What Every Project Participant Needs to Know About Delay Claims
August 05, 2024 —
Andrew G. Vicknair - The Dispute ResolverA “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays.
I. Types of Delays
Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule.
Read the court decisionRead the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
Governor Brown Signs Legislation Aimed at Curbing ADA Accessibility Abuses in California
June 02, 2016 —
Garret Murai – California Construction Law BlogThis past week Governor Jerry Brown signed
Senate Bill 269. The new law is the latest attempt to curb lawsuits brought under the Americans with Disabilities Act of 1990 (“ADA”) and related states laws which many businesses and governmental entities have called unfair and predatory. Others, have used more
colorful descriptions.
The ADA Debate
At the heart of the debate is a small but growing number of ADA plaintiffs who regularly sue businesses and governmental entities alleging that their properties do not provide equal access to disabled individuals. These ADA plaintiffs and their attorneys, including other members of the disabled community, argue that these lawsuits improve access to places of public accommodation by disabled individuals, are permitted under the law, and that the businesses and government agencies they sue can’t be heard to complain since the ADA has been on the books for over twenty-five years.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
Chinese Brooklyn-to-Los Angeles Plans Surge: Real Estate
April 01, 2014 —
Nadja Brandt and John Gittelsohn – BloombergIt took just one 15-minute phone call in July to persuade Ifei Chang to join Shanghai-based developer Greenland Holding Group Co. and lead a U.S. expansion. Within three months, she was running $6 billion of projects as part of a record push by Chinese investors into American property.
Greenland reached a preliminary agreement in October to buy a 70 percent stake in the $5 billion Atlantic Yards development in Brooklyn, New York. That followed a July deal to acquire a $1 billion residential-and-entertainment project in downtown Los Angeles. Chang, who took charge of that site upon arriving in the U.S., is now on the hunt for more investments.
“In China, you climb a ladder where everything is floating and moving so fast,” Chang, 49, said in an interview at her sparsely furnished 46th-floor L.A. office overlooking the empty lot where the Metropolis project will be built. “We come from a country of 1.4 billion people and a lot of economic growth. This kind of project and investment speed is very normal in China. That’s why we are so confident we will deliver this project.”
Greenland, like other Chinese companies, is committing to a growing number of multibillion-dollar developments outside of its home market. Chinese investments in U.S. commercial properties jumped almost 10-fold last year from 2012, with Manhattan the biggest area for purchases, followed by other New York City boroughs and Los Angeles, according to research firm Real Capital Analytics Inc.
Ms. Brandt may be contacted at nbrandt@bloomberg.net; Mr. Gittelsohn may be contacted at johngitt@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
Nadja Brandt and John Gittelsohn, Bloomberg
Corps Releases Final Report on $29B Texas Gulf Coast Hurricane Defense Plan
October 11, 2021 —
James Leggate - Engineering News-RecordA $28.87 billion plan to protect the Texas Gulf Coast’s residents and infrastructure against hurricanes and storm surge with a series of coastal storm risk management and ecosystem restoration projects took a step closer to reality Sept. 10 with the release of a final feasibility report and final environmental impact statement from the U.S. Army Corps of Engineers and Texas General Land Office (GLO).
Reprinted courtesy of
James Leggate, Engineering News-Record
Mr. Leggate may be contacted at https://www.enr.com/leggatej@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
No Interlocutory Appeals of "Garden-Variety" Contract Disputes
March 12, 2015 —
Jesse Howard Witt – Acerbic WittColorado’s new procedure for interlocutory appeals has its limits. In the recent decision of Rich v. Ball Ranch Partnership, ___ P.3d ___, 2014 COA 6 (2015), the Colorado Court of Appeals held that Appellate Rule 4.2 does not permit interlocutory review of questions of law in “garden-variety” or “run-of-the-mill” contract disputes. This resolves a subtle question that has been lingering since Colorado first created the interlocutory appeal process four years ago.
Prior to 2011, Colorado did not permit civil litigants to seek appellate review prior to final judgment, except in a small handful of situations. As I discussed in an article at the time, this changed with the passage of C.R.S. § 13-4-102.1 and the adoption of Rule 4.2, which granted the court of appeals discretion to permit the immediate appeal of certain district court orders. These provisions allowed parties to seek interlocutory review of orders before the conclusion of a case if a district court could certify that (1) immediate review might promote a more orderly disposition or establish a final disposition of the litigation, and (2) the order involved a controlling and unresolved question of law. The rule was patterned after 28 U.S.C. § 1292(b), which provides similar relief in the federal courts.
Read the court decisionRead the full story...Reprinted courtesy of
Jesse Howard Witt, The Witt Law FirmMr. Witt welcomes comments at www.acerbicwitt.com
Texas Federal Court Delivers Another Big Win for Policyholders on CGL Coverage for Construction-Defect Claims and “Rip-and-Tear” Damages
March 14, 2022 —
Blake A. Dillion, Jared De Jong & Scott S. Thomas - Payne & FearsInsurers regularly argue that commercial general liability (“CGL”) policies are not performance bonds and therefore there is no coverage for claims seeking damages for defective or faulty workmanship. Insurers also argue there is no coverage for so-called “tear-out” or “rip-and-tear” damages, where fixing property damage requires replacing defective work that has not itself been damaged. Fortunately, in a newly decided case, a Texas federal district court rejected both arguments by an insurer. Amerisure Mutual Insurance Company v. McMillin Texas Homes, LLC, No. SA-20-CV-01332-XR, 2022 WL 686727 (W.D. Tex. Mar. 8, 2022).
As with most construction-defect claims, this case involved homeowner claims against a residential developer, McMillin Texas Homes (“McMillin”). After the homes were completed, homeowners complained about defects in the artificial stucco exterior finish and filed suit. McMillin tendered to its insurer, Amerisure Mutual Insurance Company (“Amerisure”). Amerisure then sued McMillin for declaratory relief, arguing that it had no duty to defend or indemnify the homeowner claims. McMillin filed a counterclaim alleging Amerisure breached its policies by refusing to defend or indemnify McMillin.
Reprinted courtesy of
Blake A. Dillion, Payne & Fears,
Jared De Jong, Payne & Fears and
Scott S. Thomas, Payne & Fears
Mr. Dillion may be contacted at bad@paynefears.com
Mr. De Jong may be contacted at jdj@paynefears.com
Mr. Thomas may be contacted at sst@paynefears.com
Read the court decisionRead the full story...Reprinted courtesy of
Landmark Contractor Licensing Case Limits Disgorgement Remedy in California
November 09, 2020 —
Candace Matson - Construction & Infrastructure Law BlogContractors performing work in California are required to be licensed by the California State License Board (“CSLB”). Cal. Bus. & Prof. Code §7065. Except for sole proprietors, contractors are typically licensed through “qualifiers,” i.e., officers or employees who take a licensing exam and meet other requirements to become licensed on behalf of the contractor’s company. Contractors who perform work in California without being properly licensed are subject to a world of hurt, including civil and criminal penalties (see, e.g., Cal. Bus. & Prof. Code §§ 7028, 7028.6, 7028.7, 7117, and Cal. Labor Code §§ 1020-1022), and the inability to maintain a lawsuit to recover compensation for their work. Cal. Bus & Prof. Code § 7031(a); Hydra Tech Systems Ltd. v. Oasis Water Park, 52 Cal.3rd 988 (1991).
But arguably the worst ramification of not being property licensed is that established in Business & Professions Code Section 7031(b), which provides that any person who uses the services of an unlicensed contractor may bring an action for the return of all compensation paid for the performance of the work, commonly known as “disgorgement.” This remedy is particularly harsh (often described as “draconian”) because it makes no allowance for the fact that an unlicensed contractor will likely have already paid out the bulk of its compensation to its subcontractors, suppliers and vendors, but nevertheless can be ordered to disgorge all compensation.
Read the court decisionRead the full story...Reprinted courtesy of
Candace Matson, Sheppard MullinMs. Matson may be contacted at
cmatson@sheppardmullin.com
Couple Sues for Construction Defects in Manufactured Home
July 31, 2013 —
CDJ STAFFA West Virginia couple has sued the manufacturer of their home for construction defects and damage. Darrell and Teri Pearson claim that the home they purchased from Giles Industries was defective. They further claim that Kitchen’s Construction failed to set the home up properly and that the firm did not repair damaged sections of home. The suit also names the firm that sold the home and others.
Read the court decisionRead the full story...Reprinted courtesy of