Liability Policy’s Arbitration Endorsement Applies to Third Party Beneficiaries, Including Additional Insureds
May 11, 2020 —
Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLPIn Philadelphia Indemnity Ins. Co. v. SMG Holdings, Inc. (No. C082841; filed 12/31/19, ord. pub. 1/28/20), a California appeals court held that a binding arbitration clause in an insurance policy extends to a third party, such as an additional insured.
In Philadelphia v. SMG, Philadelphia issued a general liability policy to a youth organization, Future Farmers of America (FFA), that had contracted to use the Fresno Convention Center for its annual convention. The contract required FFA to obtain liability insurance and to name the property manager, SMG, and the City of Fresno, as additional insureds. Philadelphia issued FFA a commercial lines CGL policy with an endorsement affording coverage to “managers, landlords, or lessors of premises” for “liability arising out of the ownership, maintenance or use of that part of the premises leased or rented” to the named insured. It also covered “any person or organization where required by a written contract executed prior to the occurrence” but only for liability arising from the named insured’s negligence.
Reprinted courtesy of
Christopher Kendrick, Haight Brown & Bonesteel LLP and
Valerie A. Moore, Haight Brown & Bonesteel LLP
Mr. Kendrick may be contacted at ckendrick@hbblaw.com
Ms. Moore may be contacted at vmoore@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Minnesota Addresses How Its Construction Statute of Repose Applies to Condominiums
April 27, 2020 —
William L. Doerler - The Subrogation StrategistCourts often struggle with the question of when the statute of repose starts to run for construction projects that involve multiple buildings or phases. In Village Lofts at St. Anthony Falls Ass’n v. Housing Partners III-Lofts, LLC, 937 N.W.2d 430 (Minn. 2020) (Village Lofts), the Supreme Court of Minnesota addressed how Minnesota’s 10-year statute of repose, Minn. Stat. § 541.051, applies to claims arising from the construction of a condominium complex. The court held that the statute of repose begins to run at different times for: a) statutory residential warranty claims brought pursuant to Minn. Stat. §§ 327A.01 to 327A.08, et. seq.; and b) common law claims arising out of the defective and unsafe condition of the condominium buildings.
As stated in Village Lofts, Housing Partners III-Lofts, LLC (Housing Partners) developed the Village Lofts at St. Anthony Falls, a condominium complex consisting of Building A and Building B. Housing Partners retained Kraus-Anderson Construction Company (Kraus-Anderson) as the general contractor for Building A. Kraus-Anderson retained Elness Sweeney Graham Architects, Inc. (ESG), Doody Mechanical, Inc. (Doody) and Kenneth S. Kendle, P.E. (Kendle) to work on Building A. In September 2002, the City of Minneapolis (City) issued a partial certificate of occupancy (CO) for Building A, including the building’s public spaces. On October 4, 2002, Housing Partners filed the declaration creating the Village Lofts at St. Anthony Falls condominium, to be operated by Village Lofts at St. Anthony Association (Village Lofts Association). On October 10, 2002, Housing Partners sold the first unit in Building A and in November of 2003, the City issued a CO for the entire building, excluding two units.
Read the court decisionRead the full story...Reprinted courtesy of
William L. Doerler, White and Williams LLPMr. Doerler may be contacted at
doerlerw@whiteandwilliams.com
No Coverage For Wind And Flood Damage Suffered From Superstorm Sandy
July 27, 2020 —
Tred R. Eyerly - Insurance Law HawaiiThe court found that the policy's anti-sequential clause barred coverage for damage caused by Hurricane Sandy. Estate of Doerfler v. Fed. Ins. Co., 2020 N.J. Sup. Unpub. LEXIS 920 (May 14, 2020).
The insureds held identical homeowners policies from Chubb and Federal Insurance Company. Damage resulting from flood was not covered. The policies' "surface water exclusion" stated,
[W]e do not cover any loss caused by: flood, surface water, waves, tidal water, overflow of water from a body of water . . . or spray from any of these even if driven by wind.
The insureds also had separate flood insurance policies, insuring the structure of each home for $250,000.
