FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Subcontract Should Flow Down Delay Caused by Subcontractors

December 21, 2020 — David Adelstein - Florida Construction Legal Updates
A general contractor’s subcontract with its subcontractor should include a provision that entitles it to flow down liquidated damages assessed by the owner stemming from delays caused by the subcontractor. Such a provision does not mean the general contractor does not have to prove delays caused by the subcontractor or can arbitrarily allocate the amount or days it claims the subcontractor is liable. The general contractor still will need to reasonably establish the delays the subcontractor caused the critical path of the schedule, i.e., delayed the job. In addition to the right to flow down liquidated damages, the subcontract should also entitle the general contractor to recover its actual extended general conditions caused by the subcontractor’s delays (regardless of whether the owner assesses liquidated damages). The objective is that if the subcontractor delays the job, the subcontractor is liable for liquidated damages the general contractor is liable to the owner for in addition to the general contractor’s own delay damages. This is an important subcontractual provision so that the risk of delay caused by subcontractors is clearly flowed down to them in the subcontract. In a 1987 case, Hall Construction Co., Inc. v. Beynon, 507 So.2d 1225 (Fla. 5th DCA 1987), the subcontract at-issue contained language that stated, “The parties hereto agree that a supplier who delays performance beyond the time agreed upon in this Purchase Order shall have caused [general contractor] liquidated damages in the amount required of [general contractor] by their contract per day for each day such delay continues which sum the supplier hereby agrees to pay.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

American Council of Engineering Companies of California Selects New Director

January 22, 2014 — Beverley BevenFlorez-CDJ STAFF
Brad Diede has been selected as the new executive director of the American Council of Engineering Companies of California, according to GlobeSt.com. “ACEC California is dedicated to strengthening the engineering and surveying professions, protecting the general public and promoting the use of the private sector in building a better California.” Paul Meyer is retiring after 32 years as the executive director. Diede brings over ten years’ experience as executive director of the California Professional Association of Specialty Contractors. He will begin work at ACEC California January 27th. Read the court decision
Read the full story...
Reprinted courtesy of

---

Pensacola Bridge Repair Plan Grows as Inspectors Uncover More Damage

September 28, 2020 — Jim Parsons - Engineering News-Record
With a still-growing list of repairs needed to restore the barge-damaged Pensacola Bay Bridge, the Florida Dept. of Transportation has yet to determine a timeline for completing repairs. But assessments by the agency’s inspectors indicate that impacts from several Skanska-owned construction barges that unmoored during Hurricane Sally not only resulted in five irreparable spans, as previously reported, but at least two more that will require partial replacement. Jim Parsons, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Blockbuster Breakwater: Alternative Construction Method Put to the Test in Tampa Bay

August 14, 2023 — Scott Judy - Engineering News-Record
On June 7, 2023, Tampa Bay news reporters trekked to the Sunshine Skyway bridge for a Florida Dept. of Transportation press conference that would explain the mystery behind the hundreds of curiously shaped concrete structures lining nearly the entire length of the span’s mile-plus-long south fishing pier access road. Reprinted courtesy of Scott Judy, Engineering News-Record Mr. Judy may be contacted at judys@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Part I: Key Provisions of School Facility Construction & Design Contracts

May 16, 2018 — David R. Cook Jr. - Autry, Hall & Cook, LLP
We all expect our school construction projects will go smoothly, on time and under budget. But despite our best efforts, some projects will encounter speed bumps, detours or outright roadblocks. While there are many precautions a school facility manager may take, one of the best precautions is to have solid construction and design contracts. A good contract will account for the known risks and specify an outcome in favor of the school authority. School construction risks can be categorized into a few categories: performance risk, time risk, cost risk and political risk. Some risks are typical to all construction projects, while others are peculiar to the unique needs of school authorities. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

---

Florida trigger

May 18, 2011 — CDCoverage.com

In Johnson-Graham-Malone, Inc. v. Austwood Enterprises, Inc., No. 16-2009-CA-005750-XXXX-MA (Fla. 4th Cir. Ct. Duval County, April 29, 2011), insured JGM was the general contractor for an apartment project completed in 1998. In 2007, the project owner sued JGM seeking damages for defective construction resulting in moisture penetration property damage. JGM tendered its defense to Amerisure. Amerisure denied a defense. JGM defended and settled the underlying suit and then filed suit against Amerisure seeking recovery of defense and settlement costs. The trial court granted JGM’s motion for partial summary judgment. The court first addressed Amerisure’s duty to defend. Applying Florida law, the court held that, although the underlying complaint alleged that the property damage was not discovered until after expiration of the Amerisure policies



Read the full story…



Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Will There Be Construction Defect Legislation Introduced in the 2019 Colorado Legislative Session?

March 18, 2019 — David McLain - Colorado Construction Litigation Blog
With the 2019 Colorado legislative session well underway, the construction industry is waiting with bated breath to see what the Democrat controlled legislature might do with respect to construction defect legislation. In recent years, having a split legislature has prevented any attempts to roll back positive changes in the law, either from the legislature or Colorado courts, that have been hailed by the construction community. This year, odds are good that we will see at least one bill similar to two introduced last year that would hinder the ability to have disputes decided by binding arbitration. While not full frontal assaults on the Colorado Supreme Court decision in the Vallagio case, HB18-1261, the “Colorado Arbitration Fairness Act,” and HB 18-1262, the “Arbitration Services Provider Transparency Act,” would have negatively impacted the ability to resolve any type of case through arbitration. Anything that prevents the resolution of construction defect cases through arbitration will increase the judgments and settlements in such cases, ultimately increasing the costs of construction and for insurance for those in the industry. Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

---

Not so Fast – Florida’s Legislature Overrules Gindel’s Pre-Suit Notice/Tolling Decision Related to the Construction Defect Statute of Repose

May 11, 2020 — Rahul Gogineni - The Subrogation Strategist
As discussed in a prior blog post, in Gindel v. Centex Homes, 2018 Fla.App. LEXIS 13019, Florida’s Fourth District Court of Appeal held that when the plaintiffs provided a pre-suit notice in compliance with §558.004 of Florida’s construction defect Right-to-Cure statute, Fla. Stat. §§ 558.001 to 558.005, et. seq., they commenced a “civil action or proceeding,” i.e. an “action,” within the meaning of Florida’s construction defect Statute of Repose, Florida Statue § 95.11(3)(c). Thus, the court held that the plaintiffs commenced their action prior to the time Florida’s 10-year statute of repose period ended. In overturning the lower court’s dismissal of the action, the court found that because the Right-to-Cure statute, §558 of the Florida Statutes, sets out a series of mandatory steps that must be taken prior to bringing a judicial action, filing pre-suit notice of claim sufficiently constituted an “action” for purposes of Florida’s Statute of Repose. For various reasons, the parties appealed the decision to the Supreme Court of Florida. In July of 2019, before the Florida Supreme Court could decide whether to hear the case, the Florida legislature passed legislation that effectively overruled the decision. To overrule the decision, the Florida Legislature modified § 558.004 of Florida’s Right-to-Cure statute to expressly state that a notice of claim served pursuant to the Right-to-Cure statute does not toll the 10-year statute of repose period for construction claims. See Fla. Stat. § 558.004(d). Read the court decision
Read the full story...
Reprinted courtesy of Rahul Gogineni, White and Williams LLP
Mr. Gogineni may be contacted at goginenir@whiteandwilliams.com

---