Courthouse Reporter Series - How to Avoid Having Your COVID-19 Expert Stricken
September 25, 2023 —
Andrew G. Vicknair - The Dispute ResolverExpert witnesses play a key role in litigation, especially when dealing with construction issues. The testimony of an expert at trial can be a deciding factor in helping persuade a jury or judge in your client’s favor. Thus, it is imperative that your expert’s opinion meet the proper legal standard.
In Polaris Engineering, Inc. v. Texas International Terminals, LTD, the United States District Court for the Southern District of Texas reiterated the importance of an expert’s opinion complying with the applicable legal standards governing expert testimony. 2023 U.S. Dist. LEXIS 109413 (S.D. Tex. June 26, 2023).
The legal standard at issue in Polaris was Rule 702 of the Federal Rules of Evidence. Polaris involved a suit arising from a contract related to the design, engineering, and construction of a terminal and crude-oil processing facility for Texas International Terminals in Galveston, Texas. There were four separate contracts that governed the Project. One of the contracts governed the creation of the 50,000 barrel per day crude processing unit. Because the parties wanted to move quickly, they agreed to certain assumptions about the Project and specifically designed a change order process whereby the price and schedule could be adjusted if the agreed upon assumptions were incorrect.
Read the court decisionRead the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
Vallagio v. Metropolitan Homes: Colorado Supreme Court Upholds Declarant Consent Provision to Amend Arbitration Out of Declarations
June 15, 2017 —
Jean Meyer - Colorado Construction LitigationOn June 5, 2017, the Colorado Supreme Court announced the Vallagio at Inverness Residential Con. Ass’n v. Metro. Homes, Inc., No. 15SC508, 2017 CO 69 (Colo. June 5, 2017) decision. In short, the Colorado Supreme Court upheld the validity of declarant “consent-to-amend” provisions and expressly held that claims under the Colorado Consumer Protection Act are arbitrable.
By way of background, the Vallagio at Inverness Residential Condominiums were developed by Metro Inverness, LLC, (“Declarant”) which also served as the declarant for its homeowners association. Metropolitan Homes was Metro Inverness’ manager and the general contractor on the project. Greg Krause and Peter Kudla served as declarant-appointed members of the Association’s board during the period of declarant control.
When it set up the Association, the Declarant included within the Association’s declaration a mandatory arbitration provision specifically for construction defect claims. This provision stated that it “shall not ever be amended without the written consent of Declarant and without regard to whether Declarant owns any portion of the Real Estate at the time of the amendment.”
Read the court decisionRead the full story...Reprinted courtesy of
Jean Meyer, Higgins, Hopkins, McLain & Roswell, LLCMr. Meyer may be contacted at
meyer@hhmrlaw.com
Follow Up on Continental Western v. Shay Construction
March 28, 2012 —
Brady Iandiorio, Higgins, Hopkins, McLain & Roswell, LLCWriting in Construction Law Colorado, Brady Iandiorio revisits the case Continental Western v. Shay Construction. He promises to continue to follow cases dealing with Colorado HB 10-1394.
Recently the Court ruled on two Motions to Reconsider filed by Defendants Milender White and Shay Construction.
Procedurally, the Motions to Reconsider were ruled on by the Honorable William J. Martinez, because the day after the motions were filed the action was reassigned to Judge Martinez. In the short analysis of the Motion to Reconsider, the court leaned on Judge Walker D. Miller’s ruling on the summary judgment and his analysis of the (j)(5) and (j)(6) exclusions.
As a quick refresher regarding the grant of summary judgment, Judge Miller agreed with Continental Western’s argument that the asserted claims were excluded under the “damage to property” exclusion. The policy’s exclusions state: “(j) Damage to Property . . . (5) that particular part of real property on which you or any contractors or subcontractors working directly or indirectly on your behalf are performing operations, if the ‘property damage’ arises out of those operations; or (6) that particular part of any property that must be restored, repaired or replaced because ‘your work’ was incorrectly performed on it.” Judge Miller found that both exclusions (j)(5) and (6) applied to both Shay’s allegedly defective work.
Read the full story…
Reprinted courtesy of Brady Iandiorio of Higgins, Hopkins, McClain & Roswell, LLC. Mr. Iandiorio can be contacted at iandiorio@hhmrlaw.com.
Read the court decisionRead the full story...Reprinted courtesy of
Insurer Not Entitled to Summary Judgment on Construction Defect, Bad Faith Claims
October 07, 2019 —
Tred R. Eyerly - Insurance Law HawaiiThe federal district court denied the insurer's motion for summary judgment seeking to establish there was no coverage for construction defect claims and for bad faith. Country Mut. Ins. Co. v. AAA Constr. LLC, 2019 U.S. Dist. LEXIS 115935 (W.D. Okla. July 12, 2019).
Jeffrey and Tammy Shaver entered two contracts with AAA Construction for the construction of a garage and of a barn on their property. After construction was completed, the Shavers sued AAA Construction for building the garage over two high-pressure gas pipelines and the utility easements associated with them. They alleged AAA Construction was negligent for constructing over a working utility line. AAA Construction's insurer, Country Mutual Insurance Company (CMIC) denied coverage because the alleged faulty workmanship of AAA Construction did not constitute an "occurrence" under the policy.
CMIC sued AAA Construction for a declaratory judgment that it had no duty to defend or indemnify. CMIC moved for summary judgment.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Recovering Unabsorbed Home Office Overhead Due to Delay
May 30, 2022 —
David Adelstein - Florida Construction Legal UpdatesIn the
preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs.
Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.
To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period.
CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Three's a Trend: Second, Fourth and Ninth Circuits Uphold Broad "Related Claims" Language
February 23, 2016 —
Greg Steinberg – White and Williams LLPThe hallmark of a claims-made insurance policy is that the policy only provides coverage for claims that are “first made” during the policy period. As noted by the Texas Supreme Court, “for the insurer, the inherent benefit of a claims-made policy is the insurer's ability to close its books on a policy at its expiration and thus to attain a level of predictability unattainable under standard occurrence policies.”[1]
To ensure this “level of predictability,” claims-made insurance policies contain provisions stating that all “Related Claims” will be treated as a single claim deemed first made at the time the earliest of such claims was made. The “Related Claims” provision is an issue that comes up time and again – claims can span years, especially in the context of regulatory investigations, which often culminate in enforcement proceedings and litigation. This inevitably leads to disputes regarding whether later claims can be related back to the earlier claim, an issue that becomes even thornier when different insurers participate on different policy years.
Over time, case law on “Related Claims” has been mixed and somewhat inconsistent, with each case tending to hinge on its own unique set of facts, making it difficult to identify a clear standard for determining whether claims are related. However, three recent decisions out of the Second, Fourth and Ninth Circuits show that courts are increasingly deferring to the plain language of the policy and applying these provisions broadly.
Read the court decisionRead the full story...Reprinted courtesy of
Greg Steinberg, White and Williams LLPMr. Steinberg may be contacted at
steinbergg@whiteandwilliams.com
Can a Home Builder Disclaim Implied Warranties of Workmanship and Habitability?
August 30, 2021 —
Kevin J. Parker - Snell & Wilmer Real Estate Litigation BlogIn a recent Arizona Court of Appeals case, Zambrano v. M & RC II LLC, 2021 WL 3204491 (7/29/2021), the Court of Appeals addressed the question whether a home builder’s attempt to disclaim implied warranties of workmanship and habitability was effective. In that case, the buyer initialed the builder’s prominent disclaimer of all implied warranties, including implied warranties of habitability and workmanship. After the purchase, the buyer sued the builder, claiming construction defects. The builder moved for summary judgment, seeking enforcement of the disclaimer of warranties. The trial court granted the builder’s motion for summary judgment, thereby enforcing the disclaimers. The buyer appealed.
The Court of Appeals addressed the question whether – as a matter of public policy – the implied warranties of workmanship and habitability were waivable. The Court of Appeals started the analysis by noting that the Arizona Supreme Court had, in a 1979 case, judicially eliminated the caveat emptor rule for newly built homes. The court further noted the long history of cases detailing the public policy favoring the implied warranties. But the court also noted the competing public policy of allowing parties to freely contract; explaining that the usual and most important function of the courts is to maintain and enforce contracts rather than allowing parties to escape their contractual obligations on the pretext of public policy.
Read the court decisionRead the full story...Reprinted courtesy of
Kevin J. Parker, Snell & WilmerMr. Parker may be contacted at
kparker@swlaw.com
Pass-Through Subcontractor Claims, Liquidating Agreements, and Avoiding a Two-Front War
April 26, 2021 —
Bradley Sands, Jones Walker LLP - ConsensusDocsSubcontractor claims happen. When those subcontractor claims are prompted by owner actions or responsibilities, the general contractor must always be vigilant to plan for and work to avoid a two-front war in which the general contractor is pushing the owner for recovery while at the same time disputing the subcontractor’s entitlement.
Cooperation between the general contractor and the subcontractor and avoiding that two-front war can be accomplished through pass-through claims and ideally liquidating agreements. A pass-through claim is a claim by the subcontractor who has suffered damages by the owner with whom it has no contract, presented by the general contractor. A liquidating agreement or subcontract “liquidating language” goes a step further than simply a pass-through claim by “liquidating” the general contractor’s liability for the subcontractor’s claim and limiting the general contractor’s liability to the value recovered against the owner. The distinction between pass-through claims generally and use of liquidating agreements or language is described in greater detail below.
Pass-through subcontractor claims are routine in construction and an important, common sense approach to deal with ever-present changes and the unexpected that can have cost and time implications. Despite the common sense basis for subcontractor pass-through claims, there are important legal considerations that must be addressed, and critical planning required, starting with the subcontract clauses.
Read the court decisionRead the full story...Reprinted courtesy of
Bradley Sands, Jones Walker LLPMr. Sands may be contacted at
bsands@joneswalker.com
