Construction Bidding for Success
May 22, 2023 —
The Hartford Staff - The Hartford InsightsWhen construction companies develop a history of successful projects, they often consider bidding on larger projects. However, larger projects can carry greater risks.
If your company has successfully completed numerous $10 million projects and is considering a bid on a $100 million project, there are several factors to consider before submitting a proposal. That is because bidding on the wrong project could potentially put you out of business.
“When a contractor bids a larger project, there is a greater financial risk,” says Tim Holicky, a senior executive underwriter at The Hartford. There are more subcontractors to manage and additional materials to purchase, which all leads to greater financial risk.
Read the court decisionRead the full story...Reprinted courtesy of
The Hartford Staff, The Hartford Insights
Look to West Africa for the Future of Green Architecture
May 16, 2022 —
Kriston Capps - BloombergIn 2014, a crowd of demonstrators stormed Burkina Faso’s National Assembly building, setting it ablaze and ending the nearly 30-year rule of President Blaise Compaoré.
A year later, Burkenabè architect Diébédo Francis Kéré was asked to imagine a new parliamentary building — one that would reflect a more democratic future for the West African nation. Kéré conceived a six-story stepped pyramid that slopes up gently from the ground, inviting citizens to gather, climb and take in views of the capital city, Ouagadougou. The ruins of the former parliament building next door would be transformed into a rainwater-collecting memorial park.
The project remains a ways off: Burkina Faso continues to struggle with political unrest, including a coup d’état in January 2022. But Kéré’s fast-growing prominence may improve the odds that his vision will eventually materialize. In March, he became the first African architect to win the Pritzker Architecture Prize, the design field’s top honor.
Read the court decisionRead the full story...Reprinted courtesy of
Kriston Capps, Bloomberg
Tips for Drafting Construction Contracts
May 04, 2020 —
Stuart Rosen - Construction ExecutiveWhen negotiating a construction contract, a contractor and its advisers must first determine the areas of greatest concern.
For example, if the contractor believes that the drawings that were prepared by the architect and other design professionals are deficient, the contractor may want to reference those deficiencies in the contract. The contractor should emphasize that it is not responsible for the drawings and to the extent the project schedule is extended to allow the parties to address such issues with the drawings, the contractor would be entitled to additional compensation.
This article provides contractors with additional tips, with a broad focus on project delays, for their protection when negotiating and drafting construction contracts, and helps contractors understand the rationale for such tips to better prepare contractors in such negotiations.
Contractor’s liability to the owner for delay damages
It is imperative that the contract include a waiver of claims for consequential damages. AIA Document A201TM – 2017 includes such a waiver, which provides, in pertinent part, “The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this Contract … This mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14.”
Reprinted courtesy of
Stuart Rosen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Rosen may be contacted at
srosen@proskauer.com
Florida’s Supreme Court Resolves Conflicting Appellate Court Decisions on Concurrent Causation
December 21, 2016 —
Afua S. Akoto – Saxe Doernberger & Vita, P.C.The Supreme Court of Florida kicked off December with an opinion that determined which theory of recovery applies when multiple perils combine to create a loss, and at least one of those perils is excluded by the terms of a policy. In Sebo v. American Home Assurance Company, Inc.,1 the court resolved the conflict between the Florida Appellate Courts for the Second District and the Third District and declared the concurrent cause doctrine (CCD) as the more applicable theory of recovery over the efficient proximate cause doctrine (EPC).
The underlying dispute concerned damage to a home Sebo purchased in Naples, Florida in April 2005. The American Home Assurance Company (AHAC) insured the home under a manuscript policy specifically created for the property with limits of over eight million dollars. In May 2005, Sebo discovered major water leaks in the main foyer, master bathroom, exercise room, piano room, and living room of the home. In August, paint fell off the walls after it rained, and it became clear that the house suffered from major design and construction defects. When Hurricane Wilma struck in October, the house was further damaged by rain water and high winds, and was eventually demolished.
