessary, limit by category or issue the types of items on-site personnel can bind the lower-tiered party to.

Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Miller Act Claim for Unsigned Change Orders

June 30, 2016 — David Adelstein – Florida Construction Legal Updates
Contracts and subcontracts often contain language that requires change orders to be in writing and that no change order work shall be performed unless agreed to in advance in a signed change order. Oftentimes change order work is performed but the parties have not complied with the strict requirements of the contract by having this work signed off by the parties in a change order prior to the commencement of the work. Well, can such requirements be waived? If so, can such change orders form the basis of a Miller Act claim? The answer is generally yes provided the party arguing waiver can support the waiver with evidence (that the other party voluntarily relinquished the requirements through its course of conduct / actions). Read the court decision
Read the full story...
Reprinted courtesy of David M. Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Former Owner Not Liable for Defects Discovered After Sale

January 29, 2014 — Beverley BevenFlorez-CDJ STAFF
In a “tentative decision” by Judge Steven Kleifield, Mark Van Peebles and a real estate company have been exonerated “of any liability in a lawsuit involving the sale of the actor’s Playa del Rey condominium, whose buyer says he discovered mold and a flooring defect,” according to the Patch. However, the judge “ordered the Waterfront Homeowners Association to pay Adel Bebawy $26,217 for repair work on the floor and the kitchen as well as civil penalties for not keeping him informed about board meetings.” The suit began in 2009 after Bebawy alleged “he discovered the floor had a severe slope and that there was significant mold in a bathroom,” reported the Patch. Kleifield, however, stated that the mold didn’t affect the condo’s value. Furthermore, Kleifield wrote that the sloping didn’t become an issue until Bebawy began installing a hardwood floor. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES