Cambridge Massachusetts Building Expert Directory

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Real Estate Trends: Looking Ahead to 2021

November 09, 2020 — Adam Weaver - Gravel2Gavel Construction & Real Estate Law Blog
2020 has been an unprecedented year, and, while there are likely more twists and turns to come before December 31, it is essential to look at how the real estate markets have changed this year and which trends are likely to continue into 2021. The COVID-19 pandemic has impacted nearly every industry, including commercial real estate, and its impact will continue to influence the market and commercial real estate long after the virus has been eradicated. Commercial Real Estate Loan Modifications As the United States’ economy stalled, shut down and slowly started to recover throughout 2020, many businesses were negatively impacted, and most property owners found themselves negotiating with both their lenders and tenants. As tenants were unable to pay rent, property owners were unable to service their debt, which led to a surge of loan modifications this year. This trend certainly will continue through the first half of 2021, as the economy continues to recover. Read the court decision
Read the full story...
Reprinted courtesy of Adam Weaver, Pillsbury
Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com

Real Estate & Construction News Roundup (3/20/24) – Construction Backlog Falls, National Association of Realtors Settle Litigation, and Commercial Real Estate Market’s Effect on City Cuts

April 15, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, bad loans outweigh loss reserves at top six U.S. banks, the FCC announces a proposed rule aimed at “bulk billing,” office-to-multifamily conversion projects grow in major metro cities, and more!

The National Association of Realtors has agreed to settle litigation that accused them of artificially inflating real estate commissions – a major decision that could reshape the housing market for buyers, sellers and agents. (Rachel Siegel, The Washington Post)
An NYU professor considers the positives and negatives of cities cutting services or raising other kinds of taxes to offset the continued faltering of the commercial real estate market. (Alan Rappeport, The New York Times)
Construction backlog fell in February for every size of contractor except for those with under $30 million in annual revenue, while, over the past year, the largest contractors – those with greater than $50 million in revenue – have experienced the greatest decline in backlog. (Sebastian Obando, Construction Dive).

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Neighbor Allowed to Remove Tree Roots on Her Property That Supported Adjoining Landowners’ Two Large Trees With Legal Immunity

July 14, 2016 — Paul R. Cressman, Jr. – Ahlers & Cressman PLLC Blog
A recent Washington Court of Appeals opinion addressed the rights of a neighbor to destroy roots and branches on her property that belonged to trees located on an adjoining landowner’s property.[1] Mustoe had two large Douglas-fir trees located entirely on her property, about two and one-half feet from the property line with her neighbor Ma. Ma caused a ditch to be dug on her property along the border with Mustoe’s lot. The ditch was 18-20 inches deep. In the process, Ma exposed and removed the trees’ roots, leaving them to extend only three-four feet from the trunks of the trees. This resulted in a loss of nearly half of the trees’ roots, all from the south side, exposing them to southerly winds with no support. The damaged trees posed a high risk of falling on Mustoe’s home. The landscape value of the trees was estimated to be $16,418. The cost of their removal was estimated to be $3,913. Mustoe filed suit against Ma asserting that Ma had negligently, recklessly, and intentionally excavated and damaged her trees, along with other property, and also sought emotional distress damages. The trial court dismissed Mustoe’s suit. The Court of Appeals affirmed. Read the court decision
Read the full story...
Reprinted courtesy of Paul R. Cressman, Jr., Ahlers & Cressman PLLC
Mr. Cressman may be contacted at pcressman@ac-lawyers.com