Read the court decisionRead the full story...Reprinted courtesy of
Afua S. Akoto, Saxe Doernberger & Vita, P.C.Ms. Akoto may be contacted at
asa@sdvlaw.com
Let it Shine: California Mandates Rooftop Solar for New Residential Construction
May 16, 2018 —
Garret Murai - California Construction Law BlogCalifornia. Birthplace of the Frisbee, skateboard, television, canned tuna and (yup) fortune cookies has added another first to the list: California has become the first state in the nation to mandate the use of solar panels for new residential construction.
On May 9, 2018, the California Energy Commission (CEC) unanimously approved the state’s 2019 Building Energy Efficiency Standards. The 2019 Energy Efficiency Standards update the California Building Standards Codes found at Title 24 of the California Code of Regulations which are updated every three years. The 2019 Energy Efficiency Standards go into effect on January 1, 2020.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
New York Considers Amendments to Construction Industry Wage Laws that Would Impose Significant Burden Upon Contractors
August 04, 2021 —
Richard W. Brown & Michael D. Angotti - Saxe Doernberger & Vita, P.C.A bill that would amend the the wage and hour requirements of the New York Labor Law was recently passed by the New York State Legislature and is expected to be signed by Governor Cuomo. Bill Number S2766C (the “Bill”) is intended to protect construction workers against wage theft. However, it places a heavy burden on contractors to police the payroll practices of its downstream subcontractors and exposes them to potentially significant liability for the wage and hour violations of their subcontractors.
The proposed Bill would make a contractor or upstream subcontractor jointly and severally liable for any wages owed to employees of their subcontractors. The Bill allows for a private right of action for such subcontractor’s employee (or such employee’s representative) to bring a civil or administrative action seeking payment of unpaid wages owed pursuant to Section 198 of the New York Labor Law. In such an action against a subcontractor for unpaid wages, the contractor or upstream subcontractor is not only jointly and severally liable for any unpaid wages, but also for the prevailing claimant’s reasonable attorney fees, prejudgment interest, and, absent a good faith defense, liquidated damages equal to the amount of the wages owed.
Reprinted courtesy of
Richard W. Brown, Saxe Doernberger & Vita, P.C. and
Michael D. Angotti, Saxe Doernberger & Vita, P.C.
Mr. Brown may be contacted at RBrown@sdvlaw.com
Mr. Angotti may be contacted at MAngotti@sdvlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Kahana Feld Partner Noelle Natoli Named President of Women Lawyers Association of Los Angeles
October 07, 2024 —
Linda Carter - Kahana FeldLOS ANGELES – Sep. 16, 2024 – Kahana Feld is pleased to announce that partner Noelle Natoli was recently installed as the 2024-25 president of the Women Lawyers Association of Los Angeles (WLALA).
The mission of WLALA is to promote the full participation in the legal profession of women lawyers and judges from diverse perspectives and backgrounds, maintain the integrity of our legal system by advocating principles of fairness and equality, and improve the status of women by supporting their exercise of equal rights.
Natoli is a partner based in Kahana Feld’s Los Angeles office and focuses her civil trial practice on the defense of both insurers and insureds primarily in the areas of elder abuse, transportation defense, and general liability. Her clients include individuals, family-owned businesses, and national corporations. Natoli also chairs the Diversity & Inclusion Committee for the Trucking Industry Defense Association and serves as a board member of the National Conference of Women’s Bar Associations.
Read the court decisionRead the full story...Reprinted courtesy of
Linda Carter, Kahana FeldMs. Carter may be contacted at
lcarter@kahanafeld.com
When Do You Call Your Lawyer?
October 08, 2014 —
Craig Martin – Construction Contractor AdvisorThe National Association of Home Builders recently conducted a survey asking its members about the legal issues they faced in the last 12 months and whether they consulted their attorney to deal with the problem. Below are some highlights of the survey.
Legal Issue % of Homebuilders % Contacted Counsel
Warranty/call back claims 34% 51%
Contract disputes 22% 84%
Defective Install/Workmanship 20% 83%
OSHA Issues 13% 33%
CGL Coverage Questions 11% 73%
Construction Liens 10% 57%
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com