Seattle Washington Building Expert Directory

District Court Allows DBE False Claims Act Case to Proceed

February 23, 2017 — Wally Zimolong – Supplemental Conditions
Last week, I posted about how whistleblowers continue to receive large settlements related to DBE fraud. A somewhat recent case from the federal court in Maryland shows how whistleblowers are ferreting out DBE fraud on construction projects receiving any form of federal funding. The Case The case involves a bridge painting project in Maryland that was let by the Maryland State Highway Administration. The contract required the prime contractor to meet a 15% DBE participation goal. The prime contractor submitted a bid stating it would have 15.12% DBE participation. After it was awarded the contract, the prime contractor – as is typical – submitted additional forms certifying to the MSHA that 15.12% of its contract price would be performed by a DBE firm. The prime contractor indicated that one DBE subcontractor, Northeast Work and Safety Boats, LLC (“NWSB”), would perform the 15.12% of the work. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Gloria Gaynor Sues Contractor over Defective Deck Construction

October 22, 2013 — CDJ STAFF
Gloria Gaynor, known for her 1978 disco hit, “I Will Survive” is suing the firm that renovated her second-floor deck, alleging that the work lead to water intrusion into her home. Ms. Gaynor also accuses the company of consumer fraud, alleging that Diaz Landscape Design & Tree Service LLC lacked registration as a home improvement contractor and failed to obtain a building permit for the structure. Ms. Gaynor paid about $38,000 for the replacement of her deck and other renovations to her property in 2007. Subsequently, the singer noticed “ponding of water on the deck, water damage to wood sills and supports, and the formation of mold,” according to the lawsuit. Diaz Landscape attempted repairs, but “the problems persisted and continue to persist causing further damage.” The lawsuit claims that the cost of replacing the defective deck construction would cost about $120,000. Read the court decision
Read the full story...
Reprinted courtesy of

What Makes a Great Lawyer?

February 06, 2019 — Danielle Carter - Bremer Whyte Brown & O'Meara LLP
Good lawyers have mastered and understand the analytical and communication skills taught in law school, but great lawyers build upon this foundation by continuing to develop traits and skills for success. Here are five tips to help good lawyers enhance client outcomes and excel within their profession. Be Objective Lawyers cannot be effective advocates unless they are first willing to perceive and analyze problems from all angles. Lawyers must discern strong claims from weak; urgent concerns from long-term; and large issues from small. A lawyer who adopts the tone of an emotionally-charged client risks alienating the court and jury. Read the court decision
Read the full story...
Reprinted courtesy of Danielle Carter, Bremer Whyte Brown & O'Meara LLP
Ms. Carter may be contacted at info@bremerwhyte.com

Liebherr Claims Crane Not Cause of Brazil Stadium Construction Accident

February 14, 2014 — Beverley BevenFlorez-CDJ STAFF
Crane manufacturer Liebherr said in a statement that “its crane was not the cause” of the November 2013 construction incident that killed two workers, according to KHL. Liebherr claimed that “its investigations show that the crane had no technical defects and that the ground was not sufficiently stable for crane travel with a suspended load on the day of the accident.” Liebherr “assumes that all the reports currently being prepared about the accident will not reach any different conclusions,” reported KHL. Read the court decision
Read the full story...
Reprinted courtesy of

Safety Versus a False Sense of Security: Challenges to the Use of Construction Cranes

March 18, 2019 — Christopher Machut - Construction Executive
The history of safety is, in part, the history of resistance to safety. From transportation and travel to sports and entertainment, the safeguards taken for granted were once too allegedly controversial or costly for companies to grant to consumers. Imagine driving a car without a seatbelt or being a passenger in a minivan without side-impact airbags or anti-lock brakes, or playing football without a helmet or riding a roller coaster without a shoulder harness. Imagine, too, pulling out of parking space without a rear-view camera, unable to see passing cars or pedestrians. Cameras are now as common among compact cars as on the most uncommonly expensive sports cars and sedans. And yet, the technology that earns drivers a discount on car insurance is the same or mostly similar technology that insurers refuse to cover elsewhere. The technologies that makes parallel parking easier or easing a car into traffic a cinch is considered an extravagance on construction equipment, despite the dangers crane operators face but cannot see, despite what workers on the ground can see but not forecast, despite what cameras can record and capture. Reprinted courtesy of Christopher Machut, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

BHA has a Nice Swing Donates to CDCCF

May 21, 2014 — Beverley BevenFlorez-CDJ STAFF
Bert L. Howe & Associates (BHA) would like to congratulate the winners of the BHA Has a Nice Swing golf game for charity. With the help of the participants, BHA was able to donate $1800 to the Construction Defect Community Charitable Foundation (CDCCF). CDCCF was established to provide financial assistance for active members of the construction defect community who have uninsured expenses because of a disability, sickness, and/or the death of a community member or their immediate family member. BHA would also like to congratulate their booth’s raffle winners. Prizes included an iPad Air, four sets of Dodger tickets, a Day at the Del Mar Races, and Best Buy gift cards. Read how the CDCCF assists the construction defect community... Read the court decision
Read the full story...
Reprinted courtesy of

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Are Proprietary Specifications Illegal?

April 11, 2018 — Wally Zimolong – Supplemental Conditions
A friend came to me with a question regarding a case he was working: “can a public owner require that bidders use a specific brand name product?” “Of course not,” I said “proprietary specifications are illegal.” Or, at least that’s what I assumed. To my surprise, the law in the Commonwealth of Pennsylvania is not as clear as it is in other jurisdictions. What is a proprietary specification? A proprietary specification lists a product by brand name, make, model and/model that a contractor must (shall) utilize in construction. A basic example of a proprietary specification would state:

“Air Handlers shall be “Turbo Max” as manufactured by Chiller Corp.”

There are two problems with a proprietary specification (other than potentially being illegal): (a) they limit competition, and (b) invite steered contract awards. They limit competition because it limits the type of material that can be used on the project. In the example above, there could be equivalent air handlers available at a better price but the contractor could not use that lower priced product in its bid. Thus, the taxpayers end up paying more for tile. Also, contractors may not be able to secure a certain brand name product because of exclusive distribution agreements. Again, using the example above, contractor A’s competitor may have the exclusive distribution agreement with Chiller Corp. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES