FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

No Coverage for Homeowner Named as Borrower in Policy but Not as Insured

July 08, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The magistrate judge recommended that the homeowner's complaint seeking coverage for damage caused by Hurricanes Laura and Delta be denied because the homeowner was only named as the borrower under the policy. LeDay v. Integon Nat'l Ins. Co., 2024 U,S. Dist. LEXIS 87369 (W.D. La. April 15, 2024). When the homeowner sought coverage for hurricane damage, it was denied. The homeowner then sued and Integon moved to dismiss. Integon argued it did not issue a policy to the homeowner, but the policy was issued to Midland Mortgage. The pro se homeowner did not respond to the motion. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Contractors Liable For Their Subcontractor’s Failure To Pay Its Employees’ Wages And Benefits

November 01, 2022 — Edward O. Pacer & David J. Scriven-Young - ConsensusDocs
Recently, Illinois Governor J.B. Pritzker signed two House Bills that amend the Illinois Wage Payment & Collections Act, 820 ILCS 115 et. seq. (“Wage Act”), to provide greater protection for individuals working in the construction trades against wage theft in a defined class of projects. Pursuant to this new law, every general contractor, construction manager, or “primary contractor,” working on the projects included in the Bill’s purview will be liable for wages that have not been paid by a subcontractor or lower-tier subcontractor on any contract entered into after July 1, 2022, together with unpaid fringe benefits plus attorneys’ fees and costs that are incurred by the employee in bringing an action under the Wage Act. This new wage theft law follows several other states that have considered and passed similar legislation. These amendments to the Wage Act apply to a primary contractor engaged in “erection, construction, alteration, or repair of a building structure, or other private work.” However, there are important limitations to the amendment’s applicability. The amendment does not apply to projects under contract with state or local government, or to general contractors that are parties to a collective bargaining agreement on a project where the work is being performed. Additionally, the amendment does not apply to primary contractors who are doing work with a value of less than $20,000, or work that involves only the altering or repairing of an existing single-family dwelling or single residential unit in a multi-unit building. Reprinted courtesy of Edward O. Pacer, Peckar & Abramson, P.C. (ConsensusDocs) and David J. Scriven-Young, Peckar & Abramson, P.C. (ConsensusDocs) Mr. Pacer may be contacted at epacer@pecklaw.com Mr. Scriven-Young may be contacted at dscriven-young@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Insurer Beware: Failure to Defend Ends with Hefty Verdict

June 01, 2011 — Douglas Reiser, Builders Council Blog

Served with a lawsuit that you turned over to your insurer? Insurer refusing to defend you? Well, find some hope in this news. Washington’s IFCA has the claws to ensure that insurers perform their duties.



Contractors heavily rely on the defense provisions of their Commercial General Liability (CGL) policies. In construction, a legal dispute can easily rear its head when you least expect it. Luckily, Washington registered contractors are required to maintain CGL insurance. That insurance often provides contractors with adequate legal defense in the event that they are sued.



But, what if your insurer turns down the defense request? They might be staring at massive damages. A current Reiser Legal client, Australia Unlimited, Inc., recently won a large verdict against Hartford Insurance, after the insurer unreasonably denied their claim. The firm who represented Australia Unlimited Inc. in that case, Hackett Beecher and Hart, were successful in procuring a $5.43 Million verdict



Read the full story…



Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

A Court-Side Seat: Recent Legal Developments at Supreme and Federal Appeals Courts

December 18, 2022 — Anthony B. Cavender - Gravel2Gavel
This is a review of initial Supreme Court and Federal Appeals Courts oral arguments and other matters in October 2022. Oral Arguments at the Supreme Court Michael Sackett, et ux., v. Environmental Protection Agency The Supreme Court’s 2022 term began on October 3, 2022, with this important oral argument. For many years, the petitioner has encountered EPA opposition to the construction of a home on his property located near a lake in Idaho. The agency insists that the land is subject to federal regulatory jurisdiction, in that a Clean Water Act permit will be needed before work can proceed. Several courts have already weighed in on this issue; whether the land in question is considered a regulated “wetlands” pursuant to the “significant nexus” test developed by the Court in the Rapanos case decided in 2006. The oral argument was fairly long and spirited. The justices appear to believe that the “significant nexus” is unworkable because in many instances it provides little or no guidance to landowners as to whether their property may be subject to federal jurisdiction, and thus subject to civil and even criminal penalties. Justice Kavanaugh remarked that “this case is going to be important for wetlands throughout the country and we have to get it right.” Later, Justice Gorsuch lamented the fact that implementing a test for federal jurisdiction under the Clean Water Act test is so difficult to apply: “If the federal government doesn’t know [if a property is adjacent to navigable water and is regulated,] “does a reasonable landowner have any idea.” The issue is very difficult to resolve, and the Congress has indicated that is has no interest in entering this regulatory thicket. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---

WSHB Expands to Philadelphia

July 28, 2016 — Beverley BevenFlorez-CDJ STAFF
Wood Smith Henning & Berman LLP (WSHB) announced “the opening of its newest regional office at One Liberty Place, 1650 Market Street, 36th Floor, Philadelphia, Pennsylvania 19103,” according to a press release. Elizabeth Chalik will be the managing partner at the new location. Chalik is “a highly regarded litigator with close to 15 years of trial experience” and her practice has focused on products liability, casualty, toxic tort and transportation litigation. Furthermore, Chalik is admitted to practice law in both New Jersey and Pennsylvania. “It is fitting that as we celebrate WSHB’s 19th year, we are opening our 19th office,” said Daniel Berman, Firm Chairman and Co-founder. “With this expansion, we continue our pattern of strategic long term growth. That, coupled with Liz’s proven track record and many years in Philadelphia, further expands our ability to better serve our clients in the Northeast.” Chalik has been recognized on the Super Lawyers List of Rising Stars for three years running. “I am thrilled to be joining Wood Smith Henning & Berman. WSHB’s long-standing reputation and dedication to their clients drew me to them and I knew that this would be the right place for me,” said Chalik. “I could not be more excited about the opportunity to manage WSHB’s new Philadelphia office!” WSHB also has offices located in Connecticut, Denver, Fresno, Glendale, Las Vegas, Los Angeles, Miami, New Jersey, New York, Northern California, Orange County, Phoenix, Portland, Rancho Cucamonga, Riverside, San Diego, Seattle and Tampa. Read the court decision
Read the full story...
Reprinted courtesy of

---

Rhode Island Finds Pollution Exclusion Ambiguous, Orders Coverage for Home Heating Oil Leak

March 06, 2023 — Kayla S. O'Connor - Saxe Doernberger & Vita, P.C.
The Rhode Island case of Regan Heating and Air Conditioning, Inc. v. Arbella Protection Insurance Company, Inc., et. al.1 provides much-needed guidance regarding ambiguity and the term “pollution.” In Regan, the Rhode Island Supreme Court held that a pollution exclusion contained in the Plaintiff’s “Commercial Package Policy” was ambiguous as to whether home heating oil that escaped into a customer’s basement constituted a “pollutant” under the policy. This case stems from a 2015 incident wherein Regan was in the process of removing an older heating system and installing a new heating system in a customer’s home when that customer discovered 170 gallons of home heating oil in his basement. The customer sued Regan, alleging negligence and demanding remediation for the property damage caused by the oil leak. Read the court decision
Read the full story...
Reprinted courtesy of Kayla S. O'Connor, Saxe Doernberger & Vita, P.C.
Ms. O'Connor may be contacted at KOconnor@sdvlaw.com

---

The Latest News on Fannie Mae and Freddie Mac

May 01, 2014 — Beverley BevenFlorez-CDJ STAFF
The Federal Housing Finance Agency released a report on April 30th, which stated that in a severe economic downturn Fannie Mae (FNMA) and Freddie Mac (FMCC) “could require an additional bailout of as much as $190 billion… according to the results of stress tests,” according to Clea Benson writing for Bloomberg. “These results of the severely adverse scenario are not surprising given the company’s limited capital,” FNMA Senior Vice President Kelli Parsons said in a statement, as reported by Benson published in Bloomberg. “Under the terms of the senior preferred stock purchase agreement, Fannie Mae is not permitted to retain capital to withstand a sudden, unexpected economic shock of the magnitude required by the stress test.” Furthermore, in another Bloomberg article, Cheyenne Hopkins and Clea Benson reported that Democrats remain divided on how to replace FNMA and FMCC. “If we don’t get this right, we’ll create major disturbances in the housing market which will have a profound impact on families, on homeownership and certainly on our national economy,” Oregon Democrat Jeff Merkley said in an interview, as reported by Cheyenne and Benson. “Merkley described himself as ‘still in negotiations’ with the bill’s sponsors.” Read the full story, Clea Benson Article... Read the full story, Cheyenne Hopkins & Clea Benson Article... Read the court decision
Read the full story...
Reprinted courtesy of

---