Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected
September 05, 2022 —
Margarita Kutsin - Ahlers Cressman & Sleight[
1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion.
WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT.
Read the court decisionRead the full story...Reprinted courtesy of
Margarita Kutsin, Ahlers Cressman & SleightMs. Kutsin may be contacted at
margarita.kutsin@acslawyers.com
Suppliers of Inherently Dangerous Raw Materials Remain Excluded from the Protections of the Component Parts Doctrine
December 02, 2015 —
Leah B. Mason & Michael J. Worth – Haight Brown & Bonesteel, LLPIn Brady v. Calsol, Inc. 2015 No. B262028, the California Court of Appeal, Second District, reversed summary judgment for a raw materials supplier where there was a triable issue of fact as to whether the benzene levels contained in the supplier’s mineral spirits could have caused plaintiffs’ leukemia.
Plaintiffs were mechanics Ernest Brady and David Gibbs, who used Safety-Kleen solvent to degrease automotive parts. Brady and Gibbs were diagnosed with leukemia allegedly caused by exposure to Safety-Kleen solvent during the course of their employment. In 2008, Plaintiffs sued Calsol, Inc., a distributor of mineral spirits for the ultimate manufacturer, Safety-Kleen Systems, Inc. Plaintiffs asserted negligence and strict products liability claims. Specifically, plaintiffs alleged that benzene, a carcinogen found in mineral spirits, caused their leukemia. Benzene is only carcinogenic to humans at certain levels. The parties dispute the levels of benzene found in the mineral spirits supplied to Safety-Kleen. Calsol contended the benzene levels were present only in low concentrations. Plaintiffs alleged the benzene levels were capable of causing injury.
Reprinted courtesy of
Leah B. Mason, Haight Brown & Bonesteel LLP and
Michael J. Worth, Haight Brown & Bonesteel LLP
Ms. Mason may be contacted at lmason@hbblaw.com
Mr. Worth may be contacted at mworth@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Texas Supreme Court Rules That Subsequent Purchaser of Home Is Bound by Original Homeowner’s Arbitration Agreement With Builder
May 29, 2023 —
Kim Altsuler - Peckar & Abramson, P.C.In a new opinion
Lennar Homes of Texas Land and Construction, Ltd., et al. v. Kara Whiteley, Cause No. 21-0783, 66 Tex. Sup. Ct. J. 8740, issued May 12, 2023, the Texas Supreme Court partially reversed two lower court decisions and held that an arbitration provision contained in the original homeowner’s contract with the builder was binding on a subsequent homeowner. In the decision, the court found that Kara Whiteley—the second owner of the home in Galveston, Texas—was bound to arbitrate her construction defect claims with Lennar by virtue of the doctrine of “direct-benefits estoppel.” The rationale was based on the fact that Whitely was seeking benefits emanating from Lennar’s contract with the original homeowner.
The residence in question was first purchased from Lennar in May 2014. Whiteley purchased the home in July 2015. The original contract documents included several arbitration provisions—one in the Purchase and Sale Agreement, one in the Limited Warranty issued by Lennar, and one in the general warranty deed. Whiteley sued Lennar in Galveston County District Court alleging mold growth and other defects at the property. Lennar moved for arbitration and its motion was granted. The parties arbitrated the case and Lennar received an award in its favor. Lennar then moved the District Court to confirm the arbitration award, and Whiteley filed a cross-motion to vacate the award, arguing that Lennar’s original motion to compel arbitration should not have been granted. The District Court agreed with Whiteley, vacating the arbitration award. Lennar appealed. The Court of Appeals affirmed the District Court’s vacatur, and Lennar appealed to the Texas Supreme Court.
Read the court decisionRead the full story...Reprinted courtesy of
Kim Altsuler - Peckar & Abramson, P.C.Ms. Altsuler may be contacted at
kaltsuler@pecklaw.com
New Executive Order: Revitalizing Our Nation’s Commitment to Environmental Justice for All
May 08, 2023 —
Anthony B. Cavender - Gravel2GavelThe White House has released the text of the President’s new Executive Order strengthening the Federal Government’s commitment to taking new actions to enhance and promote environmental justice. The Order was published in the Federal Register on April 26, 2023 at 88 FR 25251. President Clinton’s pioneering 1994 Executive Order remains effective, but the Federal Government must, as part of a whole-of-government approach to environmental justice, “build upon and strengthen its commitment to deliver environmental justice to all communities across America.”
Unlike that Order, this Order defines “environmental justice.” For purposes of this new Order, “environmental justice” takes into account all adverse human health and environmental effects and hazards, including those related to climate change, the cumulative impacts of environmental and other burdens, and the legacy of racism or other structural or systematic barriers, and ensures equitable access to a healthy, sustainable and resilient environment in which to live, play, work, learn, worship and engage in cultural and subsistence practices.
“Federal activity” is now broadly defined as “any agency rulemaking, guidance, policy, program, practice or action that affects or has the potential to affect human health and the environment, including any agency action related to climate change.” This Order references the seven previous Executive Orders devoted to climate change, clean energy and the Inflation Reduction Act.
Read the court decisionRead the full story...Reprinted courtesy of
Anthony B. Cavender, PillsburyMr. Cavender may be contacted at
anthony.cavender@pillsburylaw.com
Homeowner Protection Act of 2007 Not Just for Individual Homeowners Anymore?
March 22, 2017 —
Maggie Stewart - Colorado Construction Litigation On March 9, 2017, the Colorado Court of Appeals announced its decision in Broomfield Senior Living Owner, LLC v. R.G. Brinkmann Company, No. 16CA0101, 2017 COA 31 (Colo. App. Mar. 9, 2017). As a matter of first impression, the Court evaluated whether a senior living facility constitutes “residential property” protected by the Homeowner Protection Act of 2007 ("HPA") provision of the Construction Defect Reform Act (CDARA).
In 2007, Plaintiff Broomfield entered into a contract with Defendant Brinkmann for construction of a senior assisted and independent living facility. The contract contained warranty provisions related to the quality of construction and cautioned that Plaintiff’s failure to provide Defendant with prompt notice of any defects would result in waiver of any claim for breach. The contract also limited Defendant Brinkmann’s liability by identifying three separate accrual provisions that would determine the time period in which Plaintiff could bring a claim. The project was completed in 2009.
Read the court decisionRead the full story...Reprinted courtesy of
Maggie Stewart, Higgins, Hopkins, McLain & Roswell, LLCMs. Stewart may be contacted at
stewart@hhmrlaw.com
Going Digital in 2019: The Latest Technology for a Bright Future in Construction
February 18, 2019 —
Jim Romeo - Construction ExecutiveThe spectrum of technology available to today’s contractors is wide and deep. This techno-ecosystem will change just about every operational tick and tock needed to build world-class projects—from where and how people work to what equipment they use and how they record payments.
“Generally speaking, the use of technology in construction is surging, particularly in the past three to five years,” says Chris Amato, principal and national advisory leader for the Chicago-based management consultancy Grant Thornton. “It’s becoming the cost of doing business; every player, at some point or another, is going to need to embrace it to some degree. The key questions are where to start, where to invest and how to minimize risk.”
Reprinted courtesy of
Jim Romeo, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
In Pennsylvania, Contractors Can Be Liable to Third Parties for Obvious Defects in Completed Work
July 10, 2023 —
Michael L. DeBona - The Subrogation StrategistIn Brown v. City of Oil City, No. 6 WAP 2022, 2023 Pa. LEXIS 681 (2023), the Supreme Court of Pennsylvania (Supreme Court) recently held that a contractor can be liable for dangerous conditions it creates even if the hazard is obvious or known by the property owner. In City of Oil City, the City of Oil City (Oil City) contracted with Harold Best and Struxures, LLC and Fred Burns, Inc. (collectively Contractors) to reconstruct the concrete stairs to the city library. Contractors completed their work at the end of 2011. In early 2012, Oil City received reports of issues with the stairs. Oil City notified Contractors that it considered the stairs dangerous and that Contractors’ defective workmanship created the condition. Neither Oil City or Contractors took any action to fix the stairs or warn of the danger and the stairs’ condition worsened with time.
On November 23, 2015, David and Kathryn Brown exited the library. Kathryn Brown tripped on one of the deteriorated steps, falling and striking her head. Kathryn suffered a traumatic head injury and passed away six days later. The Estate of Kathryn Brown and David Brown, individually (collectively, the Browns), sued Oil City as the owner of the library and Contractors. With respect to Contractors, the Browns asserted that Contractors’ work on the stairs created a dangerous condition that presented an unreasonable risk of harm to those using the steps.
Read the court decisionRead the full story...Reprinted courtesy of
Michael L. DeBona, White and WilliamsMr. DeBona may be contacted at
debonam@whiteandwilliams.com
KF-103 v. American Family Mutual Insurance: Tenth Circuit Upholds the “Complaint Rule”
May 12, 2016 —
Adria Robinson – Colorado Construction LitigationIn Colorado, the “complaint rule” requires insurance carriers to provide a defense to its insured when the allegations contained in the complaint allege any set of facts that may fall within an insurance policy. Some insurers have pushed back on this rule arguing that it may cause an insurer to exercise its duty to defend although the underlying facts ultimately do not fall within the policy.
In KF 103-CV, LLC v. American Family Mutual Insurance Company, 2015 WL 6517782, the Tenth Circuit of the United States Court of Appeals upheld the complaint rule. In its decision, the Tenth Circuit cited several Colorado state court rulings recognizing the courts’ intent to incentivize insurers to defend policies that may facially fall within the terms of the policy. Where there is uncertainty about coverage, the Tenth Circuit cited a Colorado Supreme Court case stating, “[t]he appropriate course of action for an insurer who believes that it is under no obligation to defend, is to provide a defense to the insured under the reservation of its rights.”
Read the court decisionRead the full story...Reprinted courtesy of
Adria Robinson, Higgins, Hopkins, McLain & Roswell, LLCMs. Robinson may be contacted at
robinson@hhmrlaw.com
