Seattle Washington Building Expert Directory

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Cal/OSHA ETS: Newest Version Effective Today

January 17, 2022 — Amy R. Patton, Matthew C. Lewis & Rana Ayazi - Payne & Fears
The newest version of the Cal/OSHA ETS goes into effect today, Jan. 14, 2022, and will expire on April 15, 2022. A redline of the recently expired Cal/OSHA ETS and the newest Cal/OSHA ETS is available HERE. The newest Cal/OSHA ETS, which was drafted prior to Dec. 16, 2021, is already partially out-of-date based on the California Department of Public Heath’s Guidance For the Use of Masks (released Jan. 5, 2022) and the CDPH’s Guidance for Local Health Jurisdictions on Isolation and Quarantine of the General Public (released Jan. 8, 2022); these changes have been addressed in the Cal/OSHA ETS FAQs. With all of these changes occurring (not to mention all of the litigation surrounding the now-stayed federal OSHA ETS), California employers are asking: How do I comply with the current Cal/OSHA ETS and the updated CDPH Guidance? Here are the key points to ensure you are in compliance:

New Shorter Isolation and Quarantine Periods

Day 0: First day of symptoms or the day a positive test specimen was collected. Begin isolation.
Day 1: First full day after symptoms developed or positive test specimen was collected.
Day 5: Recommended day to take COVID-19 test.

Reprinted courtesy of Amy R. Patton, Payne & Fears, Matthew C. Lewis, Payne & Fears and Rana Ayazi, Payne & Fears Ms. Patton may be contacted at arp@paynefears.com Mr. Lewis may be contacted at mcl@paynefears.com Ms. Ayazi may be contacted at ra@paynefears.com Read the court decision
Read the full story...
Reprinted courtesy of

Top 10 Take-Aways from the 2024 Fall Forum Meeting in Pittsburgh

December 03, 2024 — Marissa L. Downs - The Dispute Resolver
Over 500 construction law attorneys and consultants convened last week at the confluence of three rivers in what became the first-ever meeting in Pittsburgh, Pennsylvania of the ABA Forum on Construction Law. The Steel City was a fitting backdrop for a meeting focused on issues of design in construction. Thanks to the hard work of many, most notably the newly minted Forum Chair Keith Bergeron and Meeting Coordinators Kendall Woods and Michael Clark, the meeting's attendees brought home new connections and a host of new lessons learned. Read on for my top 10 take-aways from the 2024 Fall Meeting in Pittsburgh and feel free to share yours in the comments below. 10. An architect's standard of care does not require perfection. A common refrain across many of the meeting's plenary sessions was that any design that is produced by human hands will never be perfect. In recognition of our own fallibility, the legal standard to which design professionals will be held to account does not require that their designs be error-free. A design professional must generally exercise the degree of care and skill ordinarily exercised by professionals performing similar services under similar circumstances. Establishing what that means in each locality will vary and will most likely need to be supported by the expert opinion of another practicing design professional. Read the court decision
Read the full story...
Reprinted courtesy of Marissa L. Downs, Laurie & Brennan, LLP
Ms. Downs may be contacted at mdowns@lauriebrennan.com

Legal Disputes Soar as Poor Information Management Impacts the AEC Industry

July 03, 2022 — Ideagen Plc
Managers in Architecture, Engineering and Construction (AEC) are facing more disruptive disputes in 2022 compared to last year according to the latest independent research from regulatory compliance company Ideagen. The survey of business leaders from AEC firms in the US and UK revealed that 78% of respondents experienced some kind of dispute in the business, compared to 63% in 2021, with information accessibility and visibility, caused largely by high staff turnover, the main root causes. With the challenges that the industry continues to face following COVID and increasing costs of materials, this is an added but unnecessary challenge facing the industry. Stuart Rowe, Vice President of Collaboration Strategy at Ideagen, whose customers include the US Navy, Gensler, Arup and Ramboll, said: "The working world has continued to change in the last 12 months, which is reflected in the AEC industry's evolving priorities. The COVID-19 pandemic led to a huge shift to remote working which saw an increased need for effective collaboration tools, however, this year is appears that hybrid working is the new normal in the industry. "Four-fifths of the people we spoke to said email is still king for project correspondence. This is a huge concern as most project scope changes reside in email inboxes. Failing to properly manage all information and records also prevents a Golden Thread, or a Single Source of Truth, across projects and businesses." Ideagen undertook the independent survey to support developments to their Mail Manager software, used by 2,500 architecture, engineering and construction firms in 16 countries worldwide. It revealed a number of insights into how the industry is managing changing work patterns. Download the full research here. Read the court decision
Read the full story...
Reprinted courtesy of