Stop by BHA’s Booth at WCC and Support the Susan G. Komen Foundation

May 12, 2016 — Beverley BevenFlorez-CDJ STAFF
If you’re attending the annual West Coast Casualty Seminar at the Disneyland Hotel today and tomorrow, be sure to stop by the Bert L. Howe & Associates, Inc., booth and Sink a Putt for Charity. This year, participant’s efforts on the green will help benefit the Susan G. Komen Race for the Cure. As in years past, sink a putt in the BHA golf challenge and win a $25 Best Buy gift card, and for every successful putt made, BHA will make a $25 cash donation in the golfer’s name to the Susan G. Komen Foundation. New this year, BHA is hosting three Championship Rounds and during those periods BHA will double their charitable contributions. For every ATTEMPTED (sink or miss), BHA will make a $50 donation to Susan G. Komen, and for every putt MADE (sunk), the golfer will also win a $50 Best Buy gift card. Championship rounds are going on today between the times of 10:30am-10:45 am, 3:00pm-3:30pm, and 5:30pm-6:30pm. So be sure to get over to the BHA booth for your chance to support important cancer research as well as possibly taking home a nice gift card for yourself. BHA also wishes to thank Dave Stern for all of his hard work for the construction defect community in putting together this must go to seminar and for promoting such worthwhile charities each year. Read the court decision
Read the full story...
Reprinted courtesy of

Not Our Territory: 11th Circuit Dismisses Hurricane Damage Appraisal Order for Lack of Jurisdiction

July 24, 2023 — Veronica P. Adams & Koorosh Talieh - Hunton Insurance Recovery Blog
The hurdles policyholders have faced with the appraisal process in Florida are far from over. In the past, many Florida courts have limited the scope for appraisal, strictly construing the policy provision against the policyholder. Yet, recently, in Positano Place at Naples I Condominium Association, Inc., et al. v. Empire Indemnity Insurance Company, the Eleventh Circuit dismissed an insurer’s appeal of the district court’s ruling compelling appraisal and a stay of a pending litigation. In Positano Place at Naples I Condominium Association, Inc., et al. v. Empire Indemnity Insurance Company, the policyholder Positano filed a claim for property insurance benefits under the policy as a result of damage to the property from Hurricane Irma in 2017. After investigating the claim, Empire found that there was damage to only three of the five properties covered under the policy and disputed the amount of loss. Reprinted courtesy of Veronica P. Adams, Hunton Andrews Kurth and Koorosh Talieh, Hunton Andrews Kurth Ms. Adams may be contacted at vadams@HuntonAK.com Mr. Talieh may be contacted at ktalieh@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Boston Team Secures Summary Judgment Dismissal on Client’s Behalf in Serious Personal Injury Case

October 21, 2024 — Lewis Brisbois Newsroom
Boston, Mass. (October 14, 2024) - Boston Managing Partner Kenneth B. Walton and Partner Matthew M. O' Leary recently secured summary judgment on behalf of a civil engineering firm in a serious personal injury matter arising from a trip-and-fall incident in a mall parking lot. The client was retained to provide site civil engineering design for the parking lot of a local mall. The design included multiple bioretention areas known as rain gardens. In November of 2019, a woman tripped and fell while attempting to cross a rain garden to reach her car. She suffered significant bodily injuries, including a fracture of the cervical spine that resulted in partial paralysis. The woman and her husband sued the mall's owner for negligence and loss of consortium in June 2021. The owner, in turn, impleaded Lewis Brisbois' client and the lot's builder, asserting third-party claims for contribution, contractual and common law indemnity, and breach of contract. In addition, the builder cross-claimed against Lewis Brisbois' client for contribution and common law indemnity. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

What You Need to Know About Additional Insured Endorsements

August 30, 2017 — Gary Barrera - California Construction Law Blog
A well-drafted insurance clause is an integral part of a construction contract because it sets forth a subcontractor’s obligations to add the general contractor to its policies of insurance as an additional insured and identifies the manner by which the general contractor will qualify as an additional insured. In a typical construction contract, the general contractor will be an additional insured via a scheduled endorsement or a blanket endorsement. Scheduled Endorsements A scheduled endorsement contains a “schedule” in which the person or organization that is named in the schedule is added to the policy as an additional insured. The following scheduled endorsements are commonly used in construction contracts. Read the court decision
Read the full story...
Reprinted courtesy of Gary Barrera, Wendel Rosen Black & Dean LLP
Mr. Barrera may be contacted at gbarrera@wendel.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES