Fairfield Connecticut Building Expert Directory

Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can’t Look Back Again)

October 05, 2020 — Christopher G. Hill - Construction Law Musings
I’ve discussed the continuing litigation between White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc. previously here at Construction Law Musings because the case was another reminder that your construction contract terms matter and will be interpreted strictly here in the Commonwealth of Virginia. The prior opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision. In the latest opinion from the Court (PDF) the Court looked at when and how any liquidated damages would be calculated. In its June 22, 2020 opinion, the Court put the issue as follows:

White Oak’s motion for partial summary judgment presents a narrow issue: whether courts may consider the damages actually sustained by a party as a result of a contract breach when deciding if liquidated damages required by a contract “grossly exceed” a party’s actual damages.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Incorporate Sustainability in Building Design to Meet Green Construction Goals

September 25, 2018 — Norma Lehman - Construction Executive
A few miles outside the city limits of Austin, Texas, construction work is expected to soon begin on the Austin Ridge Bible Church’s tri-level, 80,000-square-foot building. The building will house a 2,500-seat sanctuary, classrooms and other spaces where congregants can gather for prayer and fellowship. When the project is completed, scheduled for the end of 2019, it will produce a worship place that will significantly reduce the building’s energy costs in the years ahead. Reprinted courtesy of Norma Lehman, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Hawaii Supreme Court Finds Subcontractor Has No Duty to Defend Under Indemnity Provision

July 14, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Hawaii Supreme Court vacated the decision of the Intermediate Court of Appeals [see prior post here] and determined that a subcontractor did not have a duty to defend the developer upon tender under an indemnify provision in the parties' contract. Arthur v. State of Hawaii, 2016 Haw. LEXIS 155 (June 27, 2016). A simplified version of the detailed facts and procedural history follows. The case involved the wrongful death of Mona Arthur. Mona typically gardened on the hillside behind her home. She would cross a concrete drainage ditch and climb over a two-foo-high chain length fence to reach the hillside. Mona was found lying in a concrete ditch with severe head injuries, which ultimately led to her death. Her husband and estate sued for her wrongful death. Claims were asserted for negligence in failing to build a fence higher than two feet, which would have prevented Mona from having access to the garden. Defendants included the Department of Hawaiian Home Lands; Kamehameha Investment Corporation ("KIC"), the developer; Design Partners, Inc., the architect; Coastal Construction Company, the general contractor; and Sato and Associates, the civil engineer. The second amended complaint sought punitive damages against KIC. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Reaffirming the Importance of Appeal Deadlines Under the Contract Disputes Act

January 26, 2017 — Chadd Reynolds – Autry, Hanrahan, Hall & Cook, LLP
A recent United States Court of Federal Claims (“COFC”) decision emphasizes the importance of deadlines for appealing a contracting officer’s (“CO”) decision under the Contract Disputes Act (“CDA”). On July 22, 2016, the COFC granted the consolidation of two naval contract dispute appeals totaling nearly $12.4 million in response to Nova Group/Tutor-Saliba’s (“NTS”) motion to resolve two Requests for Equitable Adjustment (“REA”) in the same forum. See Nova Group/Tutor-Saliba v. United States, No. 15-885C, 2016 WL 4009886, at *5 (Fed. Cl. July 22, 2016). NTS’s motion before the COFC sought to transfer an appeal of a REA before the COFC to the Armed Services Board of Contract Appeals (“ASBCA”), where another appeal of a REA arising under the same contract was presently on appeal. The COFC rejected NTS’s appeal to transfer the REA to the ASBCA because NTS did not appeal the REA within the 90-day limit under the CDA. Instead, the COFC allowed NTS to transfer the REA before the ASBCA to the COFC because timeliness was not an issue. Read the court decision
Read the full story...
Reprinted courtesy of Chadd Reynolds, Autry, Hanrahan, Hall & Cook, LLP
Mr. Reynolds may be contacted at reynolds@ahclaw.com

Common Law Indemnity Claim Affirmed on Justifiable Beliefs

June 30, 2016 — Rick Erickson – Snell & Wilmer Real Estate Litigation Blog
Yesterday, the Arizona Court of Appeals issued an interesting opinion in Hatch Development v. Solomon. Hatch illustrated two key points in real estate and construction litigation: (1) a contractor’s indemnity does not always require an expressly written obligation; and (2) when facts are undisputed that a contractor is solely at fault for a construction defect, a property owner can be indemnified after paying a neighboring property owner for damages caused by the contractor’s defective work. Read the court decision
Read the full story...
Reprinted courtesy of Rick Erickson, Snell & Wilmer
Mr. Erickson may be contacted at rerickson@swlaw.com

Angela Cooner Named "Top Lawyer" by Phoenix Magazine in Inaugural Publication

October 10, 2022 — Angela L. Cooner - Lewis Brisbois
Phoenix, Ariz. (September 7, 2022) – Phoenix Partner Angela L. Cooner was recently recognized for her work in Commercial Litigation by Phoenix Magazine in its inaugural list of Top Lawyers. Ms. Cooner was named a Top Lawyer after Phoenix Magazine partnered with research firm Data Joe to collect and tally online survey results from local practicing attorneys. The survey asks respondents to provide the names of up to three attorneys they deem the best in 39 legal specialties. After the votes are tallied and the nominees are confirmed to be members of Valley-based firms and in good standing, the top 10-20% of vote-getters in each category are named to the Top Lawyers list. Ms. Cooner is a member of Lewis Brisbois’ Construction and General Liability Practices. For more than two decades, she has managed an array of matters, including construction litigation, complex commercial litigation, professional liability cases, product liability issues, premises liability cases, and real estate litigation. Earlier this year, she was appointed vice-chair of the State Bar of Arizona’s inaugural Board of Legal Specialization Construction Defect Law Advisory Commission. Read the court decision
Read the full story...
Reprinted courtesy of Angela L. Cooner, Lewis Brisbois
Ms. Cooner may be contacted at Angela.Cooner@lewisbrisbois.com

Texas School District Accepts Settlement Agreement in Construction Defect Case

October 08, 2014 — Beverley BevenFlorez-CDJ STAFF
The Pine Tree ISD Board of Trustees “voted to accept a mediated settlement agreement to end litigation concerning the District’s middle school and its construction issues,” according to KETK News. Pine Tree ISD, located in Longview, Texas, “sued a number of defendant companies for construction and design defects at that campus.” The school district “will receive the total sum of $820,500,” which “will cover the District’s costs in remediating the campus to repair the construction problems, as well as implementing new systems designed to prevent future issues, both of which came out of the District’s general fund.” Read the court decision
Read the full story...
Reprinted courtesy of

Homebuilders See Record Bearish Bets on Shaky Recovery

June 18, 2014 — Callie Bost – Bloomberg
Someone thinks the housing rebound is built on shaky foundations. A record 180,000 puts traded on the SPDR S&P Homebuilders (XHB) exchange-traded fund on June 11, according to data compiled by Bloomberg. The contract with the highest ownership pays off in the event of a 20 percent slump by December in the ETF tracking stocks from DR Horton Inc. to Williams-Sonoma Inc. Prospects for rising interest rates and an uneven recovery in the housing market have hurt returns this year, sending the SPDR Homebuilders ETF down 3.3 percent. While economic data yesterday showed that builders broke ground on 1 million U.S. homes in May, permits, a proxy for future construction, decreased because of fewer applications for condominiums and apartment buildings. Read the court decision
Read the full story...
Reprinted courtesy of
Ms. Bost may be contacted at cbost2@bloomberg.net

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES