Fairfield Connecticut Building Expert Directory

The Word “Estimate” in a Contract Matters as to a Completion Date

February 12, 2024 — David Adelstein - Florida Construction Legal Updates
Language in a contract matters. The word “estimates” or “estimated” matters particularly when it comes to a date certain such as a substantial completion or completion date. Remember this. Here is an example. In Parque Towers Developers, LLC v. Pilac Management, Ltd., 49 Fla.L.Weekly D190a (Fla. 3d DCA 2024), a trial court held that the developer did not complete the construction of five condominium units by the date in the purchase agreements. The developer appealed because “[t]he agreements contain no date certain for the completion of the units, but rather include a clause that ‘Seller estimates it will substantially complete construction of the Unit, in the manner specified in this Agreement, by December 31, 2017, subject to extensions resulting from ‘Force Majeure (the ‘Outside Date’).’” Parque Towers, supra. Another provision in the purchase agreements stated, “[w]henver this Agreement requires Seller to complete or substantially complete any item of construction, that item will be understood to be complete or substantially complete when so completed or substantially completed in Seller’s opinion. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Judicial Panel Denies Nationwide Consolidation of COVID-19 Business Interruption Cases

October 05, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The Judicial Panel on Multidistrict Litigation denied motions to centralize pretrial proceedings in pending COVID-19 business interruption claims. In re COVID-19 Business interruption Protection Insurance Litigation, 2020 U.S. District. LEXIS 144446 (Aug. 12, 2020). Plaintiff policy holders sought consolidation, contending their policies provided coverage for business interruption losses caused by the COVID-19 pandemic and the related government orders suspending, or severely curtailing, operations of non-essential businesses. The Panel considered 15 actions on the pending motions, but had notice of 263 related actions. Some plaintiffs opposed centralization or sought to be excluded from any MDL. Some argued the Panel should centralize the coverage actions on a state-by-state, regional, or insurer-by-insurer basis. The Panel did not accept consolidation of all cases. There was little potential for common discovery across the litigation because there was no common defendant as the actions involved either a single insurer or insurer-group. The various cases involved different insurance policies with different coverages, conditions, exclusions, and policy language, purchased by different businesses in different industries located in different states. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

No Coverage for Counterclaim Arising from Insured's Faulty Workmanship

August 03, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The Eighth Circuit found there was no coverage for the insured's faulty workmanship. Am. Family Mut. Ins. Co., S.I. v. Mid-American Grain Distributors, LLC, 958 F.3d 748 (8th Cir. 2020). Mid-American contracted with Lehenbauer to design and construct a grain storage and distribution facility for Lehenbauer. Before the work was competed, Lehenbauer terminated Mid-American's services. Mid-American then sued Lehenbauer for breach of contract. Lehenbauer counterclaimed against Mid-American, alleged breach of "implied duties of workmanlike performance and fitness for a particular purpose" and negligence. Mid-American tendered the counterclaim to American Family. American Family accepted the tender under a reservation of rights, but sued Mid-American for a declaratory judgment. The district court granted American Family's motion for summary judgment, concluding that the counterclaims did not allege an occurrence. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Toolbox Talk Series Recap - Guided Choice Mediation

November 05, 2024 — Douglas J. Mackin - The Dispute Resolver
In the September 26, 2024 edition of Division 1's Toolbox Talk Series, Clifford Shapiro presented on Guided Choice Mediation (“GCM”) and how it can lead to better outcomes in construction disputes. GCM is an approach to mediation that focuses on early and efficient dispute resolution, which prominent mediators created as a public interest project. Shapiro described his particular variant of GCM based on his experience while acknowledging that other Guided Choice Mediators’ processes may differ from his in various ways. Shapiro’s brand of GCM focuses on ensuring that parties have reasonable expectations and appropriate settlement authority prior to arriving at a mediation. Some of the strategies to help accomplish these noble goals are (i) early mediator engagement, (ii) mediator facilitation of information exchange, (iii) mediator involvement with insurance issues (particularly important in construction defect cases, especially those with multiple defendants), (iii) pre-mediation ex parte meetings, and (iv) mediator participation in risk analysis. These strategies are not typical in the more traditional/historic approach to mediation in which mediation is scheduled based on a scheduling order, mediation statements are sent to the mediator roughly a week before the scheduled mediation (and sometimes not even shared with anyone other than the mediator), and the parties speak with the mediator for the first time on the day of the mediation. Read the court decision
Read the full story...
Reprinted courtesy of Douglas J. Mackin, Cozen O’Connor
Mr. Mackin may be contacted at dmackin@cozen.com

Know Your Obligations Under Both the Prime Contract and Subcontract

December 02, 2015 — Craig Martin – Construction Contractor Advisor
A recent case out of New Mexico highlights the importance for subcontractors to review their contract with the general and the contract between the general and the owner. In Centex/Worthgroup, LLC v. Worthgroup Architects, L.P, the architect claimed that the limitation of liability clause in the prime contract trumped the provisions of the subcontract. The court disagreed and ruled that the specific provision in the subcontract controlled. In the case, a general contractor was hired to expand and renovate a resort. The general contractor subcontracted with an architect to design a mechanically stabilized earth wall. The prime contract contained a limitation of liability clause that states:

general contractor shall require its design professional Subcontractor(s) to obtain insurance in an amount not less than $3,000,000. Owner agrees that it will limit general contractor’s liability to Owner for any errors or omissions in the design of the Project to whatever sums Owner is able to collect from the above described professional errors and omissions insurance carrier.

Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Power & Energy - Emerging Insurance Coverage Cases of Interest

November 30, 2020 — David G. Jordan & Tiffany Casanova - Saxe Doernberger & Vita, P.C.
The Power & Energy sector faces a multitude of risks that impact output and profitability, requiring sound risk management and robust insurance programs. As of recent, like most industries, there have been significant challenges facing the industry in light of COVID-19. These issues, including decreased product demand as well as supply- side issues, have been well documented. However, other issues continue to impact Power & Energy providers, with significant insurance coverage implications that are worthy of note. Below is a summary of three open cases of interest, where declaratory relief has been sought by energy providers’ insurance carriers, seeking an avoidance of coverage. 1. Fracking Dispute and “Intentional Acts” In the Texas case of The James River Insurance Co. v. Clearpoint Chemicals LLC et al., No. 4:20-cv-0076 (N.D.Tex), James River Insurance Company (“James River”) is asking a federal district court to declare that it does not owe defense or indemnity to its insured for acts it defines as both intentional and/or malicious acts. Reprinted courtesy of David G. Jordan, Saxe Doernberger & Vita, P.C. and Tiffany Casanova, Saxe Doernberger & Vita, P.C. Mr. Jordan may be contacted at DJordan@sdvlaw.com Ms. Casanova may be contacted at TCasanova@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Best Lawyers® Recognizes 49 White and Williams Attorneys

September 16, 2024 — White and Williams LLP
Thirty-eight White and Williams lawyers were recognized in Best Lawyers in America® 2025. Inclusion in Best Lawyers® is based entirely on peer-review. The methodology is designed to capture, as accurately as possible, the consensus opinion of leading lawyers about the professional abilities of their colleagues within the same geographical area and legal practice area. Best Lawyers® employs a sophisticated, conscientious, rational, and transparent survey process designed to elicit meaningful and substantive evaluations of quality legal services. In addition, eleven lawyers were recognized as Best Lawyers: Ones to Watch® in America. This recognition is given to attorneys who are earlier in their careers for outstanding professional excellence in private practice in the United States. The firm is also pleased to announce Best Lawyers® has recognized three attorneys as "Lawyer of the Year” including: Chuck Eppolito, Litigation - Health Care, Philadelphia, who focuses his practice on medical malpractice defense as well as other insurance-related defense; William D. Kennedy, Litigation – Insurance, Philadelphia, who focuses his practice on complex claims of injury and damage arising in both the professional and general liability contexts; and, Michael O. Kassak, Litigation – Insurance, Cherry Hill, who focuses his practice on large complex commercial matters including insurance coverage and healthcare disputes. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

New California Construction Law for 2019

January 02, 2019 — Daniel F. McLennon - Smith Currie
The California Legislature introduced over 2637 bills in the second half of the 2017-2018 session. This article summarizes some of the more important bills affecting contractors in their roles as contractors, effective January 1, 2019, unless otherwise noted. Not addressed here are many other bills that will affect contractors in their roles as businesses, taxpayers, and employers. Each of the summaries is brief, focusing on what is most important to contractors. Because not all aspects of these bills are discussed, each summary’s title is a live link to the full text of the referenced bills for those wanting to explore the details of the new laws. Read the court decision
Read the full story...
Reprinted courtesy of Daniel F. McLennon, Smith Currie
Mr. McLennon may be contacted at dfmclennon@smithcurrie.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES