Fairfield Connecticut Building Expert Directory

Adobe Opens New Office Tower and Pledges No Companywide Layoffs in 2023

April 18, 2023 — Edward Ludlow & Brody Ford - Bloomberg
Adobe Inc., breaking ranks with an industry cutting costs and laying off workers, has opened a new office tower in its home city, adding new capacity for staff and pledging no companywide job cuts in 2023. The Founders Tower is an 18-story, 1.25 million-square-foot shimmering glass addition to San Jose, California, a city Adobe has called home since the early ’90s. The software company’s fourth tower has capacity for 3,000 employee workstations, Adobe said Wednesday in a statement. Despite opening a new office with amenities, the company remains supportive of hybrid and flexible work arrangements. “We’re actually committed to continuing to grow here,” Adobe Chief People Officer Gloria Chen said in an interview with Bloomberg Television to air Wednesday. “We are committed to not having companywide layoffs.” Reprinted courtesy of Edward Ludlow, Bloomberg and Brody Ford, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Cause Still Unclear in March Retaining Wall Collapse on $900M NJ Interchange

June 07, 2021 — Stephanie Loder - Engineering News-Record
A probe continues by construction engineer Hardesty and Hanover LLC into what caused the late March collapse of a retaining wall that is part of one of New Jersey's largest roadbuilding projects—the already late-running effort called Direct Connection, which aims to untangle the convoluted interchange of north-south I-295 and east-west Route 42 in Camden County. Reprinted courtesy of Stephanie Loder, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Lawsuit Decries Environmental Assessment for Buffalo, NY, Expressway Cap Project

July 08, 2024 — Justin Rice - Engineering News-Record
The New York Civil Liberties Union has filed a lawsuit against the New York State Dept. of Transportation for redeveloping Buffalo’s Kensington Expressway with a “limited and flawed” environmental assessment. Reprinted courtesy of Justin Rice, Engineering News-Record Mr. Rice may be contacted at ricej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

Sixth Circuit Holds that Some Official Actions Taken in the “Flint Water Crisis” Could Be Constitutional Due Process Violations

March 27, 2019 — Anthony B. Cavender - Gravel2Gavel
In what the Court of Appeals describes as “the infamous government-created environmental disaster known at the Flint Water Crisis,” a panel of the U.S. Court of Appeals for the Sixth Circuit has ruled that some of the government personnel responsible for this disaster may be liable, under 42 U.S.C. § 1983, for monetary damages based on the Substantive Due Process Clause of the Fourteenth Amendment to the Constitution. The case is Guertin, et al., v. State of Michigan, et al., decided on January 4, 2019. On April 25, 2014, the City of Flint, MI, facing a financial crisis, agreed to switch its drinking water supply from the water provided by the Detroit Water and Sewerage Department to untreated water available from the Flint River that would be treated in the waterworks owned and operated by the City. However, the City waterworks could not provide the needed treatment, which resulted in the corrosive Flint River water leaching lead out of the old Flint water pipes. Soon thereafter, a public health and environmental crisis enveloped Flint. Many lawsuits have been filed against many defendants, and many civil and criminal investigations have been opened. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

New NEPA Rule Restores Added Infrastructure Project Scrutiny

May 10, 2022 — Pam McFarland - Engineering News-Record
The White House Council on Environmental Quality has finalized a regulation that restores basic project environmental review practices that were in place prior to changes made during the Trump administration. The rule is the first of two that will have the Biden administration’s stamp on how such reviews are done under the National Environmental Policy Act (NEPA) for major federal construction projects. Reprinted courtesy of Pam McFarland, Engineering News-Record Ms. McFarland may be contacted at mcfarlandp@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

A Tort, By Any Other Name, is Just a Tort: Massachusetts Court Bars Contract Claims That Sound in Negligence

March 20, 2023 — Gus Sara - The Subrogation Strategist
In University of Massachusetts Building Authority v. Adams Plumbing & Heating, Inc., 2023 Mass. App. Unpub. LEXIS 28, 102 Mass. App. Ct. 1107, the Appeals Court of Massachusetts (Appeals Court) considered whether the lower court properly held that the plaintiff’s breach of contract and indemnification claims were time-barred by the statute of repose because they sounded in tort. The Appeals Court held that while the six-year statute of repose only applies to tort claims, they can also bar claims for breach of contract and indemnification if they sound in tort. The Appeals Court affirmed the lower court’s ruling, finding that the plaintiff’s breach of contract and indemnification claims were just negligence claims disguised as non-tort claims. In 2013 and 2014, the University of Massachusetts (UMass) retained various contractors to renovate the dining hall for one of its campus buildings, which included the installation of new ductwork for the kitchen’s exhaust system. The dining hall opened for service in September 2014. In the Spring of 2018, it was discovered that the ductwork for the kitchen had collapsed. Further investigation revealed other deficiencies with the exhaust system. On December 1, 2020, UMass filed a lawsuit against various contractors, asserting negligence, breach of contract, and indemnification. The breach of contract claims alleged breach of express warranties. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

Granting Stay, Federal Court Reviews Construction Defect Coverage in Hawaii

January 06, 2012 — Tred R. Eyerly - Insurance Law Hawaii

The federal district court ultimately stayed a construction defect case, but offered comments on the current status of coverage disputes for such defects in Hawaii. See National Union Fire Ins. Co. of Pittsburgh, Pa. v. Simpson Mfg. Co., 2011 U.S. Dist. LEXIS 128481(D. Haw. Nov. 7, 2011).

National Union filed a complaint for declaratory relief to establish it had no duty to defend or to indemnify Simpson Manufacturing Company in four actions pending in the Hawaii state courts. The state court actions concerned allegedly defective hurricane strap tie hold downs that were manufactured and sold by Simpson. The hurricane ties allegedly began to prematurely corrode and rust, causing cracking, spalling and other damage to homes.

National Union contended the underlying allegations did not constitute "property damage" caused by an "occurrence," as defined in the policies.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES