SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Mixing Concrete, Like Baking a Cake, is Fraught with Problems When the Recipe is Not Followed

February 26, 2015 — Garret Murai – California Construction Law Blog
“Mixing concrete, like baking a cake, is fraught with problems when the recipe is not followed.” – Justice Kenneth Yegan, State Ready Mix, Inc. v. Moffatt & Nichol, California Court of Appeal for the Second District, Case No. B253421 (January 8, 2015). I love jurists who aren’t afraid to mix in a little humour in their opinions. But “[t]he law,” as a framed needlepoint in one of my colleague’s offices says, “is serious business.” And the State Ready Mix case involved one of the thorniest problems in construction litigation: What to do when you’re sued and you think someone else is to blame. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Seven Former North San Diego County Landfills are Leaking Contaminants

April 07, 2011 — Beverley BevenFlorez CDJ STAFF

Deborah Sullivan Brennan of the North County Times reported that seven former dumps in San Diego are leaking contaminants into the surrounding groundwater. John R. Odermatt, a senior engineering geologist for the California Regional Water Quality Control Board s San Diego region, told the North County Times, “the risk to most county residents is very small or negligible, while local water supplies located in more rural areas may be at a somewhat elevated but unquantified level of risk.”



This issue is causing heavy scrutiny of a new proposed landfill in Gregory Canyon. The landfill would be located on 308 acres of undeveloped land near Pala, alongside the San Luis Rey River. The group “Save Gregory Canyon” has been speaking out against the landfill, stating that “the project threatens major detrimental impacts to both surface and groundwater, as well as a potential compromise of the two major San Diego Water Authority pipelines nearby.” Richard Felago, a Gregory Canyon Ltd. Consultant, told the North County Times that the 8-foot-thick liner, composed of layers of gravel and synthetic material, would not leak.



The appeal hearing is being rescheduled later this month after one of the three panelists recused himself due to having a competing interest in the property, according to the article by Gary Warth in the North County Times.



Read the full story (link 1)...
Read the full story (link 2)...

Read the court decision
Read the full story...
Reprinted courtesy of

---

CA Supreme Court Rejects Proposed Exceptions to Interim Adverse Judgment Rule Defense to Malicious Prosecution Action

August 24, 2017 — David W. Evans & Stephen J. Squillario – Haight Brown & Bonesteel LLP
In Parrish v. Latham & Watkins (No. S228277 - August 10, 2017) (“Parrish”), the California Supreme Court examined the “interim adverse judgment rule” in a different context than previous decisions on the subject. The rule provides that if an earlier action succeeds after a hearing on the merits, this success establishes the existence of probable cause and precludes a subsequent malicious prosecution action. In a typical case applying the rule, a plaintiff in the underlying action defeats the defendant’s motion for summary judgment but then loses the case at trial leading to a subsequent malicious prosecution claim. In Parrish, the Court addressed whether the rule applies when the trial court had denied the defendant’s summary judgment motion but concluded after the defense prevailed at a bench trial that the suit had been brought in “bad faith” due to a lack of evidentiary support. Reprinted courtesy of David W. Evans, Haight Brown & Bonesteel LLP and Stephen J. Squillario, Haight Brown & Bonesteel LLP Mr. Evans may be contacted at devans@hbblaw.com Mr. Squillario may be contacted at ssquillario@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Thank You for Seven Years of Election to Super Lawyers

May 01, 2023 — Christopher G. Hill - Construction Law Musings
It is with humility and a sense of accomplishment that I announce that I have been selected for the seventh straight year to the Virginia Super Lawyers in the Construction Litigation category for 2023. Add this to my recent election to the Virginia Legal Elite in Construction and I’ve had a pretty good year. As always, I am thrilled to be included on these peer-elected lists. So without further ado, thank you to my peers and those on the panel at Virginia Super Lawyers for the great honor. I feel quite proud to be part of the 5% of Virginia attorneys that made this list for 2023. The full lists of Virginia Super Lawyers will appear in the May edition of Richmond Magazine. Please check it out. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Sanctions Issued for Frivolous Hurricane Sandy Complaint Filed Against Insurer

February 26, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court for the district of New Jersey cracked down on a Texas law firm that filed 250 Hurricane Sandy related cases against insurers without adequate investigation. Lighthouse Point Marina & Yacht Club, LLC v. Int'l Marine Underwriters, 2015 U.S. Dist. LEXIS 6430 (D. N.J. Jan. 20, 2015). The Texas firm filed more that 250 actions in New Jersey courts against insurers to recover for alleged property damage caused by Hurricane Sandy. The original complaints were nearly identical with the same typos. The complaint in this case alleged that the insurer did not pay benefits under the policy for "extreme external and internal damages, as well as other wind-related loss," but did not specify the value or nature of the damage. The insurer answered that it sent an adjuster to the property soon after the storm and found wind damages to two fences, but no damage to any building on the property. The adjuster valued the claim at $1,612.00 and recommended a payment of $612.00, after applying the $1000 deductible. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Insurer Rejects Claim on Dolphin Towers

July 22, 2011 — CDJ STAFF

A year after residents were forced to leave Dolphin Towers in Sarasota, Florida because of concrete problems, some residents are defaulting on their obligations, abandoning their units. In June, the building’s insurer, Great American, rejected a claim, arguing that the building’s problems were due to latent defects, not covered under the policy. Repair estimates, previously put at $8.2 million, have now risen to $11.5 million. If homeowners cover this cost, it would require an assessment of about $100,000 for each unit.



About thirty owners are in arrears on dues and fees. Charlotte Ryan, the president of the Dolphin Tower board, wrote to owners, that “the board will have no choice but to lien your property and pursue foreclosure if you do nothing to bring your delinquencies up to date.” However, as homeowners default, the funding for repairs is imperiled. The board has already spent more than $500,000 on shoring up the building and hiring consultants. Their lawyers, on the other hand, are working on a contingency basis.



Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---