Candis Jones Named “On the Rise” by Daily Report's Georgia Law Awards

September 29, 2021 — Candis Jones - Lewis Brisbois Newsroom
Atlanta Partner Candis Jones was named a lawyer “On the Rise” by the Daily Report (part of Law.com). Ms. Jones is one of 20 attorneys from Georgia to receive this distinction as part of the publication's 2021 Georgia Law Awards. The Daily Report’s “On the Rise” category recognizes outstanding attorneys under the age of 40 who have made an impression on their colleagues, their clients, and the larger legal community of Georgia. Winners are selected by the publication’s editorial staff. Ms. Jones is a member of Lewis Brisbois' General Liability Practice and has extensive experience with insurance defense, premises liability, personal injury, and medical malpractice cases. Her clients include Fortune 500 companies, numerous insurance carriers, and a major metropolitan transit authority. Outside her legal practice, Ms. Jones is an active member of her legal community and was recently installed as President of the Gate City Bar Association, the oldest African-American bar association in the State of Georgia. Read the court decision
Read the full story...
Reprinted courtesy of Candis Jones, Lewis Brisbois
Ms. Jones may be contacted at Candis.Jones@lewisbrisbois.com

Harmon Towers to Be Demolished without Being Finished

October 02, 2013 — CDJ STAFF
Engineering.com looks at why the Harmon Tower in Las Vegas will be coming down at some point in the future. Construction stopped, unfinished in 2008. Taking the building down will cost about $400 million, which the building’s owner feels that the developer should pay. Inspectors concluded that the building did not meet the earthquake specifications for Las Vegas. The contractor claimed that the fault was due to the design specifications and that the supports were further weakened during destructive testing. Read the court decision
Read the full story...
Reprinted courtesy of

Finding Plaintiff Intentionally Spoliated Evidence, the Northern District of Indiana Imposes Sanction

March 14, 2018 — Shannon M. Warren – The Subrogation Strategist
On January 23, 2018, the Northern District of Indiana issued a decision that clarifies what constitutes spoliation of evidence under Indiana law. In Arcelormittal Ind. Harbor LLC v. Amex Nooter, LLC, 2018 U.S. Dist. LEXIS 10141 (N.D. Ind.), the defendant filed a motion for sanctions, alleging that the plaintiff intentionally spoliated critical evidence. The defendant sought dismissal of the action, asserting that the plaintiff intentionally discarded and lost important physical evidence within hours of a fire that occurred while the defendant’s employees were performing work at its facility. The decision underscores the importance of taking immediate action to properly identify and secure potentially material evidence in order to satisfy ones duty to preserve pre-suit evidence and avoid any spoliation defenses and associated sanctions. In Arcelormittal, the court initially considered whether to apply state or federal law when analyzing a litigant’s duty to preserve pre-suit evidence and determine if that party committed spoliation. Since the case was brought in federal court based on diversity jurisdiction, the court held that Indiana state law governed the spoliation analysis. As noted by the court, under Indiana state law, “the intentional destruction, mutilation, altercation, or concealment of evidence” is considered to be spoliation. Thus, under Indiana law, a party who knew or should have known that litigation was imminent “may not lose, destroy or suppress material facts or evidence.” The plaintiff argued that Indiana law requires a showing of improper purpose or bad faith to establish that a litigant spoliated evidence. The Arcelormittal court rejected the plaintiff’s argument. Read the court decision
Read the full story...
Reprinted courtesy of Shannon M. Warren, White and Williams LLP
Ms. Warren may be contacted at warrens@whiteandwilliams.com

Ownership is Not a Conclusive Factor for Ongoing Operations Additional Insured Coverage

November 15, 2017 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In McMillin Management Services v. Financial Pacific Ins. Co. (No. D069814, filed 11/14/17), a California appeals court held that an insurer had a duty to defend a general contractor under an “ongoing operations” additional insured (AI) endorsement for damage occurring after the named insured subcontractor completed its work, because the endorsement did not limit coverage solely to liability during the subcontractors’ ongoing operations, but rather, broadly provided coverage for liability “arising out of” such operations. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES