Economic Damages and the Right to Repair Act: You Can’t Have it Both Ways
March 16, 2017 —
Garret Murai – California Construction Law BlogIn 2002, the California State Legislature passed Senate Bill 800 also known as the Right to Repair Act (Civil Code Sections 895 et seq.) in an effort to stem a then rising tide in residential construction defect litigation.
SB 800, which applies to newly constructed residential units including single-family homes and condominiums (but not condominium conversions) sold after January 1, 2003, was intended to curb residential construction defect lawsuits by giving developers and others in the construction chain an opportunity to repair construction defects before being sued in court. SB 800 also provides minimum construction standards and limits the time in which a homeowner can bring a claim for construction defects.
In Acqua Vista Homeowners Association v. MWI, Case No. D068406 (January 26, 2017), the California Court of Appeals for the Fourth District examined the circumstances in which homeowners can sue a material supplier under the Right to Repair Act.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
Bailout for an Improperly Drafted Indemnification Provision
February 11, 2019 —
David Adelstein - Florida Construction Legal UpdatesA recent opinion came out that held that even though an indemnification provision in a subcontract was unenforceable per Florida Statute s. 725.06, the unenforceable portion is merely severed out of the indemnification clause leaving the rest of the clause intact. In essence, an otherwise invalid indemnification clause is bailed out by this ruling (which does not even discuss whether this subcontract had a severability provision that states that if any portion of any provision in the subcontract is invalid, such invalid portion shall be severed and the remaining portion of the provision shall remain in full force and effect).
This opinion arose from a construction defect case, CB Contractxors, LLC v. Allens Steel Products, Inc.,43 Fla.L.Weekly D2773a (Fla. 5thDCA 2018), where the general contractor, sued by an association, flowed down damages to subcontractors based on the contractual indemnification provision in the subcontracts. Subcontractors moved to dismiss the contractual indemnification claim because it was not compliant with Florida Statute s. 725.06. The indemnification provision required the subcontractors to indemnify the general contractor even for the general contractors own partial negligence, but failed to specify a monetary limitation on the extent of the indemnification as required by Florida Statute s. 725.06. (The indemnification clause in the subcontract was the standard intermediate form of indemnification that required the subcontractor to indemnify the general contractor for claims regardless of whether the claims were caused in part by the general contractor.)
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
Damage to Plaintiffs' Home Caused By Unmoored Boats Survives Surface Water Exclusion
April 06, 2016 —
Tred R. Eyerly – Insurance Law HawaiiThe magistrate's recommended decision found that damage to plaintiffs' home caused by boats that became loose during Hurricane Sandy was not barred as "water borne material" under the surface water exclusion. Spindler v. Great N. Ins. Co., 2016 U.S. Dist. LEXIS 16532 (E.D. N. Y. Feb. 2, 2016).
Plaintiffs' home abutted the East Bay. The property had an exterior deck and a long dock that floated on the bay. Hurricane Sandy damaged plaintiffs' home and dock. A neighbor witnessed two boats, driven by the storm, repeatedly strike plaintiffs' dock, house, and deck. There was no dispute that water infiltrated plaintiffs' yard prior to the entry of the boats. Plaintiffs spent $286,280 to repair damaged items from the storm.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Nine ACS Lawyers Recognized as Super Lawyers – Two Recognized as Rising Stars
August 26, 2024 —
Ahlers Cressman & Sleight PLLCGoing outside the norm of our blogs, which usually discuss construction related issues, Ahlers, Cressman, & Sleight is pleased to announce that nine members of our firm have been selected to the 2024 Washington Super Lawyers list.
Each year, a rigorous process that involves a nomination by peers and a third-party verification of honors, awards, verdicts, settlements, and other criteria relating to their work as an attorney, aims to select no more than five percent of the lawyers in Washington state from no more than seventy practice areas for this distinction. As mentioned, the first step in the process is to be evaluated on their work as an attorney, next candidates are evaluated by their peers and given ratings based on the information known about their work. Finally, candidates are grouped into four firm-size categories and final selections are made. The grouping process is done so that candidates are compared fairly to their peers by firm size, eliminating the potential unfairness that comes with comparing large and small firm outcomes and attorney practices.
The Rising Star list involves an even narrower criteria than the Super Lawyers list. The initial process is the same, however, candidates for the Rising Stars list must be under the age of forty or have less than ten years of experience. For this category less the two and a half percent of lawyers in Washington are selected, making this quite a feat for those who have accomplished the honor.
Read the court decisionRead the full story...Reprinted courtesy of
Ahlers Cressman & Sleight PLLC
Deescalating Hyper Escalation
July 05, 2023 —
Paul F. Williamson - Construction Executive Recent years have seen the construction industry get hit by a perfect storm of rising costs, workforce shortages, delivery delays, supply-chain issues, inflation, interest-rate hikes and materials price escalation. The cost of construction has become more expensive, leaving all parties to grapple with the sufficiency of their risk-management strategies and the ramifications of contracts that are ill-equipped to deal with unprecedented cost increases. Of particular concern to industry participants are the volatile price fluctuations that construction materials have undergone and how to appropriately mitigate the risks they present.
Although owners, general contractors and subcontractors may seek to mitigate future risks, many who are party to an existing contract all too often must scramble to divine how to absorb significantly more financial risk than they expected pre-pandemic. Contracts that were bid and entered into prior to the pandemic may have seen, in some instances, double- and triple-digit percent increases in prices due to hyper escalation, with little recourse to address such situations. While parties to private contracts are free to mitigate their risk through contract negotiations, parties to federal or state public procurements are somewhat more constrained.
Reprinted courtesy of
Paul F. Williamson, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
California Joins the Majority of States in Modifying Its Survival Action Statute To Now Permit Recovery for Pain, Suffering And Disfigurement
January 03, 2022 —
Krsto Mijanovic & Elizabeth D. Rhodes - Haight Brown & BonesteelOn January 1, 2022, California Code of Civil Procedure (“CCP”)Section 377.30 et seq., as amended by Senate Bill 447, otherwise known as the “survival action” statute1, goes into effect. On that date, all plaintiffs filing new civil cases filed on or after January 1, 2022, and before January 1, 2026, and plaintiffs in any action or proceeding granted trial preference pursuant to CCP Section 36 before January 1, 2022, will be expressly allowed to recover damages for a decedent’s pain, suffering, or disfigurement in a survival action.2 This is a significant change in California law. In that regard, California is now the 46th state to permit this form of recovery.
As reported in the Legislative Counsel’s Digest3, Consumer Attorneys of California and Consumer Federation of California, which co-sponsored Senate Bill 447, opined to the Legislature that the prior law provided a “death discount” to defendants which incentivized bad faith delays in resolution, and caused unnecessary congestion of the already overburdened court system. These argued issues will be vetted by the Legislature using the four-year reporting requirement that is also part of the amendment to the statute, requiring plaintiffs who recover this newly permitted category of damages to report the valuation and details of the case to the Judicial Council within 60 days of the judgment or other operative court document being entered in the court’s docket.4 The amendment will be evaluated by the Legislature for amendment or extension on or before January 1, 2026.
Reprinted courtesy of
Krsto Mijanovic, Haight Brown & Bonesteel and
Elizabeth D. Rhodes, Haight Brown & Bonesteel
Mr. Mijanovic may be contacted at kmijanovic@hbblaw.com
Ms. Rhodes may be contacted at erhodes@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Replacing Coal Plants with Renewables Is Cheaper 80% of the Time
May 31, 2021 —
Leslie Kaufman - BloombergAbout 80% of U.S. coal plants are now more expensive to keep running than to swap out for new wind and solar capacity, according to a report from Energy Innovation, a non-partisan climate and energy think tank.
While renewables cost more than fossil energy for much of the last century, prices for new wind and solar have dropped so quickly in recent years that they were already cheaper than new coal. This report shows that the price differential holds true for a growing amount of existing coal, as well. “This is becoming true for more and more plants moving forward—and at an accelerating pace,” said Eric Gimon, a senior fellow with Energy Innovation and a co-author of the report.
Coal has been steadily declining as a fixture of the U.S. energy mix for more than a decade due to combined pressure from activists and market forces. The Sierra Club, which runs the Beyond Coal campaign aimed at eliminating coal power in the U.S., says that 339 plants have either been retired or are on their way to retirement since 2010, leaving just 191 still operating indefinitely. (Michael R. Bloomberg, the founder and majority owner of Bloomberg LP, the parent company of Bloomberg News, has committed $500 million to launch Beyond Carbon, a campaign aimed at closing the remaining coal-powered plants in the U.S. by 2030 and slowing the construction of new gas plants.)
Read the court decisionRead the full story...Reprinted courtesy of
Leslie Kaufman, Bloomberg
Not So Fast, My Friend: Pacing and Concurrent Delay
April 25, 2022 —
William E. Underwood - ConsensusDocsWhen critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays.
Pacing versus Concurrent Delay
As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief.
Read the court decisionRead the full story...Reprinted courtesy of
William E. Underwood, Jones Walker LLP (ConsensusDocs)Mr. Underwood may be contacted at
wunderwood@joneswalker.com