Superstorm Sandy created wind gusts as high as eighty miles per hour. A severe storm surge caused tides to rise between nine and eleven feet. The storm surge caused surface water to flood onto plaintiffs' properties and their homes ultimately collapsed.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Performance Bond Primer: Need to Knows and Need to Dos
February 01, 2022 —
Rafael Boza - Gravel2Gavel Construction & Real Estate Law BlogIf you are a construction contractor, you deal with performance bonds as part of your business and daily work. They are necessary for almost every project you are participating or will participate in, and, along with other sister bonds, constitute a basic tool to be able to work in construction. However, how much do you really know about this tool? Who in your organization knows how to use it? Are you relying on your insurance broker to procure the bonds? Can your broker competently review the terms of the bond? Are you, as a contractor, relying on the surety to explain and determine what you need for the project—a fox guarding the hen house?
To understand how a performance bond works and how to effectively tailor it to your needs, we need to understand the basics. What is a performance bond? Who are the parties to a performance bond? What does performance bond not do? What should be covered under a performance bond? How does a performance bond fit in a company’s overall risk management processes? A clear understanding of these and other basic topics will facilitate operations and reduce the risk of claims.
Read the court decisionRead the full story...Reprinted courtesy of
Rafael Boza, PillsburyMr. Boza may be contacted at
rafael.boza@pillsburylaw.com
Additional Insured is Loss Payee after Hurricane Damage
October 01, 2024 —
Tred R. Eyerly - Insurance Law HawaiiConstruing the policy language, the federal district court found that the policy's additional insured was the loss payee for damage caused by Hurricanes Laura and Delta. TCP Ryan St. LLC v. Weschester Surplus Lines Ins. Co., 2024 U.S. Dist. LEXIS 125529 (W.D. La. July 16, 2024).
Hurricanes Laura and Delta caused damage to TCP Ryan Street, LLC's (TCP) property. Westchester had issued a policy to MRI Heritage Brand, Inc. (MRI). MRI, as lessee, was obligated pursuant to the lease terms to "purchase and maintain . . . a policy of fire, extended coverage, vandalism and malicious mischief (or 'all risk') insurance coverage on all real property situated at the Lease Premises." The lease also required MRI to obtain coverage under a policy naming only the landlord as the sole insured and provided that the proceeds would be payable to the landlord.
The policy provided that no entity was covered unless Westchester had received identifying information for the entity during the application process or the entity was added by endorsement.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Before Celebrating the Market Rebound, Builders Need to Read the Fine Print: New Changes in Construction Law Coming Out of the Recession
November 26, 2014 —
Alan H. Packer - Newmeyer & Dillion, LLPAs the homebuilding market continues to improve, many builders find themselves maneuvering familiar roads. That said, important new realities have taken hold since the market collapse. Navigating these changes requires extra thought for practical and legal reasons.
Using Old Designs “Off the Shelf”?
The adoption of the California Building Standards Code in 2010, with an updated schedule to go into effect January 1, may complicate the use of older designs. In addition, some builders are contemplating building on pads constructed five or more years ago, temporarily shelved until market conditions improved. Because of changes in both the applicable Code and due to possible changes in the underlying soils and drainage, these projects require additional scrutiny before starting construction.
Mechanic’s Lien Law Changes
Not too long ago, the California Legislature recently overhauled the entire mechanic’s lien law system in California. New forms, new statutory references, new rules and deadlines are all applicable to projects under construction now. Make sure your documents are up to date, as the use of older forms (particularly for liens, progress payments, and final payments) could create legal problems in the future.
Indemnity Law Changes
Since 2006, California lawmakers have passed four rounds of legislation aimed at limiting indemnity provisions in construction contracts. The laws are aimed at two aspects of indemnity law: “Type 1” indemnity provisions, and liability for the costs of defending a claim.
Type 1 Indemnity. California law previously permitted a builder to obtain “Type 1” indemnity from its subcontractors for all claims. Under a Type 1 provision, if a claim arose out of the trade’s work, the trade was fully responsible to defend and indemnify the builder – even if other trades or the Builder were partially at fault. Some cases even allowed, typically in a commercial context, the builder to obtain Type 1 indemnity even if the trade was not negligent, as long as the claim involved its work.
Defense Obligation. In 2008, California’s highest court issued an opinion in Crawford v. Weather Shield, evaluating an indemnity provision requiring trade (a window supplier/manufacturer) to defend the builder in claims involving allegations of damages arising out of the trade’s work. Because the trade had contractually agreed to defend the builder, the Court held it responsible for the builder’s defense costs -- even though, ultimately, the trade was found
not liable for the actual damages claimed.
Recent legislation after Crawford has dramatically shifted how indemnity provisions will be enforced. Builders may no longer obtain Type 1 indemnity for residential construction defect claims covered by SB800; instead, indemnity is limited to the extent a claim arises out of the trade’s work. Even more recent legislation applied these changes to claims arising out of commercial construction projects. The recent legislation allows the trades “options” on how to defend the builder, with an eye toward requiring that they pay only a “reasonably allocated” portion for the builder’s defense costs.
Smart builders are refining their contract documents to take into account these new limitations on indemnity provisions.
Insurance Market Changes
Due to uncertainties in subcontractor insurance and other factors, many builders have also converted their liability insurance from a “bring your own” model to “wrap-up” insurance, where the builder’s policy also covers their trades. Builders should carefully examine their subcontracts in light of this change as well.
Trade Partner Changes
On a practical level, many trade partners, particularly in the residential sector, have gone out of business or moved on to greener pastures. Builders need to find and negotiate contracts with new trade partners on the fly, and educate them on the builders’ procedures for payment and construction.
SB800 documentation
A decade ago, most builders updated their purchase documents and subcontracts for California’s “Right to Repair Law” (also known as SB800), which set forth functionality standards for construction defects in residential housing, and procedures for resolving claims prior to litigation. Builders ramping up to meet market demand should examine how they implemented SB800 changes in contract documents. Issues to consider:
- Whether to opt out of -- or back into -- statutory procedures.
- Whether to include arbitration or judicial reference provisions to control where claims are litigated after the SB800 process.
- Re-training personnel to preserve SB800 rights, including sign-offs on purchase documentation and recordation of key documents.
- Recent Court of Appeal decisions have complicated the SB800 landscape, potentially opening the door to “common law” tort claims in at least subrogation contexts. Strategic planning at the document stage may be a good way to mitigate this risk as the cases wind their way through the judicial process.
The continuing surge in building activity is a welcome sign for builders who have weathered the storm. Before taking too many steps, builders should consult with counsel, their designers, and their insurance advisors to take into account the new realities of this recovering housing market.
About the Author
Alan H. Packer is a partner in the expanding Walnut Creek, CA, office of the law firm of
Newmeyer & Dillion LLP whose specialties include real estate, insurance, and construction litigation. To reach Alan, call 925.988.3200 or email him at alan.packer@ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?
January 27, 2020 —
Ted R. Gropman & Christine Z. Fan - ConsensusDocsConstruction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.
Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved.
There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973).
Reprinted courtesy of
Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP
Mr. Gropman may be contacted at gropmant@pepperlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Is Performance Bond Liable for Delay Damages?
October 20, 2016 —
David Adelstein – Florida Construction Legal UpdatesThere is an argument that a performance bond is not liable for delay damages UNLESS the bond specifically allows for the recovery of such damages. Keep this in mind when requiring a performance bond so that the bond covers the associated risks (and damages) you contemplate when requiring the bond. This argument is supported by the Florida Supreme Court’s 1992 decision in American Home Assur. Co. v. Larkin General Hosp., Ltd., 593 So.2d 195, 198 (Fla. 1992):
The language in the performance bond, construed together with the purpose of the bond, clearly explains that the performance bond merely guaranteed the completion of the construction contract and nothing more. Upon default, the terms of the performance bond required American [performance bond surety] to step in and either complete construction or pay Larkin [obligee] the reasonable costs of completion. Because the terms of the performance bond control the liability of the surety, American’s liability will not be extended beyond the terms of the performance bond. Therefore, American cannot be held liable for delay damages.
However, the Eleventh Circuit in National Fire Ins. Co. of Hartford v. Fortune Const. Co., 320 F.3d 1260(11th Cir. 2003), also analyzing an issue relating to the recoverability of delay-type damages against a performance bond, did not narrowly interpret the Florida Supreme Court’s decision in Larkin General Hospital.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.Mr. Adelstein may be contacted at
dma@katzbarron.com
