Washington Supreme Court Expands Contractor Notice Obligations
November 28, 2018 —
Brett M. Hill - Ahlers Cressman & Sleight BlogThe Washington State Supreme Court dealt another blow to public works contractors in Washington State. In a case recently issued by the court, Nova Contracting, Inc. v. City of Olympia, [1] the court expanded contractors’ obligations when providing notice on public works construction projects. The Nova Contracting case was the subject of a previous blog. The case involved Nova Contracting and the City of Olympia. Nova was the low bidder on the contract. Nova alleged that the City of Olympia did not want Nova to win the job and intentionally hindered Nova’s ability to perform the job. The facts alleged by Nova, which were covered in the previous blog, involved the City’s improper and apparently punitive rejection of submittals on the job and the City’s eventual wrongful termination of Nova. Of significance in the case is that Nova never actually began work on the job. All that Nova had done at the time of termination was begin mobilizing its equipment on site. The Court of Appeals found that Nova had alleged sufficient facts to establish that the City violated the duty of good faith and fair dealing by improperly rejecting Nova’s submissions and had breached the contract with Nova by improperly terminating.
Read the court decisionRead the full story...Reprinted courtesy of
Brett M. Hill, Ahlers Cressman & Sleight PLLCMr. Hill may be contacted at
brett.hill@acslawyers.com
New Zealand Using Plywood Banned Elsewhere
October 30, 2013 —
CDJ STAFFCopper chromium arsenate helps protect wood against insect damage and fungal growth. Unfortunately, its use leads to arsenic exposure. The safety concerns over CCA for both construction workers and the people who later use the buildings have led to the CCA-treated plywood being banned or restricted in most countries, including the United States, Canada, France, the United Kingdom, and Germany.
New Zealand is not on the list of countries restricting or banning CCA-treated wood. Dr. Merial Watts, a science coordinator for Pesticide Action Network NZ described the product as an “unacceptable public health risk,” and said that “wrapping homes in CCA-treated plywood is a very bad idea.”
One construction official, speaking anonymously, noted that “workers have to handle it with gloves and full body suits,” but those guidelines may not be followed. A foreman on a building site said “I know about the treatment but I don’t take many precautions.”
Read the court decisionRead the full story...Reprinted courtesy of
Why Construction Law- An Update
May 07, 2015 —
Christopher G. Hill – Construction Law MusingsBack in 2009, only a year or so after my first post here at Musings, I posted on why I’m in the field of construction law. Well, a lot has happened in the over 5 years since then, not the least of which is my move to solo practice in July of 2010 and the later certification as a mediator. As I sit here, I look back at the passage of time and the events between my last thoughts on this subject and now and wonder if my thoughts have changed?
Frankly, not much has changed as far as my attitude toward the practice of construction law. Despite my kids occasionally rolling their eyes when I talk about a case of interest to me and their sometimes moniker for me as a “dirt lawyer,” I continue to find the representation of the construction professionals that I call clients and friends to be fulfilling and worthwhile. Even in the face of criticisms that we lawyers cause more problems that we solve, I firmly believe that I and other good construction lawyers can and do help avoid and anticipate more problems than I cause.
As one of the few solo construction attorneys here in the Richmond area, if anything, I am more involved in the construction community. Between my continued and even increased involvement with the AGC of Virginia and my more recent appointment to the board of the Virginia State Bar‘s Construction Law and Public Contracts Section, I have gained even more insight into the workings of the legal and business landscapes of construction. With each new piece of information gained by such involvement, I see another side to the business of construction that I may not have thought of.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher G. Hill, Construction Law MusingsMr. Hill may be contacted at
chrisghill@constructionlawva.com
Recovering Unabsorbed Home Office Overhead Due to Delay
May 30, 2022 —
David Adelstein - Florida Construction Legal UpdatesIn the
preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs.
Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.
To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period.
CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Georgia Court of Appeals Upholds Denial of Coverage Because Insurance Broker Lacked Agency to Accept Premium Payment
December 07, 2020 —
Lawrence J. Bracken II, Michael S. Levine & Rachel E. Hudgins - Hunton Insurance Recovery BlogIn American Reliable Insurance Company v. Lancaster, the Georgia Court of Appeals reversed the denial of a property insurer’s summary judgment motion concerning the insurer’s denial of a fire loss claim. The basis of the denial was that the policyholders had failed to pay the policy premium. The policyholders, Charlie and Wanda Lancaster, claimed that they had paid their policy premiums for several years to their insurance agent, Macie Yawn. In October 2014, American Reliable mailed a renewal notice to the Lancasters notifying them that premium payments had to be made directly to the insurer. After it did not receive payment from the Lancasters, American Reliable sent them a cancellation notice in December 2014, again notifying them that payments be made directly to the insurer. The Lancasters denied having received either notice from American Reliable, but the record included a receipt for certificate of mailing.
After the Lancaster’s home burned down in 2015, American Reliable denied coverage on the grounds that the policy had been cancelled for nonpayment of premium. In the subsequent coverage action, the trial court denied American Reliable’s motion for summary judgment, ruling that a factual issue existed as to the actual and apparent agency of the insurance agent, Yawn. On appeal, the Court of Appeals found that the trial court erred in deciding that there was a factual issue concerning Yawn’s agency. Specifically, the Court of Appeals ruled that the record showed American Reliable had terminated Yawn’s agency to accept policy premiums, and that the Lancaster’s received notice of that termination in the renewal and cancellation notices. In addition to determining that Yawn was not an actual agent, the Court held that Yawn did not have apparent agency, because the notices sent to the Lancasters stated that the premium payment was to be paid to American Reliable, not to the agent.
Reprinted courtesy of
Lawrence J. Bracken II, Hunton Andrews Kurth,
Michael S. Levine, Hunton Andrews Kurth and
Rachel E. Hudgins, Hunton Andrews Kurth
Mr. Bracken may be contacted at lbracken@HuntonAK.com
Mr. Levine may be contacted at mlevine@HuntonAK.com
Ms. Hudgins may be contacted at rhudgins@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
America’s Infrastructure Gets a C-. It’s an Improvement Though
April 05, 2021 —
Garret Murai - California Construction Law BlogEvery four years the American Society of Civil Engineers (ASCE) issues a report card assigning a letter grade to the nation’s infrastructure. ASCE issued their 2021 Infrastructure Report Card earlier this month.
Our country’s grade in 2021? A disappointing C-.
It’s an improvement though. When ASCE issued their 2017 Infrastructure Report Card we didn’t even pass the class with a grade of D+.
In short, there’s room for improvement. A lot of room for improvement.
C- is just the cumulative grade however. ASCE’s Report Card is divided into industry segments with grades assigned to each segment. Individual grades for some, but not all, of the segments include the following:
- Aviation: The nation’s airports received a grade of D+. According to the Report Card, terminal, gate and ramp availability are not meeting the needs of a growing passenger base which has increased from 964.7 million to 1.2 billion per year and a has a 10-year shortfall of $111 billion.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Quick Note: Aim to Avoid a Stay to your Miller Act Payment Bond Claim
February 23, 2017 —
David Adelstein – Florida Construction Legal UpdatesStrategy is important. This is especially true if you are trying to avoid arbitration. In a recent federal district court case, a subcontractor sued the prime contractor and the Miller Act payment bond surety. The subcontractor, however, had an arbitration provision in its subcontract with the prime contractor. The prime contractor moved to compel arbitration pursuant to the subcontract and moved to stay the subcontractor’s Miller Act payment bond claim. The last thing, and I mean the last thing, the subcontractor wanted to do was to stay its claim against the Miller Act payment bond. However, the district court compelled the subcontractor’s claim against the prime contractor to arbitration and stayed the subcontractor’s Miller Act payment bond claim pending the outcome of the arbitration. See U.S. v. International Fidelity Ins. Co., 2017 WL 495614 (S.D.Al. 2017). This is not what the subcontractor wanted.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
dadelstein@gmail.com
Settlement Conference May Not Be the End in Construction Defect Case
February 21, 2013 —
CDJ STAFFThe builder has been sentenced to jail for theft. The building has been condemned over construction defects. And the settlement conference probably won’t bring an end to the case. The building in question is a condominium complex, located at 770 Sandy Street in Norristown, Pennsylvania. Bruce Fazio took out a $2.5 million construction loan to build it. And when it was done, there were inspections over construction defects, the building was condemned, and then the court ordered repair work. The city of Norristown has sued Fazio to recover the more than $1.5 million it took to repair the building and allow at least some condominium owners to move back in.
The suit alleges that Norristown officials failed to properly inspect the construction work, and that inspectors were not properly certified. Further, it is alleged that secretaries and clerks signed off on inspection reports and certificates of occupancy.
Read the court decisionRead the full story...Reprinted courtesy of
