Columbus Ohio Building Expert Directory

You’ve Been Suspended – Were You Ready?

April 20, 2020 — Curtis W. Martin, Patrick J. Greene, Jr. & Levi W. Barrett - Peckar & Abramson
“Effective tomorrow … the City is suspending all regular activity at construction sites in Boston.” This was just one of the surprises that greeted contractors last week. Contractors and owners with projects across the country are scrambling to comply with mandated governmental suspensions. Project participants should begin contingency planning for possible project shutdowns. Reacting to Suspension Your legal rights and remedies will be largely determined by your contract and the laws applicable to it. But some basic principles will be applicable depending on the source of the suspension. Suspension by the Owner: An owner work suspension suggests review of the contract’s suspension of work clause. Federal contractors would look to the FAR Suspension of Work clause, FAR 52.242-14, but that is applicable if the suspension is by the Contracting Officer; the US would argue that a systemic suspension was a sovereign act and outside the FAR clause. Contractors for private work and state or municipal work may have contractual suspension of work clauses. At least some suspension clauses provide relief for time and money. Reprinted courtesy of Peckar & Abramson attorneys Curtis W. Martin, Patrick J. Greene and Levi W. Barrett Mr. Martin may be contacted at cmartin@pecklaw.com Mr. Greene may be contacted at pgreene@pecklaw.com Mr. Barrett may be contacted at lbarrett@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

CA Senate Report States Caltrans ‘Gagged and Banished’ its Critics

August 06, 2014 — Beverley BevenFlorez-CDJ STAFF
According to the Sacramento Bee, the California Senate’s latest report said that “at least nine top experts for the new $6.5 billion San Francisco-Oakland Bay Bridge” were “’gagged and banished’” after complaining “about substandard work by the Shanghai, China, firm that built much of the span.” According to the report, reported by the Sacramento Bee, Tony Anziano, Caltrans’ chief executive of the project, “removed or demoted quality-assurance and fabrication engineers who tried to force the contractor to fix cracked roadway welds.” The report did not evaluate the bridge’s quality or safety, however, it “called for greater openness in large construction projects, a review of the weld problems by independent experts, and an investigation of allegations that engineering decisions were made by non-engineers.” Read the court decision
Read the full story...
Reprinted courtesy of

4 Steps to Take When a Worker Is Injured on Your Construction Site

March 27, 2023 — Zachary Perecman - Construction Executive
The construction industry continues to be one of the fastest-growing labor trades. According to the Center for Construction Research and Training, since 2019, 11.4 million U.S. workers have been employed in construction, a 25% increase from 2011. Amid this growth, the industry has remained one of the most dangerous, and workers are often at higher risk of injuries and deaths due to occupational incidents. According to the U.S. Bureau of Labor Statistics, there are 150,000 injuries on construction work sites annually. Under Occupational Health and Safety Administration (OSHA) law, employers have a responsibility to provide a safe work environment. That includes providing a workplace that is free of serious recognized hazards. Despite best efforts in implementing risk-mitigation and safety protocols, employers must be prepared with an incident procedure should an incident occur on a jobsite. Taking immediate, clear actions can impact the severity and outcome of injuries from a workplace incident. With this in mind, employers should take the lead in implementing safety procedures for injuries on construction sites and should inform all safety site managers and workers of the steps that should be taken. Reprinted courtesy of Zachary Perecman, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Houston Bond Issue Jump-Starts 237 Flood Control Projects

September 10, 2018 — Louise Poirier & Pam Radtke Russell - Engineering News-Record
More than $3 billion in flood risk reduction and repair projects can move forward in Houston following a vote held on Hurricane Harvey's anniversary that authorized a $2.5-billion bond program. Reprinted courtesy of Louise Poirier, ENR and Pam Radtke Russell, ENR Ms. Poirier may be contacted at poirierl@enr.com Ms. Russell may be contacted at Russellp@bnpmedia.com Read the court decision
Read the full story...
Reprinted courtesy of

Luxury-Apartment Boom Favors D.C.’s Millennial Renters

August 27, 2014 — Heather Perlberg – Bloomberg
Mandy Johnson was priced out of Virginia Square Towers, a luxury-apartment building rising across the Potomac River from Washington, D.C., where about $3,000 a month would bring perks such as a swimming pool, yoga studio and a game room with virtual golf and zombie dodge ball. Less than 24 hours after declining to sign the contract in June, she got an e-mail from a leasing manager offering two months’ free rent. That brought the monthly payment down for Johnson and her roommate by about $450 over the term of the lease and put the place within reach. “The building is still under construction, so we have to deal with that part, but we are also able to have this brand new apartment for the same price as one in older buildings, so we went for the shiny object,” said Johnson, 28, who works at a nonprofit that gives scholarships to military families. Read the court decision
Read the full story...
Reprinted courtesy of Heather Perlberg, Bloomberg
Ms. Perlberg may be contacted at hperlberg@bloomberg.net

Last Call: Tokyo Iconic Okura Hotel Meets the Wrecking Ball

August 26, 2015 — Komaki Ito & Andreea Papuc – Bloomberg
Tokyo’s iconic nod to Japanese Modernism, the Hotel Okura, will bid farewell to its last guests next week and face the wrecking ball, despite petitions from around the world to save it. The 1960s-era hotel, which has welcomed international dignitaries and inspired a throng of admirers eager for preservation, will close its doors Aug. 31 to make way for a gleaming new hotel rebuilt in time for the 2020 Olympics, at a cost of about 100 billion yen ($836 million). “What’s odd about the Okura is that it’s a perfect embodiment of ‘60s Modernism, and it represents that very first wave of new development in the region,” Tyler Brule, editor in chief of Monocle magazine, who spearheaded a campaign that included a petition with almost 9,000 signatures, said in an e-mailed response to questions. “For this reason alone, it deserves to be preserved.” Reprinted courtesy of Komaki Ito, Bloomberg and Andreea Papuc, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

The Benefits of Incorporating AI Into the Construction Lifecycle

December 23, 2024 — Ian Warner - Construction Executive
Interest in artificial intelligence has been spreading like wildfire over the past few years. AI is not a new term for Trimble, which has been capturing and leveraging construction data for decades. From hardware to software, the field to the office or among stakeholders, harnessing and making meaning out of data is the crux of Trimble’s business. Generative AI is simply a new set of tools that provide a richer narrative around data, making it more insightful and actionable. As a company that helps connect stakeholders across the entire construction lifecycle—design, construction and operations/ maintenance—AI has been woven in and leveraged across a number of Trimble solutions to help contractors do more with less, while also giving them greater decision-making power and the ability to focus on other key challenges. While the use cases for AI are diverse and ever-changing, below are a few key areas where Trimble has doubled down on AI, with the goal of making contractors’ jobs less cumbersome and repetitive, safer and more capable of being upskilled—efforts which will only continue to grow in the coming years. Reprinted courtesy of Ian Warner, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

A Few Green Building Notes

April 03, 2019 — Christopher G. Hill - Construction Law Musings
This past week, the blogosphere (if that’s even the word these days) has been abuzz about green building and the value that green can add to a project. Three items in particular (among many) got my attention. The first of these was the fact that a new private sustainability rating system is ready for launch. The Institute for Sustainable Infrastructure (or ISI) is seeking public comment on its proposed envISIon. This new system (aptly dubbed Version 1.0) will go “live” in July for comment. Why mention this new system? First of all, ISI’s founding members are the American Society of Civil Engineers (ASCE), the American Public Works Association (APWA) and the American Council of Engineering Companies (ACEC). This trio gives the new program some fairly heavy weight backing. Second, while there are rating systems aside from the ever present LEED, none have taken hold in any real way to compete with LEED. I am curious to see if the envISIon system has any better luck. Finally, this shows that sustainable building is of interest to more than the USGBC and those of us that discuss LEED on a daily basis. I find this to be a great thing that could lead to more societal acceptance of sustainable practices as a standard practice rather than a goal. Hopefully such efforts will offset the other two notes that caught my eye recently. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

COLUMBUS OHIO BUILDING EXPERT DIRECTORY AND CAPABILITIES