Fairfield Connecticut Building Expert Directory

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Newmeyer Dillion Named 2020 Best Law Firm in Multiple Practice Areas by U.S. News-Best Lawyers

November 24, 2019 — Newmeyer Dillion
Prominent business and real estate law firm Newmeyer Dillion is pleased to announce that U.S. News-Best Lawyers® has recognized the firm in its 2020 "Best Law Firms" rankings, with six of its practice areas earning the highest ranking possible - Tier 1 in the Orange County Metro area. The practices recognized include Commercial Litigation, Construction Law, Insurance Law, Litigation - Construction, Litigation - Real Estate and Real Estate Law. Firms included in the 2020 "Best Law Firms" list have been recognized by their clients and peers for their professional excellence. Firms achieving a Tier 1 ranking have consistently demonstrated a unique combination of quality law practice and breadth of legal expertise. “We are grateful that the firm’s clients and our peers again recognize our personalized approach to legal service. We strive to provide creative solutions that propel our clients’ businesses forward,” said Managing Partner Paul Tetzloff. To be eligible for the “Best Law Firms” ranking, a firm must have at least one attorney recognized in the current edition of The Best Lawyers in America for a specific practice area. Best Lawyers recognizes the top 4 percent of practicing attorneys in the U.S., selected through exhaustive peer-review surveys in which leading lawyers confidentially evaluate their professional peers. ABOUT NEWMEYER DILLION For 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of corporate, privacy & data security, employment, real estate, construction, insurance law and trial work, Newmeyer Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com Read the court decision
Read the full story...
Reprinted courtesy of

Texas Allows Wide Scope for Certificate of Merit

January 07, 2025 — Lian Skaf - The Subrogation Strategist
The purpose of certificate of merit (sometimes referred to as affidavit of merit) statutes is to identify frivolous claims before the court wastes time and resources during litigation. More common in medical malpractice cases, several states have enacted similar requirements for professional negligence claims dealing with construction-related issues. While a subrogation attorney should not be bringing a frivolous case to suit anyway, the requirement adds another step in the process that plaintiffs need to properly navigate. Chapter 150 of the Texas Civil Practice and Remedies Code requires that in an action arising out of professional services by a licensed or registered professional, claimants must file an affidavit from a qualified expert attesting to the theories of recovery, the negligence and the factual basis for the claims. The expert must be competent, have the same professional license or registration as the defendant and practice in the area of practice of the defendant. In Janis Smith Consulting, LLC v. Rosenberg, No. 03-23-00370-CV, 2024 Tex. App. LEXIS 7961, the Court of Appeals of Texas, Third District (Court of Appeals) addressed a challenge from the defendant as to the sufficiency of the plaintiff’s certificate of merit in an interlocutory appeal. The Court of Appeals affirmed the lower court’s dismissal of the defendant’s motion to dismiss based on the allegedly improper certificate of merit, holding that the plaintiff’s expert was sufficiently qualified to certify the legitimacy of the case. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

Engineer and CNA Dispute Claim Over Dual 2014 Bridge Failures

December 15, 2016 — Scott Van Voorhis – Engineering News-Record
An engineering company whose error led to two pedestrian bridge collapses in North Carolina in 2014 that left one worker dead and caused costly damage contends it is being unfairly denied $2 million in potential insurance coverage by its carrier due to what it claims is an “ambiguous” wording of the policy. Read the court decision
Read the full story...
Reprinted courtesy of Scott Van Voorhis, Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

Brenner Base Tunnelers Conquer Peaks and Valleys in the Alps

October 21, 2019 — Scott Blair - Engineering News-Record
A logistics tangle decades in the unraveling, the Brenner Base Tunnel project is having a banner year. Twin tunnel boring machines in May were released on their relentless journey to mine the main tunnels underneath the Alps between Austria and Italy, while a multinational crew of 2,400 workers armed with a toolkit of just about every mining technique is swarming four major worksites, including a particularly challenging area where workers must undercut a river and pass through the fast-flowing aquifer below it. Read the court decision
Read the full story...
Reprinted courtesy of Scott Blair, ENR
Mr. Blair may be contacted at blairs@enr.com

Newark Trial Team Secures Affirmance of ‘No Cause’ Verdict for Nationwide Housing Manager & Developer

January 07, 2025 — Lewis Brisbois Newsroom
Newark, N.J. (December 30, 2024) - Newark Partner Afsha Noran and Managing Partner Colin Hackett recently obtained a ruling by a New Jersey Appellate Division panel affirming a unanimous "no cause" defense verdict obtained on behalf of a nationwide housing developer and manager. In this case, the plaintiff and her two minor children brought suit against the firm's client. They appealed a unanimous no-cause jury verdict rendered in May 2023 that found the defendants not liable for mold exposure in their apartment. The plaintiffs argued that several trial errors, including improper jury instructions, a confusing verdict sheet, and prejudicial remarks by defense counsel led to an unjust result. However, the appellate court affirmed the trial court's decision, concluding that there was no miscarriage of justice and that the trial court properly exercised its discretion in handling the case. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

APROPLAN and GenieBelt Merge, Creating “LetsBuild” – the Build Phase End-to-End Digital Platform

March 18, 2019 — Aarni Heiskanen - AEC Business
Responding to a rising need to deliver an all-in-one solution, supporting on-site planning, progress communication, snagging, drawings and checklists, GenieBelt and APROPLAN have decided to merge to form LetsBuild – the European leader in delivering an end-to-end solution to the global construction industry. For the past five years, GenieBelt CEO Klaus Nyengaard and APROPLAN CEO Thomas Goubau have met on a regular basis to discuss developments in the construction technology sector and how to increase efficiency and minimise rework, miscommunication, and errors. “We share the vision that ‘simple to use’-products will bring immense value to the construction sector. When we met in October 2018, we concluded that the way to realize this vision was to unite our companies to create a broader product and cover more needs in the market,” says LetsBuild CEO Klaus Nyengaard. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Motion to Strike Insurer's Expert Opinion Granted

August 13, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The court granted the insured's motion to strike the testimony of the insurer's expert because the opinion lacked sufficient explanation or analysis. Affinity Mut. Ins. v. Thacker Air Conditioning Refrigeration Heating, 2019 U.S. Dist. LEXIS 84713 (N.D. Ind. May 20, 2019). The insured owned a market that needed renovations. The roof over an addition to the market extended from the wall of the extension to the top of the existing roof. The area between the old and new roofs was filled with blown-in insulation, so that the structural support from the new overbuilt roof was not visible. The weight of the overbuilt roof rested on top of the existing roof at the point where they met. This added additional weight on the trusses supporting the main roof. In 2014, the market upgraded the building with heating and insulation. Thacker was a subcontractor for work on the hearing system. Six gas furnaces, spaced about 35 feet apart along the length of the building, were placed by Thacker. The total weight of each unit was estimated at 280 pounds. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES