SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

A Lack of Sophistication With the Construction Contract Can Play Out In an Ugly Dispute

November 07, 2022 — David Adelstein - Florida Construction Legal Updates
There are times where a lack of sophistication can come back to haunt you. This is not referring to a lack of sophistication of the parties. The parties, themselves, could be quite sophisticated. This is referring to a lack of sophistication with the construction contract forming the basis of the relationship. While parties don’t always want to buy into the contract drafting and negotiation process, it is oftentimes the first document reviewed. Because contract terms and conditions are important. They govern the relationship, the risk, scope, amount, and certain outcomes with disputes. However, a lack of sophistication can play out when that contract that should govern the relationship, the risk, the scope, the amount, and certain outcomes doesn’t actually do that, or if it does, it does it poorly. An example of how bad a dispute can play out when it comes to the lack of sophistication on the front end is Avant Design Group, Inc. v. Aquastar Holdings, LLC, 2022 WL 6852227 (Fla. 3d DCA 2022), where a cost-plus contract was treated as a lump sum contract. Here, an owner planned to perform an extensive interior build-out to a residential unit. The owner had an out-of-country architect; because the architect was not licensed in Florida, the owner hired a local architect/designer to oversee construction and obtain goods and services for the residential interior build-out. The contract was nothing but a proposal of items and costs. The proposal stated the owner “would pay the cost of goods and services of the vendors, plus pay a ‘20% Interior Design & Administrative Fee’” to the local designer. Avant Design Group, 2022 WL at *1. The proposal further stated, “This preliminary budget of the Client’s construction costs include [sic] anticipated costs for construction materials, labor and sales tax. Any other cost, including but not limited to freight, cartage, shipping, receiving, storage and delivery are not included in the preliminary budget and will be invoiced separately.” Id., n.2. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Washington Court of Appeals Divisions Clash Over Interpretations of the Statute of Repose

August 07, 2023 — Masaki Yamada & Ryanne Mathisen - Ahlers Cressman & Sleight PLLC
The construction statute of repose under RCW 4.16.310 bars any claims arising from construction, design, or engineering of any improvement upon real property that has not accrued within six years after substantial completion or termination of services, whichever is later, even if the injury has not yet occurred. On June 20, 2023, Division One of the Washington Court of Appeals (Div. I) published its decision in Welch v. Air & Liquid Systems severely criticizing and rejecting the statute of repose reasoning contained in Maxwell v. Atlantic Richfield Co., 15 Wn. App. 2d 569, 476 P.3d 645 (2020), a Division Two (Div. II) opinion. More than a mere difference of opinion, the courts in Welch and Maxwell reached different results as to whether claims asserted against Brand Insulations, Inc. were barred by the statute of repose despite involving (i) the same procedural posture, both appeals from summary judgment decisions; (ii) the same facility, Atlantic Richfield Corporation’s (ARCO) petroleum refinery at Cherry Point in Ferndale; (iii) the same activity of installation of asbestos laden insulation on pipes; (iv) the same type of injury, mesothelioma; and (v) application of the same test set forth in Condit v. Lewis Refrigeration Co., 101 Wn.2d 106, 676 P.2d 466 (1984). Reprinted courtesy of Masaki Yamada, Ahlers Cressman & Sleight PLLC and Ryanne Mathisen, Ahlers Cressman & Sleight PLLC Mr. Yamada may be contacted at masaki.yamada@acslawyers.com Ms. Mathisen may be contacted at ryanne.mathisen@acslawyers.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Just When You Thought the Green Building Risk Discussion Was Over. . .

May 25, 2020 — Christopher G. Hill - Construction Law Musings
As a reader of Construction Law Musings, you no doubt realize that I am a big proponent of “green” or sustainable building. I have also been known to sound a bit like Eeyore when discussing the charge into the breach of green building without considering the potential risks. Thankfully, and despite some of the risk predictions made here (and elsewhere for that matter) there have not been but so many major court cases relating to these risks. However, as a recent article in ENR Magazine warns, this lack of litigation does not mean that you should let your guard down. Just because the economy, warnings by attorneys and others, and possible lack of financial incentive to sue have kept the litigation numbers down does not mean that the risks have gone away. LEED requirements, time horizons and other risks that have become evident during the process of vetting green building contracts and practices still must be dealt with in contracts and insurance policies. These risks are well laid out in the ENR article and in other places here at Musings so I won’t outline them in detail here. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Insurance Broker Stole NY Contractor's Payment, Indictment Alleges

March 21, 2022 — James Leggate - Engineering News-Record
A New York contractor was unknowingly uninsured as it worked on 14 Manhattan projects over four years because its insurance broker was pocketing its payments, according to an indictment. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

SNC-Lavalin’s Former Head of Construction Pleads Guilty to Bribery, Money Laundering

October 01, 2014 — Beverley BevenFlorez-CDJ STAFF
Riadh Ben Aissa, a former SNC-Lavalin executive, “pleaded guilty to charges including bribery and money laundering in Switzerland, according to a court filing released on Wednesday,” reported the Wall Street Journal. SNC-Lavalin “issued a separate statement acknowledging the court's acceptance of Mr. Ben Aissa's guilty pleas, adding it was recognized as ‘an injured party’ in the case and would recover an unspecified amount of money from him.” Chief Executive Robert Card stated, “SNC-Lavalin's goal is nothing less than to set a new standard for clean business in the engineering and construction industry,” as quoted by the Wall Street Journal. “We've adopted a zero-tolerance policy for ethics violations of any kind. We have the right people in place and systems and procedures which are designed to protect the company and its stakeholders from future fraudulent actions." Read the court decision
Read the full story...
Reprinted courtesy of

---

Cincinnati Team Secures Summary Judgment for Paving Company in Trip-and-Fall Case

February 05, 2024 — Lewis Brisbois
Cincinnati, Ohio (January 25, 2024) - In a recent decision by the Oldham County Circuit Court, Lewis Brisbois Partner Andrew Weber and Associate Jason Paskan obtained summary judgment for a paving company client after successfully arguing that their client did not owe the plaintiff a duty at the time leading up to her trip and fall. Although the court concluded that there was a genuine issue of fact as to whether a parking space wheel stop actually caused her fall, the court noted that whether the wheel stop “constituted an unreasonably dangerous condition necessitating a duty to eliminate them or warn of them is an entirely different matter.” Rebecca Reynolds v. Baptist Healthcare System, Inc., et al., Oldham Circuit Court Case No. 21-CI-00236, *6 (Dec. 21, 2023). The plaintiff in Reynolds drove to the hospital with her sister-in-law for medical testing. Id. at * 2. While both had been to the hospital before, due to COVID and construction in the emergency department, they had to take a different entrance into the hospital. Id. In the plaintiff’s attempt to navigate the parking lot, she allegedly tripped over a black wheel stop that was covered by a shadow. Id. The plaintiff sued the hospital as the landowner and the paving company working in the hospital’s parking lot, among others, under the theory that the failure to stripe the wheel stop, closing off spaces with the black wheel stops, or posting warnings about the condition of the parking lot would have prevented her fall. Id. at *2-3. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Chinese Billionaire Developer Convicted in UN Bribery Case

August 02, 2017 — Bob Van Voris - Bloomberg
A Chinese developer was convicted of charges he paid bribes to win backing for a United Nations conference center that he hoped to build in Macau. A jury in Manhattan on Thursday found the developer, billionaire Ng Lap Seng, guilty of all six charges he faced, including conspiracy, bribery and money laundering, in the biggest UN corruption scandal since the oil-for-food program in the early 2000s. Prosecutors claimed Ng funneled hundreds of thousands of dollars to former UN General Assembly President John Ashe and other officials. Read the court decision
Read the full story...
Reprinted courtesy of Bob Van Voris, Bloomberg

---