Fairfield Connecticut Building Expert Directory

City of Pawtucket Considering Forensic Investigation of Tower

October 08, 2014 — Beverley BevenFlorez-CDJ STAFF
Pawtucket, Rhode Island’s mayor, Donald Grebien, has asked their city council to approve “a forensic investigation of the Pawtucket City Hall tower to determine whether the city should sue the contractor that repaired it eight years ago,” the Valley Breeze reported. Back in 2011, “city officials had been unable to locate a signed contract for the tower project as they sought to hold NER responsible for continued leaking into the structure just five years after the company's $3 million renovation project was complete,” according to the Valley Breeze. “The costs of that project grew to $4.6 million once interest was factored in.” Documents have recently been discovered that Grebien believes may open the possibility to sue NER. Read the court decision
Read the full story...
Reprinted courtesy of

State Audit Questions College Construction Spending in LA

August 17, 2011 — CDJ STAFF

A state audit of the Los Angeles Community College District found many problems with their construction spending. Their report, as described in the Los Angeles Times, found construction money spent for other purposes, such as promotional photography and public relation tours, $28.3 million spent on projects that were later cancelled, and oversight committees that provided no oversight.

Earlier this year, the LA Times ran a series of articles detailing problems with the Los Angles Community College District’s construction program. The LA Times reported that the State Controller’s audit reached many of the same conclusions.

The Community College District disputed the findings.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

New York Restrictions on Flow Through Provision in Subcontracts

August 14, 2023 — Bill Wilson - Construction Law Zone
Most subcontracts include a flow through provision (also called flow down and incorporation clauses) stating that the subcontractor and contractor are bound by the same obligations as set forth in the prime contract between the contractor and owner. Many jurisdictions interpret such provisions narrowly, as illustrated in a recent case out of New York. In Amerisure Insurance Company v. Selective Insurance Group, Inc., 2023 WL 3311879, the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s interpretation of a flow through clause in a construction subcontract. The Amerisure case involved a dispute over insurance coverage for a personal injury to a subcontractor’s employee on a construction project. The owner of the project sought defense and indemnity from the general contractor (GC) and its insurance company, who in turn sought coverage for the owner as an additional insured under the subcontractor’s policy. The GC based its argument for coverage on the flow through provision in the subcontract. The prime contract required the GC to procure commercial liability insurance including the owner as an additional insured for claims caused by the GC’s negligent acts or omissions. The subcontract likewise required the subcontractor to procure commercial general liability insurance but required only that the GC be named as an additional insured. However, the subcontract also included a flow through clause, binding the subcontractor to the terms of the prime contract and assuming toward the GC all the obligations and responsibilities that the GC assumed toward the owner. However, the subcontract did not expressly require that the subcontractor name the owner as an additional insured, and in order for the owner to qualify as an additional insured under the subcontractor’s insurance policy, the subcontractor must have agreed in the subcontract to name the owner as an additional insured. Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

No Coverage for Additional Insured for Construction Defect Claim

July 02, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Seventh Circuit affirmed the district court's grant of summary judgment to the insurers, finding there was no coverage for the additional insured on a construction defect claim. St. Paul Guardian Ins. Co. v. Walsh Construction. Co., 2024 U.S. App. LEXIS 10285 (7th Cir. April 29, 2024). The City of Chicago hired Walsh Construction Company as general contractor for the Facade and Circulation Enhancement (FACE) project at O'Hare International Airport. The FACE project involved building and installing a new canopy for Terminals 1, 2 and 3. The project also called for the construction of a steel and glass curtain wall that would be integrated with the curtain wall at Terminals 2 and 3. Walsh contracted with Carlo Steel Corporation to manufacture the steel and curtain wall. Carlo, in turn, subcontracted with LB Steel, LLC to manufacture and install the steel elements of the wall, which included steel columns, hammer heads and box girders. The subcontract between Carlo and LB Steel included an indemnity provision that required LB Steel to indemnify Carlo and Walsh for any property damage resulting from LB Steel's negligent performance. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Protecting Your Business From Liability Claims Stemming From COVID-19 Exposure

June 01, 2020 — Andrew Hamelsky, Jenifer Scarcella & Joshua Tumen - White and Williams
Businesses of every nature – including grocery stores, banks, daycares, gyms and restaurants – may face increasing liability claims from customers and third parties claiming to have been exposed to the novel coronavirus, or COVID-19, while at their location. The novel virus raises issues as to whether businesses have a heightened duty of care to their customers, and what type of exposure businesses face if a customer claims to have been exposed to COVID-19 while at their premises. Recently, a lawsuit was filed against Princess Cruise lines for gross negligence in allowing passengers to be exposed to COVID-19 on a cruise ship. The lawsuit alleges that the cruise ship was allowed to go out to sea knowing that it was infected from two previous passengers who came down with symptoms of COVID-19. It further claims that the passengers were not warned of the potential exposure either before or after they boarded the ship. In other news reports around the country, business owners have reported taking extraordinary precautions to prevent customers’ risk of contracting COVID-19. For example, one grocery store recently reported that it discarded $35,000 worth of food after a customer coughed on fresh produce. Reprinted courtesy of White and Williams LLP attorneys Andrew Hamelsky, Jenifer Scarcella and Joshua Tumen Mr. Hamelsky may be contacted at hamelskya@whiteandwilliams.com Ms. Scarcella may be contacted at scarcellaj@whiteandwilliams.com Mr. Tumen may be contacted at tumenj@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

China Construction Bank Sued in US Over Reinsurance Fraud Losses

June 21, 2024 — Robert Burnson - Bloomberg
China Construction Bank Corp., the nation’s third-largest commercial lender, was accused in a US lawsuit of enabling a massive fraud in the reinsurance industry that left companies with “monumental losses” and sinking stock prices. The bank allowed employees to conspire with Israeli insurance startup Vesttoo Ltd. to sell reinsurance policies that weren’t real, according to a complaint filed late Thursday by the Porch Group in Manhattan federal court. Vesttoo filed for Chapter 11 bankruptcy in August after it was accused of using some $2 billion of fraudulent letters of credit. The Porch Group said that its unit Homeowners of America Insurance Co. lost tens of millions of dollars when its purported $300 million letter of credit proved worthless. “Not only did HOA incur colossal losses, but news of its exposure to the fraud perpetrated by Vesttoo and CCB shocked the market and imposed severe losses on Porch Group’s shareholders as its stock price plummeted,” according to the suit. Read the court decision
Read the full story...
Reprinted courtesy of Robert Burnson, Bloomberg

Little Known Florida Venue Statue Benefitting Resident Contractors

June 30, 2016 — David Adelstein – Florida Construction Legal Updates
When it comes to venue, there is a rather unknown venue statute that benefits resident contractors, subcontractors, and suppliers working on Florida projects. This statute, Fla. Stat. s. 47.025, states: Any venue provision in a contract for improvement to real property which requires legal action involving a resident contractor, subcontractor, sub-subcontractor, or materialman, as defined in part I of chapter 713, to be brought outside this state is void as a matter of public policy. To the extent that the venue provision in the contract is void under this section, any legal action arising out of that contract shall be brought only in this state in the county where the defendant resides, where the cause of action accrued, or where the property in litigation is located, unless, after the dispute arises, the parties stipulate to another venue. Read the court decision
Read the full story...
Reprinted courtesy of David M. Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES